Fairfield Connecticut Building Expert Directory

Duty to Defend Requires Payments Under Policy's Supplemental Payments Provision

February 16, 2017 — Tred R. Eyerly – Insurance Law Hawaii
The California Court of Appeal determined there was no duty to indemnify and the insured had to reimburse the insurer's contribution to a settlement. Nevertheless, there was a duty to defend, meaning the insured did not have to reimburse amounts it was entitled to under the supplemental payments provision. Navigators Specialty Ins. Co. v. Moorefield Constr., 2016 Cal. App. LEXIS 1132 (Cal. Ct. App. Dec. 27, 2016). Moorefield was the general contractor for a shopping center project to be developed by DBO Development No. 28 (DBO). The project included the construction of a 30,055-square-foot building to by used as a Best Buy store. In January 2002, DBO entered a 15-year lease with Best Buy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Federal Court Finds Occurrence for Faulty Workmanship Under Virginia Law

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
The Federal District Court in Virginia found that allegations of faulty workmanship could arise from an occurrence. Nautilus Ins. Co. v. Strongwell Corp., 2013 U.S. Dist. LEXIS 79163 (W. D. Va. June 4, 2013). Strongwell supplied certain fiberglass reinforced plastic materials to a subcontractor of Black & Veatch for a construction project at power plant. Black & Veatch subsequently sued Strongwell, claiming that numerous defects in Strongwell's materials and work were discovered after the project was completed. The complaint further alleged that as a result of the defects, there was widespread property damage to portions of the power plant. Nautilus defended under a reservation of rights. Nautilus also filed suit for a declaratory judgment that to establish it had no duty to defend or indemnify Strongwell. Strongwell moved to dismiss the complaint insofar as it requested a declaration that there was no duty to defend. Strongwell also filed a motion to stay the coverage action until the underlying case was completed. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Three Reasons Late Payments Persist in the Construction Industry

December 22, 2019 — Patrick Hogan - Construction Executive
Construction professionals are all too familiar with the payment issues that plague the construction industry. Contractors, subcontractors and material suppliers often have to deal with payment delays and even nonpayment—affecting cash flow and their ability to meet expenses. According to an Atradius study, a quarter of all B2B invoices issued in North America are overdue. The construction industry accounted for one-third of those past-due invoices, and many contractors and construction business owners do not have a positive outlook on the industry's payment issues. The same survey found 55% of U.S. firms think there will be no change in the industry’s payment practices over the coming months—one-third even expects an increase in late payments. These findings show that managing cash flow is a significant challenge in the construction industry. Having a negative cash flow will push the company toward financial trouble, which may ultimately lead to its demise. Understanding the reasons why payment issues persist in construction will help contractors protect their business, prevent these issues from happening or at least minimize their effect on the current operations. Reprinted courtesy of Patrick Hogan, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurer Must Pay Portions of Arbitration Award Related to Faulty Workmanship

October 21, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The court determined that portions of an arbitration award against the insured contractor based upon faulty workmanship were covered by the policy. Wallace v. Nautilus Ins. Co., 2019 U.S. Dist. LEXIS 122219 (D. N. H. July 23, 2010). Plaintiffs, owners of adjoining homes, hired McPhail Roofing, LLC to replace the roofs of their houses. After installation, the plaintiffs found several problems with their roofs and withheld roughly a third of the agreed-upon contract price from final payments due to McPhail. A roofing consultant found evidence of water leaking through both roofs during rainstorms. Improper installation of the shakes on the roofs allowed rain to seep through to the roof decks (the plywood underneath the roofs) and eventually into the houses. The only way to cure the installation defects was to remove and replace the roofs entirely. Plaintiffs and McPhail went to arbitration. Plaintiffs sought compensation for the damage caused by the leaking and for the replacement costs of the roofs. McPhail sought the remaining payment under the contracts. Nautilus defended McPhail under this CGL policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Ahlers Distinguished As Top Super Lawyer In Washington And Nine Firm Members Recognized As Super Lawyers Or Rising Stars

August 10, 2020 — Joshua Lane - Ahlers Cressman & Sleight Blog
ACS is very honored and pleased to announce nine members of our firm were awarded the distinction of top attorneys in Washington. Our blog articles usually cover Construction Legal News, but we feel this is a newsworthy accolade to be shared with friends and clients. To become candidates to receiving the Super Lawyer nomination, lawyers are nominated by a peer or identified by research. After completing this first step in the process, Super Lawyer’s research department analyzes 12 indicators, such as experience, honors/awards, verdicts/settlements and others. As for the third step, there is a peer evaluation by practice area. Finally, for step four, candidates are grouped into four firm-size categories. In other words, solo and small firm lawyers are compared only with other solo and small firm lawyers, and large firm lawyers are compared with other large firm lawyers. The process is very selective and only 5 percent of the total lawyers in Washington are nominated as Super Lawyers. John P. Ahlers, one of the firm’s founding partners, was recognized as the Top Lawyer out of all Washington lawyers in the State. Mr. Ahlers stated that “It was humbling to receive this distinction, particularly considering the many talented Super Lawyers in the State and I am a ‘construction lawyer’ to boot! I am grateful for the confidence my many colleagues in the bar have in me, by honoring me with their vote”. Founding partner Paul R. Cressman Jr. and partner Brett M. Hill were both recognized as one of the 100-Best Lawyers in the State. Four other firm members are also recognized as Super Lawyers: Scott R. Sleight, Bruce A. Cohen, Lawrence S. Glosser and Ryan W. Sternoff. Two other firm members, partner Lindsay (Taft) Watkins and associate Scott D. MacDonald are also recognized as Super Lawyer Rising Stars, which recognizes attorneys either 40 years old or younger, or in practice 10 years or less. Read the court decision
Read the full story...
Reprinted courtesy of Joshua Lane, Ahlers Cressman & Sleight
Mr. Lane may be contacted at joshua.lane@acslawyers.com

Mechanic’s Liens- Big Exception

January 22, 2024 — Christopher G. Hill - Construction Law Musings
Musings has discussed mechanic’s liens on numerous occasions. As we discussed in earlier posts, the general rule is that a mechanic’s lien jumps to the head of the line of liens when filed. This is true in most instances. In the typical case, a contractor puts up a building and, when the owner refuses payment, it files a mechanic’s lien that takes priority over all other liens on that property, including the construction loan deed of trust (or mortgage, depending on your state’s property laws). Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Thousands of London Residents Evacuated due to Fire Hazards

June 29, 2017 — David Suggs – Bert L. Howe & Associates, Inc.
Nearly 4,000 residents were ordered by municipal authorities to “urgently evacuate apartments in five London high-rise buildings…after fire inspectors warned that the safety of the residents could not be guaranteed,” reported the New York Times. Displaced families were urged to find shelter with family or friends, but temporary accommodations were offered. Repairs may take up to four weeks. The five London towers that were evacuated all contain the same exterior cladding and insulation that is similar to what was used in Grenfell Tower, where 79 people died in fire only the preceding week, according to the New York Times. Camden Council stated that the cladding material would be removed. They had ordered noncombustible cladding, but later learned that combustible cladding had been installed. “Preliminary tests on the insulation samples from Grenfell Tower show that they combusted soon after the test started,” Detective Superintendent McCormack said in a televised statement, as quoted by the New York Times. “Cladding tiles had also failed initial tests,” she continued. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES