Seattle Washington Building Expert Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Professional Liability Client Alert: Law Firms Should Consider Hiring Outside Counsel Before Suing Clients For Unpaid Fees

March 31, 2014 — David W. Evans and Blythe Golay - Haight Brown & Bonesteel LLP
Law firms seeking to recover attorney’s fees as the prevailing party in fee dispute litigation with their former client should hire outside counsel in order to avoid waiving any entitlement to such fees. Evaluating any potential exposure for a professional negligence claim or cross-claim before filing suit should also be considered. In Soni v. Wellmike Enterprise Company, Ltd., et al., No. B242288 (filed March 26, 2014) the California Court of Appeal for the Second District held that a law firm, represented by its own employees and associates, was not entitled to recover attorney fees as the prevailing party, pursuant to the attorney’s fee provision in the retainer agreement. The Soni decision is the latest addition to the general prohibition enunciated by Trope v. Katz (1995) 11 Cal.4th 274 (“Trope”) and its progeny that law firms are precluded from recovering attorney’s fees for self-representation. In Soni, the law firm obtained a $28,384 judgment for delinquent legal fees against a former client. The firm then filed a motion for attorney’s fees, seeking $120,912 as the fees it incurred as the prevailing party under the retainer agreement. The trial court denied the motion based on the general rule set forth in the Trope line of cases that fees are not recoverable where the firm is represented by attorneys employed by the firm, despite the presence in the applicable retainer agreement of a clause notifying the client that fees the law firm would seek if it prevailed would include those for its in-house personnel. Reprinted courtesy of David W. Evans, Haight Brown & Bonesteel LLP and Blythe Golay, Haight Brown & Bonesteel LLP Mr. Evans may be contacted at devans@hbblaw.com; Ms. Golay may be contacted at bgolay@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Environmental and Regulatory Law Update: New Federal and State Rulings

April 19, 2022 — Anthony B. Cavender - Gravel2Gavel
The first quarter of 2022 has yielded a number of decisions, reversals and agency adjustments worth note. FEDERAL CIRCUIT U.S. Court of Appeals for the D.C. Circuit – Food & Water Watch v. Federal Energy Regulatory Commission On March 11, 2022, the court decided the FERC case. On December 19, 2019, the Commission issued a Certificate to Tennessee Gas Pipeline and determined that a “modest expansion” and upgrade of the existing 11,000-mile natural gas pipeline would have no significant environmental impact. However, one of the Commissioners filed a partial dissent, arguing that the Commission’s treatment of the climate change impacts was inadequate. A petition for review was filed, and now the court has decided that the Commission erred in not accounting for the indirect effects of the expansion, namely the downstream emissions of greenhouse gas generated by the pipeline’s delivery of the gas to its customers. Consequently, NEPA’s requirement that a rigorous environmental assessment be made before the authorization was granted was violated. However, the court decided against vacating the Commission’s orders, which would have had a “disruptive effect” on the project which is, or soon will be, operational. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Court Retained Jurisdiction to Enforce Settlement Under Code of Civil Procedure Section 664.6 Despite Dismissal of Complaint

October 21, 2024 — Garret Murai - California Construction Law Blog
Attorneys will commonly add a Code of Civil Procedure section 664.6 provision in their settlement agreements to ensure that courts have continuing jurisdiction to enforce the terms of a settlement, as opposed to having to file a new complaint in the event of a breach of a settlement agreement. Oral settlements before a trial court are also enforceable under Section 664.6, but as discussed in Eagle Fire and Water Restoration, Inc. v. City of Danuba, Case No. F086052 (May 30, 2024), in cases involving a complaint and multiple cross-complaints, questions can arise as to whether a trial court has in fact retained jurisdiction under Section 664.6 to enforce an oral settlement and even what the terms of the settlement were. The Eagle Fire Case Eagle Fire and Water Restoration, Inc. was hired by the City of Dinuba to reroof the City’s police station and courthouse building. The contract was for approximately $500,000. Before completion of the project, a rainstorm caused significant water damage to the interior of the building. The City incurred over $330,000 in clean-up and repair costs and withheld approximately $319,000 from Eagle as an offset. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Utility Contractor Held Responsible for Damaged Underground Electrical Line

