Cambridge Massachusetts Building Expert Directory

OSHA’s New Severe Injury and Fatality Reporting Requirements, Are You Ready?

December 31, 2014 — Craig Martin – Construction Contractor Advisor
Last September, OSHA announced its final rules for reporting severe injuries and fatalities. The new rules take effect on January 1, 2015. Are you ready? The New Rule Requirements

OSHA’s severe injury and fatality reporting requirements apply to all employers covered by OSHA, not just those with 10 or more employees.
All employee work-related fatalities must be reported within 8 hours of the death. The previous rule required reporting only when 3 or more employees suffered a work related fatality.

Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Contractors: A Lesson on Being Friendly

April 06, 2016 — Garret Murai – California Construction Law Blog
I know. You’re just trying to be friendly. Don’t. Particularly when you’re a contractor bidding on a public works project. Those dinners at swanky restaurants, tickets to The Jersey Boys, and all expense paid trips to the Napa Valley have a way of appearing less “friendly” in hindsight, and more like bribery, or as they say, “pay to play.” In Sweetwater Union High School District v. Gilbane Building Company, California Court of Appeals for the Fourth District, Case No. D067383 (February 24, 2016), three contractors, Gilbane Building Company (“Gilbane”), The Seville Group, Inc. (“Seville”) and Gilbane/SGI Joint Venture (“Gilbane/SGI”) (collectively “Contractors”) were sued by the Sweetwater Union School District (“District”) to void their contracts with the District and for disgorgement of all monies paid to them under Government Code section 1090 after it was discovered that the Contractors had engaged in a “pay to play” scheme involving several officials of the District. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Requesting an Allocation Between Covered and Non-Covered Damages? [Do] Think Twice, It’s [Not Always] All Right.

October 12, 2020 — Todd Likman - Colorado Construction Litigation
As is often the case in construction defect and other insurance defense litigation, a plaintiff’s claims for relief typically encompass both covered and uncovered damages. Obviously, it is in the insured’s best interests to have as many damages covered by insurance as possible. From the insurer’s perspective and against the backdrop of owing duty of good faith and fair dealing to its insureds, however, it is generally better to have an allocation of covered vs. non-covered damages. This places the insurer, insured, and insurance retained defense counsel in a difficult position. A recent opinion from U.S. District Court for the District of Colorado, Rockhill Ins. Co. v. CFI-Global Fisheries Mgmt, Civil Action No. 1:16-CV-02760-RM-MJW, 2020 U.S. Dist. LEXIS 35209 (D. Colo. Mar. 2, 2020), sheds light on the issue, even though some may feel it only further muddies already murky waters. Rockhill involved review of an arbitration proceeding that property-owner, Heirloom I, LLC (“Heirloom”) filed against CFI-Global Fisheries Management (“CFI”). Rockhill Insurance Company (“Rockhill Insurance”) was asked to defend the arbitration as CFI’s professional and general liability insurer. At issue in the arbitration was Heirloom’s claim that CFI defectively designed and constructed a fisheries enhancement that was destroyed by natural processes four times in three years. Read the court decision
Read the full story...
Reprinted courtesy of Todd Likman, Higgins, Hopkins, McLain & Roswell
Mr. Likman may be contacted at likman@hhmrlaw.com

Hunton Insurance Partner Syed Ahmad Named to Benchmark Litigation’s 2019 40 & Under Hot List

October 14, 2019 — Michael S. Levine & David M. Costello - Hunton Insurance Recovery Blog
Benchmark Litigation has named Syed Ahmad, a partner in Hunton Andrews Kurth’s Insurance Coverage practice, to the publication’s 40 & Under Hot List. Benchmark Litigation is the definitive guide to America’s leading litigation firms and attorneys. The 40 & Under Hot List honors the most notable up-and-coming litigation attorneys in the United States. Those named to the list have proven their eligibility as individuals at the partner level of their respective firms who are 40 years of age or younger. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and David Costello, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

BWB&O’s Los Angeles Office Obtains Major Victory in Arbitration!

