Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor
September 09, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project.
In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Housing Advocacy Group Moved to Dissolve New Jersey's Council on Affordable Housing
November 05, 2014 —
Beverley BevenFlorez-CDJ STAFFThe New Jersey Law Journal reported that "[a]n affordable housing advocacy group in New Jersey is asking the state Supreme Court to remove from the administration of Gov. Chris Christie the authority to determine municipalities’ obligations for low- and moderate-income housing and to instead place that responsibility in the hands of trial judges."
New Jersey's state constitution mandates affordable housing obligations (referred to as the Mount Laurel decisions).
“It is no longer possible to trust that COAH can or will faithfully implement the Mount Laurel doctrine,” wrote the center’s associate director, Kevin Walsh, in the motion to enforce litigants’ rights, as quoted by the New Jersey Law Journal. “This should be the end; there should be no more extensions, no further last chances.”
Municipalities are protected from being sued by developers, however, last year the court stated "that it would consider lifting that protection if COAH failed to adopt new regulations that passed constitutional muster," according to the New Jersey Law Journal.
Read the court decisionRead the full story...Reprinted courtesy of
Designers George Yabu and Glenn Pushelberg Discuss One57’s Ultra-Luxury Park Hyatt
July 30, 2014 —
Jennifer Parker – BloombergOne57 might just be the hottest -- or at least the most expensive -- address in New York City.
The $375 million skyscraper currently piercing its blue-glass presence into Manhattan's midtown skyline is home not only to 94 private condos (two of which have already sold for $90 million); it also hosts a brand new Park Hyatt hotel, which opens this August.
Eight years in the making, this Hyatt is the first ultra-luxury hotel New York has seen since the Mandarin Oriental opened in 2003. It's intended to be a New York icon. So, naturally, Hyatt hired two Canadian guys to design it.
Meet George Yabu and Glenn Pushelberg, the dynamic couple who met as college students in Toronto in 1972, and decided to launch design firm YabuPushelberg. Now, they're earning millions per project to design luxury hotels, restaurants, and residences all over the world.
Read the court decisionRead the full story...Reprinted courtesy of
Jennifer Parker, Bloomberg
Fannie Overseer Moves to Rescue Housing With Lower Risk to Lenders
May 21, 2014 —
Kathleen M. Howley – BloombergMelvin Watt, the overseer of Fannie Mae and Freddie Mac, broke five months of silence to help boost lending as slowing sales threatens the housing recovery.
Watt, 68, in his first speech as director of the Federal Housing Finance Agency, announced new rules to reduce the risk that lenders will have to repurchase bad mortgages. The changes, designed to allow banks to relax credit standards, probably will increase housing sales by 5 percent this year, said Stephanie Karol, an economist at Englewood, Colorado-based research firm IHS Inc.
“It means a restart for the real estate recovery,” said Mark Zandi, chief economist of Moody’s Analytics Inc. “We’re not going to get back on track until we start making credit more available to potential buyers.” He said he expects Watt’s moves to spur “meaningful” sales growth.
Read the court decisionRead the full story...Reprinted courtesy of
Kathleen M. Howley, BloombergMs. Howley may be contacted at
kmhowley@bloomberg.net
Partner Bradley T. Guldalian Secures Summary Judgment Win for National Hotel Chain
August 26, 2019 —
Bradley T. Guldalian - Traub LiebermanOn June 26, 2019, Traub Lieberman Straus & Shrewsberry LLP Partner Bradley T. Guldalian secured summary judgment on behalf of a national hotel chain in a slip and fall accident filed in Osceola County Circuit Court in Kissimmee, Florida. The underlying loss occurred when the Plaintiff slipped and fell in a puddle of water allegedly existing in the hotel’s laundry room and suffered a partial thickness rotator cuff tear involving the distal infraspinatus tendon for which he underwent surgery and incurred over $70,000 in medical bills. The Plaintiff filed a premises liability action against the hotel claiming the hotel had failed to maintain its premises in a reasonably safe condition proximately causing the Plaintiff’s fall and resulting injuries.
After discovery closed, Mr. Guldalian filed a motion for summary judgment on behalf of the hotel arguing that to prevail in a negligence claim involving a “transitory foreign substance”, such as water on a floor, an injured party must plead and prove pursuant to Florida Statute 768.0755 that the business establishment had actual or constructive knowledge of the dangerous condition and should have taken action to remedy it prior to the time of the alleged fall. Constructive knowledge may be proven by circumstantial evidence showing that (1) the dangerous condition existed for such a length of time that, in the exercise of ordinary care, the business establishment should have known of the condition or (2) that the condition occurred with such regularity that it was foreseeable that the condition would be present on the day the injury occurred.
Read the court decisionRead the full story...Reprinted courtesy of
Bradley T. Guldalian, Traub LiebermanMr. Guldalian may be contacted at
bguldalian@tlsslaw.com
Candis Jones Named to Atlanta Magazine’s 2021 “Atlanta 500” List
March 01, 2021 —
Candis Jones - Lewis Brisbois NewsroomAtlanta Partner Candis Jones has been named to Atlanta Magazine’s 2021 “Atlanta 500” list of the most powerful business leaders in Atlanta. To compile this list, the publication reviewed nominations from the public and consulted experts across various sectors. The magazine’s editors and writers considered not only the status of the nominees within their respective organizations, but also whether the nominees were visionary by, for example, leading programs for their communities or creating opportunities for employees.
Ms. Jones is a member of Lewis Brisbois’ General Liability Practice. Representing a wide array of clients, including Fortune 500 companies, insurance carriers, and a major metropolitan transit authority, she focuses her practice on insurance defense, premises liability, personal injury, and medical malpractice. She was recently installed as the President of the Gate City Bar Association, the oldest African-American bar association in the state of Georgia, and also serves as a member of the Georgia Defense Lawyers Association and the Georgia Association of Black Women Attorneys.
Read the court decisionRead the full story...Reprinted courtesy of
Candis Jones, Lewis BrisboisMs. Jones may be contacted at
Candis.Jones@lewisbrisbois.com
10 Haight Lawyers Recognized in Best Lawyers in America© 2023 and The Best Lawyers: Ones to Watch 2023
August 22, 2022 —
Haight Brown & Bonesteel LLPFour Haight Brown & Bonesteel LLP attorneys were selected for Best Lawyers in America© 2023. Congratulations to:
- Bruce Cleeland – Product Liability Litigation – Defendants
- Peter Dubrawski – Product Liability Litigation – Defendants
- Denis Moriarty – Insurance law
- Ted Penny – Workers’ Compensation Law – Claimants
Six Haight Brown & Bonesteel LLP attorneys were selected for Best Lawyers®: Ones to Watch 2023. Congratulations to:
- Courtney Arbucci – Personal Injury Litigation – Defendants; Product Liability Litigation – Defendants
- Frances Brower – Product Liability Litigation – Defendants
- Kyle DiNicola – Transportation Law
- Arezoo Jamshidi – Appellate Practice; Transportation Law
- Kristian Moriarty – Transportation Law
- Bethsaida Obra-White – Construction Law; Insurance Law; Personal Injury Litigation – Defendants
Read the court decisionRead the full story...Reprinted courtesy of
Haight Brown & Bonesteel LLP
Updates to the CEQA Guidelines Have Been Finalized
February 06, 2019 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogThe California Natural Resources Agency (CNRA) recently posted final adopted text for amendments to the CEQA Guidelines. The result of over five years of development efforts by the Governor’s Office of Planning & Research and CNRA, the amendments are the most comprehensive update to the CEQA Guidelines since 1998. In “Natural Resources Agency Finalizes Updates to the CEQA Guidelines,” Pillsbury environmental attorneys Norman F. Carlin, Kevin Ashe and Eric Moorman explore the wide range of issues covered in the amendments, including the new Vehicle-Miles-Traveled (VMT) methodology for analyzing transportation impacts; use of regulatory standards as significance thresholds; environmental baselines; and numerous procedural and technical improvements.
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team