SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Implied Warranty Claims–Not Just a Seller’s Risk: Builders Beware!

May 10, 2021 — Carin Ramirez - Colorado Construction Litigation
One of the thorns in the side of every construction defect defense litigator is the implied warranty claim. The “implied warranty” is a promise that Colorado law is “implied” into every contract for a sale of a new home that the home was built in a workmanlike manner and is suitable for habitation. Defense attorneys dislike the implied warranty claim because it is akin to a strict liability standard. All that is required to provide the claim is that an aspect of construction is found to be defective — i.e., inconsistent with the building code or manufacturer’s installation instructions — regardless of whether the work was performed to the standard of care. The implied warranty claim is therefore easier to prove than a negligence claim, where a claimant must prove that a construction professional’s work fell below a standard of reasonable care. Additionally, it is not a defense to an implied warranty claim that the homeowners or the HOA are, themselves, partially liable for the defects where damage is due in part to insufficient or deferred maintenance, as it is for negligence claims. The only redeeming aspect to the implied warranty claim was that, until recently, it was believed that it could only be asserted by a first purchaser against the seller of an improvement, because the implied warranty arises out of the sale contract. Recently, the Colorado Court of Appeals opinion in Brooktree Village Homeowners Association v. Brooktree Village, LLC, 19CA1635, decided on November 19, 2020, extended the reach of the implied warranty — though just how far remains to be seen. Specifically, a division of the Court of Appeals held that an HOA can assert implied warranty claims on behalf of its members for defects in common areas, even where there is no direct contractual relationship between the parties to base the warranty upon. Read the court decision
Read the full story...
Reprinted courtesy of Carin Ramirez, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Ramirez may be contacted at ramirez@hhmrlaw.com

---

To Arbitrate or Not to Arbitrate? That is the Question

April 28, 2016 — Garret Murai – California Construction Law Blog
It’s been the fodder of debate of philosophers, academics and the rest of us for ages:

• Do we have free will or are our actions predetermined and the result of preceding events?
• Are human beings fundamentally selfless or self preserving?
• Coca-Cola or Pepsi?
• iOs or android?

And for litigators and their clients, including us construction lawyers, arbitration or litigation? Or, in short, if a project goes sideways, in what forum will you resolve your dispute? It’s an important question the answer to which could mean the difference between winning or losing. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Tacoma Construction Site Uncovers Gravestones

August 11, 2011 — CDJ STAFF

The Seattle Times reports that a transit construction project has uncovered about twenty-five gravestones. The area was historically sensitive, as it is in territory once occupied by the Puyallup Tribe. At current report, no human remains have been found and the article cites the project?s archeological consultant as describing the gravestones as “not historically significant.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Texas Supreme Court Rules That Subsequent Purchaser of Home Is Bound by Original Homeowner’s Arbitration Agreement With Builder

May 29, 2023 — Kim Altsuler - Peckar & Abramson, P.C.
In a new opinion Lennar Homes of Texas Land and Construction, Ltd., et al. v. Kara Whiteley, Cause No. 21-0783, 66 Tex. Sup. Ct. J. 8740, issued May 12, 2023, the Texas Supreme Court partially reversed two lower court decisions and held that an arbitration provision contained in the original homeowner’s contract with the builder was binding on a subsequent homeowner. In the decision, the court found that Kara Whiteley—the second owner of the home in Galveston, Texas—was bound to arbitrate her construction defect claims with Lennar by virtue of the doctrine of “direct-benefits estoppel.” The rationale was based on the fact that Whitely was seeking benefits emanating from Lennar’s contract with the original homeowner. The residence in question was first purchased from Lennar in May 2014. Whiteley purchased the home in July 2015. The original contract documents included several arbitration provisions—one in the Purchase and Sale Agreement, one in the Limited Warranty issued by Lennar, and one in the general warranty deed. Whiteley sued Lennar in Galveston County District Court alleging mold growth and other defects at the property. Lennar moved for arbitration and its motion was granted. The parties arbitrated the case and Lennar received an award in its favor. Lennar then moved the District Court to confirm the arbitration award, and Whiteley filed a cross-motion to vacate the award, arguing that Lennar’s original motion to compel arbitration should not have been granted. The District Court agreed with Whiteley, vacating the arbitration award. Lennar appealed. The Court of Appeals affirmed the District Court’s vacatur, and Lennar appealed to the Texas Supreme Court. Read the court decision
Read the full story...
Reprinted courtesy of Kim Altsuler - Peckar & Abramson, P.C.
Ms. Altsuler may be contacted at kaltsuler@pecklaw.com

---

Who Says You Can’t Choose between Liquidated Damages or Actual Damages?

October 11, 2017 — Kevin Walton - Snell & Wilmer Real Estate Litigation Blog
In Colorado, courts enforce liquidated damages provisions if three elements are satisfied: (1) the parties intended to liquidate damages; (2) the amount of liquidated damages was a reasonable estimate of the presumed actual damages caused by a breach; and (3) at the time of contracting, it was difficult to ascertain the amount of actual damages that would result from a breach. But what happens when a contract gives a party a right to choose between liquidated damages or actual damages? This seems troublesome because it allows a party to set the floor for their damages without limitation if actual damages exceed the contractual amount. As a matter of first impression, the Colorado Supreme Court addressed this issue in Ravenstar, LLC v. One Ski Hill Place, LLC, 401 P.3d 552 (Colo. 2017). In Ravenstar, plaintiffs contracted to buy condominiums from a developer. As part of their contracts, plaintiffs deposited earnest money and construction deposits equal to 15% of each unit’s purchase price. Plaintiffs breached their contract by failing to obtain financing and failing to close by the closing date. Each contract’s damages provision provided that if a purchaser defaulted, the developer had the option to retain all or some of the deposits as liquidated damages or, alternatively, to pursue actual damages and apply the deposits to that award. After plaintiffs defaulted, the developer chose to keep plaintiffs’ deposits as liquidated damages. Plaintiffs sued for return of their deposits. Read the court decision
Read the full story...
Reprinted courtesy of Kevin Walton, Snell & Wilmer
Mr. Walton may be contacted at kwalton@swlaw.com

---

Pulled from the Swamp: EPA Wetland Determination Now Judicially Reviewable

September 15, 2016 — CDJ STAFF
Landowners and developers bogged in an EPA wetland determination were recently thrown a life line when the United States Supreme Court determined The Army Corps of Engineer’s (Corps) “jurisdictional determinations” (JD) regarding wetland designations are reviewable by the court. United States Army Corps of Engineers v. Hawkes Co. Inc. Under the Clean Water Act (CWA) landowners and developers who do not have the proper permits can face severe criminal and civil penalties for releasing any pollutant into “the waters of the United States.” Anybody stuck wading through the permitting process will tell you it is difficult, time consuming, expensive, and may eventually prohibit the intended use of the property. Furthermore, there is yet to be a consensus on the definition or scope of the term “waters of the US”. Consequently, a landowners or developers may never be certain whether a permit is necessary before conducting any activity that may discharge a pollutant into a “water of the United States”. Read the court decision
Read the full story...
Reprinted courtesy of Sean Minahan, Lamson, Dugan and Murray, LLP
Mr. Minahan may be contacted at sminahan@ldmlaw.com

---

Court Slams the Privette Door on Independent Contractor’s Bodily Injury Claim

May 06, 2019 — Brett G. Moore, Michael C. Parme, Lindsey N. Ursua & Lawrence S. Zucker II - Haight Brown & Bonesteel LLP
In Johnson v. The Raytheon Company, Inc., Case No. B281411 (2019) WL 1090217, plaintiff Laurence Johnson (Johnson) was a maintenance engineer employed by an independent contractor that provided control room staff to defendant Raytheon Company, Inc. (“Raytheon”). Johnson was monitoring the computers in the control room when he received low water level alarms pertaining to the water cooling towers. Johnson went to the cooling tower wall in order to look over the wall and verify the water level. Johnson saw the upper half of an extension ladder leaning against the cooling tower’s wall. The ladder had a warning sign which said, “CAUTION” and “THIS LADDER SECTION IS NOT DESIGNED FOR SEPARATE USE.” Despite these warnings, Johnson used the ladder. As he was climbing the ladder it slid out causing him to fall and suffer injuries. Johnson sued Raytheon, the hirer of the independent contractor, arguing the ladder, among other things, was unsafe and lead to Johnson’s injuries. Johnson believed that Raytheon’s course of conduct of leaving a platform ladder (as opposed to the extension ladder) at the wall constituted an implied agreement to always have one present, on which the independent contractor’s employees relied. Johnson further argued that Raytheon was negligent in providing a dangerous extension ladder, as opposed to a platform ladder, at the wall on the night of the accident. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Brett G. Moore, Michael C. Parme, Lindsey N. Ursua and Lawrence S. Zucker II Mr. Moore may be contacted at bmoore@hbblaw.com Mr. Parme may be contacted at mparme@hbblaw.com Ms. Lindsey may be contacted at lursua@hbblaw.com Mr. Lawrence may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---