July 25, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara Partner Patrick Au and Senior Associate Theresa Mallen recently achieved a major victory in binding Arbitration. The subject action involved a construction project in the backyard of homeowner’s residence. Homeowner maintained that BWB&O’s contractor client abandoned the project. Furthermore, homeowner alleged that the work performed by BWB&O’s client was deficient. The primary construction defect claim is that the pool deck is not properly sloped which is preventing surface water from running off the top of the retaining wall as designed. The Arbitrator ultimately sided with BWB&O’s client finding that BWB&O’s client did not abandon the project, but rather was terminated by homeowner. Additionally, BWB&O successfully proved that despite the fact that the three pertinent elevations that determine the slope of the concrete pool slab were pre-established before BWB&O’s client even got on the project, that BWB&O’s client properly installed the concrete pool slab and would have established the necessary slope of the pool deck had it not been terminated from the project. Homeowner asserted many other secondary construction defect claims and the Arbitrator found in BWB&O’s client’s favor on each and every issue. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Collapse of Breezeway Attached to Building Covered

February 24, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court found that a breezeway that collapsed during a party was covered by the commercial property policy. DENC, LLC v. Philadelphia Indem. Ins. Co., 2019 U.S. Dist. LEXIS 179083 (M.D. N.C. Oct. 15, 2019). DENC owned an apartment complex that was insured by Philadelphia under an all-risk policy. During an early morning party, a large number of students gathered on the second-floor breezeway for a party. The students started jumping in the breezeway when a certain song started playing. The floor abruptly collapsed underneath the students. Philadelphia sent an adjuster to inspect the breezeway a couple days later. He wrote to Philadelphia that "the sole and proximate cause of the loss is water damage occurring over an extended period of time causing the second floor breezeway to sage and the light weight concrete to crack." Shortly thereafter, the building was condemned. A structural engineer found multiple ways in which water had seeped into the breezeway's wood framing and photographed the resulting biological growth and wood decay. He concluded that the building had sustained significant long-term water intrusion which resulted in the wood framing inability to support the loads. The water intrusion was caused by the failure to properly install a water management system on the walls, a properly integrated waterproof system for the walkway slab and framing configuration, and improper venting of dryers. DENC retained an engineer who testified that the breezeway was sagging because the concrete had broken. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insurer's Bad Faith is Actionable Tort for Purposes of Choice of Law Analysis

January 08, 2024 — Janeen M. Thomas - Saxe Doernberger & Vita, P.C.
When an insurer handles a claim in violation of its duty to act in good faith, policyholders are often eager to sue the insurer for bad faith, seeking extra contractual damages. Before filing suit, however, it is critical that policyholders consider what state’s law applies to the bad faith claim. In the recent case of Scott Fetzer Co. v. Am. Home Assurance Co., Inc.1, the Ohio Supreme Court held that Restatement (Second), Conflict of Laws, § 145 (“Section 145"), governed the choice of law dispute, which meant that the insured would be able to obtain discovery of Travelers’ claims-handling procedures, guidelines, internal documents, and communications relating to the claim.2 The insured, Scott Fetzer, argued that the materials were discoverable because documents evidencing an insurer’s bad faith are not protected by attorney-client privilege in Ohio. In response, Travelers argued that the laws of either Indiana (the place where the parties entered into the insurance contract), or Michigan (the location of the insured risk) governed the discovery dispute because Restatement (Second) § 193 (“Section 193”) governs the choice of law analysis for claims that “arise out of insurance contracts.”3 The laws of either Indiana or Michigan were more favorable for Travelers because Indiana does not allow discovery of materials covered by attorney-client privilege, and Michigan does not even recognize a cause of action for bad faith. Read the court decision
Read the full story...
Reprinted courtesy of Janeen M. Thomas, Saxe Doernberger & Vita, P.C.
Mr. Thomas may be contacted at JThomas@sdvlaw.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES