FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Evaluating Construction Trends From 2023 and Forecasting For 2024

February 12, 2024 — Jason Feld & Dominic Donato - Kahana Feld
As we begin 2024, it is informative to evaluate what transpired in 2023 in the construction industry, and especially the use of construction technology. 2023 ushered in a variety of newly implemented construction technologies including 3D printed entire houses, improved wearables that detect all aspects of the construction worker from location to temperature to heart rate, increased use of modular construction for entire apartments, hotels, and condominium projects, and eco-friendly and conservation minded technologies to minimize carbon footprint, water preservation and sustainable construction methods, to name a few. 2023 also identified some significant issues in the construction industry. First and foremost, the labor shortages and hiring of skilled and qualified workers continued to be an issue resulting in increased delays, construction accidents, and project mismanagement. The skyrocketing interest rates, decline in commercial/office projects, supply chain issues, material price fluctuation and increase changes in scope of projects all negatively impacted the construction industry in 2023. There is also the demand for renewable and infrastructure projects put strain on construction resources as the projects became “mega” with larger and more complex construction leading to multi-party, high dollar, and more complex claims. Finally, there is a growing trend of construction claims and litigation being financed by third party litigation funding sources for personal/bodily injury claims and construction defect claims. Reprinted courtesy of Jason Feld, Kahana Feld and Dominic Donato, Kahana Feld Mr. Feld may be contacted at jfeld@kahanafeld.com Mr. Donato may be contacted at ddonato@kahanafeld.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Proposed Bill Provides a New Federal Tax Credit for the Conversion of Office Buildings

September 06, 2021 — Emily K. Bias & Brittany Griffith - Gravel2Gavel Construction & Real Estate Law Blog
At the end of July 2021, a bill was introduced in the House and Senate, which, if enacted, would create a federal tax credit to fund the conversion of unused office buildings into residential, commercial, or mixed-use properties. The Revitalizing Downtowns Act (S. 2511), which is modeled after the federal historic rehabilitation tax credit, would provide a federal tax credit equal to 20 percent of “qualified conversion expenditures” with respect to a “qualified converted building.” A “qualified converted building” means any building that (i) was nonresidential real property for lease to office tenants, (ii) has been “substantially converted” from an office use to a residential, retail, or other commercial use, (iii) in the case of conversion to residential units, is subject to a state or local affordable housing agreement or has at least 20 percent of the units rent restricted and set aside for tenants whose income is 80 percent or less of area median gross income, (iv) was initially placed in service at least 25 years before the beginning of conversion, and (v) may be depreciated or amortized. Reprinted courtesy of Emily K. Bias, Pillsbury and Brittany Griffith, Pillsbury Ms. Bias may be contacted at emily.bias@pillsburylaw.com Ms. Griffith may be contacted at brittany.griffith@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Contractors Set to Implement Air Quality Upgrades for Healthier Buildings

April 12, 2021 — Nate Echtenkamp - Construction Executive
As people spend more time in offices, stores and other buildings, and colder weather forces many outdoor activities to be held indoors during the COVID-19 pandemic, construction contractors are increasingly being asked by building owners and operators to provide various mitigation strategies to improve indoor air quality to help occupants avoid being exposed to lingering airborne viral particles. Lowering the concentration of SARS-CoV-2 and other pathogens in enclosed public spaces is of the utmost importance nowadays given that Americans, on average, spend nearly 90% of their time indoors, according to the EPA. It’s fairly common knowledge that the best way to avoid infection is to follow guidelines issued by the Centers for Disease Control and Prevention that include:

• wearing masks or other face coverings;
• frequent hand-washing;
• physical distancing of at least six feet; and
• deep-cleaning procedures.

Reprinted courtesy of Nate Echtenkamp, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Florida Governor Signs Construction Defect Amendments into Law

September 17, 2015 — Beverley BevenFlorez-CDJ STAFF
According to Jeffrey Gilbert and Anaysa Gallardo Stutzman of Cozen O’Connor, Rick Scott, governor of Florida, signed HB 87 into law, which “amends the notice and opportunity to cure provisions of Chapter 558, Florida’s Construction Defect Statute.” The amendments go into effect October first. HB 87 requires “property owners to provide concrete details of the alleged defects.” Gilbert and Stutzman claimed, “Overall, these amendments seek to further the intended public policy purpose of Chapter 558, which is to provide an alternative dispute resolution mechanism and result in fewer lawsuits and lower litigation costs incurred by parties involved in construction defect matters.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

Supreme Court Set to Alter Law on Key Project, Workforce Issues

December 02, 2019 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
With its term now under way, the U.S. Supreme Court could change federal laws with industry impact—from where huge pipelines can be built and new regulation of pollution in groundwater to whether LGBTQ workers have anti-bias rights under the 1964 Civil Rights Act. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record Mr. Rubin may be contacted at rubind@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Canada's Ex-Attorney General Set to Testify About SNC-Lavalin Scandal

April 03, 2019 — Associated Press - Engineering News-Record
TORONTO (AP) — Canada's former attorney general is expected to testify Wednesday about whether she was inappropriately pressured by Prime Minister Justin Trudeau's office to avoid prosecuting a major Canadian engineering company. Ex-Attorney General Jody Wilson-Raybould has said she wants to tell "her truth" and she will speak at a hearing of the Parliament justice committee. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

---

Mortgage Bonds Stare Down End of Fed Easing as Gains Persist

October 29, 2014 — Jody Shenn – Bloomberg
The end of the Federal Reserve’s third round of bond purchases is proving to be a non-event for mortgage-backed debt. That’s partly because even though the U.S. central bank won’t be adding more home-loan securities to its balance sheet, policy makers will still be buying enough to prevent its holdings from shrinking. Those purchases are having a greater impact as the pace of net issuance slows to a quarter of the amount last year amid a weaker property market. The $5.4 trillion market for government-backed mortgage bonds is defying predictions for a slump tied to the wind-down of the Fed stimulus program, whose completion economists predict will be announced today. Yields on benchmark Fannie Mae (FNMA) notes have shrunk 0.14 percentage point this year relative to government debt, narrowing to within 1.09 percentage points of an average of five- and 10-year Treasury rates. Read the court decision
Read the full story...
Reprinted courtesy of Jody Shenn, Bloomberg
Ms. Shenn may be contacted at jshenn@bloomberg.net

---