October 11, 2017 — Brett M. Hill - Ahlers & Cressman, PLLC
The Washington State Court of Appeals recently addressed an excavation contractor’s responsibilities under the Underground Utilities Damage Prevention Act (UUDPA), RCW 19.122. That statute was enacted in 2011 and imposed certain statutory duties on parties involved with projects requiring excavation. In this case, Titan Earthworks, LLC contracted with the City of Federal Way to perform certain street improvements including installation of a new traffic signal. During the process of excavating for the traffic signal, Titan drilled into an energized underground Puget Sound Energy power line. PSE sought damages from Titan and Titan sued the City of Federal Way. Read the court decision
Read the full story...
Reprinted courtesy of Brett M. Hill, Ahlers & Cressman, PLLC
Mr. Hill may be contacted at bhill@ac-lawyers.com

No Coverage for Construction Defect Claim Only Impacting Insured's Work

January 08, 2024 — Tred R. Eyerly - Insurance Law Hawaii
In a coverage dispute between two insurers over a claim for damages caused by faulty workmanship, the court found there was no right to equitable contribution or indemnity. Travelers Prop. Cas. Co. of Am. v. Mallcraft, Inc., 2023 Cal. Super. LEXIS 67568 (Cal. Super. Ct. Sept. 15, 2023). Mallcraft was the general contractor for a building project and was sued for construction defects. Travelers was an additional insured under a policy issued to a subcontractor, KitCor. Travelers defended Mallcraft in an arbitration. Travelers sought equitable contribution and equitable indemnity from Hartford, Mallcraft's insurer. Mallcraft and Travelers stiulated to a judgment agianst Mallcraft for all costs Travelers incurred in the arbitration. Travelers' insured, KitCor, was not implicated in the construction defect claims against Mallcraft. The judgment set forth findings, including the fact that the underlying plaintiff never made any claim that KitCor perfomred work on the project or casued property damage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Homebuilders Leading U.S. Consumer Stocks: EcoPulse

February 14, 2014 — Anna-Louise Jackson and Anthony Feld – Bloomberg
Shares of U.S. homebuilders are leading consumer discretionary stocks as the new home market is poised to rebound faster than other cyclical purchases this year. The Standard & Poor’s Supercomposite Homebuilding Index -- made up of Toll Brothers Inc. (TOL), NVR Inc. and nine others -- has risen 20 percent since Nov. 11. The S&P 500 GICS Consumer Discretionary Sector Index -- which includes Lennar Corp. (LEN), PulteGroup Inc. (PHM), D.R. Horton Inc. and 81 other companies such as Home Depot Inc. and Lowe’s Cos. -- is up 1.9 percent during the same period. This follows about 10 months when homebuilders lagged behind by 45 percentage points. Shares of companies that construct new residences are a source of relative strength in what’s proven to be a “more difficult market” this year, as the S&P 500 slid almost 6 percent in less than three weeks, said Michael Shaoul, chairman and chief executive officer of Marketfield Asset Management LLC in New York, which has more than $20 billion in assets. The recent rally in homebuilders suggests “a very important transition of leadership within the consumer discretionary sector” is underway, benefiting this segment of the broader cyclical group, he said. Ms. Jackson may be contacted at ajackson36@bloomberg.net; Mr. Feld may be contacted at afeld2@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Anna-Louise Jackson and Anthony Feld, Bloomberg

Not So Universal Design Fails (guest post)

April 28, 2016 — Melissa Dewey Brumback – Construction Law in North Carolina
Today we have a guest post from Carla Williams, who works in customer service for the Williams Brothers Corporation of America. Carla humorously brings light to a serious problem– the intent behind ADA and Universal Design is very often not met with poorly-thought out applications in the real world. Enjoy, and feel free to leave a comment for Carla below. Universal design is the idea that architecture should be inherently accessible to everyone. The growing number of architects adopting universal design is great news for people with accessibility needs. Instead of having separate entrances and walkways to make a building accessible, universal design allows people of all abilities to move together. Unfortunately, many buildings are stuck back in 1990 right after the Americans with Disabilities Act was made law. These buildings may be technically “accessible,” but they aren’t spaces people with accessibility needs can maneuver very easily. Until all building designers come to understand and implement the beauty and functionality of universal design, the world is left with less than ideal accessibility. “Less than ideal” is a bit of an understatement. Many times full-on “accessibility fails” take place. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett PLLC
Ms. Brumback may be contacted at mbrumback@rl-law.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES