Fairfield Connecticut Building Expert Directory

Allegations Confirm Duty to Defend Construction Defect Claims

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Relying upon the same case cited by the Hawaii Supreme Court in its seminal decision on duty to defend, the federal district court determined the allegations sufficiently established a duty to defend construction defect claims. Voeller Constr. v. Southern-Owners Ins. Co., 2014 U.S. Dist. LEXIS 61862 (M. D. Fla. May 5, 2014). The Bay Harbor Clearwater Condominium Association, Inc. sued Voeller Construction for statutory breach of warranty and building code violations which allegedly caused damage to the condominium structure. The complaint alleged that the damage was unknown to the unit owners at the time they purchased their units. The project was completed in 2007. Expert reports attached to the complaint listed July 7, 2010, as the earliest date of discovery of the damage to the property. The CGL policies were effective from January 24, 2007 to May 9, 2009. Therefore, the insurer argued there was no coverage because the alleged "property damage" was discovered for more than one year after the policies expired. The court determined there was a duty to defend. Citing Trizec Props., Inc. v. Biltmore Constr. Co., 767 F.2d 810 (11th Cir. 1985), the court noted that if the complaint alleged facts which created potential coverage under the policy, the duty to defend was triggered. The Hawaii Supreme Court relied on Trizec and made the same ruling in Dairy Road Partners v. Island Ins Co., Ltd., 92 Haw. 398, 412, 992 P.2d 93, 107 (2000). Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Couple Sues for Construction Defects in Manufactured Home

July 31, 2013 — CDJ STAFF
A West Virginia couple has sued the manufacturer of their home for construction defects and damage. Darrell and Teri Pearson claim that the home they purchased from Giles Industries was defective. They further claim that Kitchen’s Construction failed to set the home up properly and that the firm did not repair damaged sections of home. The suit also names the firm that sold the home and others. Read the court decision
Read the full story...
Reprinted courtesy of

Indiana Appellate Court Allows Third-Party Spoliation Claim to Proceed

August 01, 2023 — Ryan Bennett - The Subrogation Strategist
In Safeco Insurance Company of Indiana as Subrogee of Ramona Smith v. Blue Sky Innovation Group, Inc., et al, No. 22A-CT-1924, 2023 Ind. App. LEXIS 157, the Court of Appeals of Indiana (Appellate Court) reversed a trial court ruling that granted the motion to dismiss filed by Michaelis Corporation (Michaelis), a restoration company. The Appellate Court ruled that the trial court erred in dismissing the plaintiff’s spoliation and negligence claims against Michaelis, who discarded evidence relating to the cause of the fire at issue. The plaintiff’s insured owned a home in Indianapolis, Indiana. On Halloween night in 2019, a fire occurred at the property. The plaintiff’s representatives preliminarily determined that the fire may have been caused by a digital dehydrator within the kitchen. Michaelis had a representative present at the site inspection and was allegedly told to preserve the kitchen area. That area was taped off with “caution” tape. Michaelis also placed a tarp over the kitchen to prevent weather damage. Despite the instructions and precautions, Michaelis demolished the kitchen and discarded the dehydrator along with other fire debris. Read the court decision
Read the full story...
Reprinted courtesy of Ryan Bennett, White and Williams LLP
Mr. Bennett may be contacted at bennettr@whiteandwilliams.com

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the court decision
Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

Wage Theft Investigations and Citations in the Construction Industry

October 11, 2017 — Evelin Y. Bailey - California Construction Law Blog
This month we share some cautionary tales for employers in the construction industry. During the past several months the California Labor Commissioner has cited or filed suit against several construction companies. In one investigation, a general contractor was held equally responsible for wages owed by a subcontractor to its employees. The lesson learned from these stories is that now more than ever it is important to have in place proper wage and hour practices and to conduct periodic audits of those practices, including those of your lower tiered contractors, preferably by experienced legal counsel. Read the court decision
Read the full story...
Reprinted courtesy of Evelin Y. Bailey, California Construction Law Blog

Construction Safety Technologies – Videos

November 02, 2017 — Aarni Heiskanen - AEC Business
Smart hard hats, drone imaging, indoor positioning, and augmented reality are some of the technologies that can make construction sites safer. Construction remains one of the most dangerous industries. In the USA, one in ten construction workers are injured every year. According to ILO, there are at least 60,000 fatal accidents on construction sites around the world every year, one in every 10 minutes. Investments in safety will certainly pay off. Culture, behavior, and attitudes have a great impact on construction safety. Technology can help, but only if it is used properly and consistently. Here’s a collection of recent videos that explain and demonstrate how digital technology can advance construction safety. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

Five Construction Payment Issues—and Solutions

October 03, 2022 — Michael Bignold - Construction Executive
Sales are important for construction companies that want to succeed. However, while companies certainly need to spend time on sales and marketing, having a full order book is only part of the equation. They still need to do the work and, even more importantly, they need to be able to collect payment from customers. Here are common payment issues in the construction industry and what leaders can do to prevent or mitigate them. 1. Change Order Disputes If a project goes exactly as planned and quoted, billing the customer is a fairly simple matter. However, it’s very rare that any job goes exactly according to the quote in the construction business. Change orders, omissions and additions are typical on jobs of any size across the industry. If contractors are not handling those changes properly by getting everything in writing, they could be in trouble when the time comes to send invoices. Reprinted courtesy of Michael Bignold, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES