Seattle Washington Building Expert Directory

CGL Coverage for Liquidated Damages and the Contractual Liability Exclusion

October 09, 2023 — Stu Richeson - The Dispute Resolver
Liquidated delay damages are common in construction contracts and are generally imposed when a contractor fails to achieve substantial completion within the time required by the contract. While contracts like the AIA A201-2017 have provisions for extending the time to achieve substantial completion when delays are caused by circumstances beyond the contractor’s control, delays can result from factors other than improper management or planning and the like, for which the owner is not required to give the contractor additional time. Courts are split on whether there is ever coverage under a CGL policy for contractually agreed upon liquidated delay damages. Liquidated delay damages are often excluded under the contractual liability exclusion of most CGL policies. The contractual liability exclusion excludes coverage for “liability for which the Insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement.” Courts often find the contractual liability exclusion in a CGL policy precludes coverage for liquidated delay damages, because such damages are contractual in nature and are triggered by the failure to bring the contract to substantial completion by a fixed deadline, regardless of the cause of the delay. However, some courts will look to the cause of the delay and find that there is coverage under a CGL policy for liquidated delay damages that are the result of property damage caused by an accident or occurrence. In Clark Const. Grp., Inc. v. Eagle Amalgamated Serv., Inc., 01-2478-DV, 2005 WL 2092998, at *1 (W.D. Tenn. Aug. 24, 2005) a general contractor entered a contract for the renovation of the convention center in Memphis. Part of the project included the demolition of a structure attached to the convention center. The demolition work was improperly performed by a subcontractor and resulted in damage to the convention center. Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

Now Available: Seyfarth’s 50 State Lien Law Notice Requirements Guide (2023-2024 Edition)

December 23, 2023 — Seyfarth Shaw LLP
Seyfarth’s Construction team is pleased to announce the release of our 2023-2024 edition of the 50 State Lien Law Notice Requirements Guide. The Guide provides the general time requirements for filing lien notices in each state, plus Washington, DC. Reprinted courtesy of Seyfarth Shaw LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Connecticut Supreme Court Rules Matching of Materials Decided by Appraisers

March 28, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The Connecticut Supreme Court determined that an appraisal panel could resolve whether the insurer must replace undamaged materials so that they match the damaged materials. Klass v. Liberty Mut. Ins. Co., 2022 Conn. LEXIS 2 (Conn. Jan. 11, 2022). The insured reported damage to the roof of his home to Liberty Mutual. A representative from Liberty Mutual inspected and noticed a few shingles missing from the rear slope of the roof. The representative agreed that the damage was caused by wind damage, a covered loss under the policy. Liberty Mutual accepted coverage and issued an estimate to replace the rear slope of the roof. The insured's contractor inspected the roof and provided an estimate that contemplated replacement of the entire roof at nearly double the cost of Liberty Mutual's estimate. The insured requested an appraisal. Liberty Mutual responded that the insured could not invoke the appraisal process in the absence of a "competing" estimate (i.e., one that addressed the claim for which coverage was accepted). Any dispute regarding the matching of the front and rear roof slope was a question of coverage, not an issue for appraisal. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Eleventh Circuit Rules That Insurer Must Defend Contractor Despite “Your Work” Exclusion, Where Damage Timing Unclear

May 13, 2019 — Michael S. Levine & David M. Costello - Hunton Andrews Kurth
The Eleventh Circuit has reversed an insurer’s award of summary judgment after finding that uncertainty about when the alleged property damage occurred raised questions about whether the damage came within the scope of the “Your Work” exclusion. More specifically, the court found unclear whether the damage occurred before or after the contractor abandoned the job, thereby triggering an exception to the “Your Work” exclusion for damage to work that had “not yet been completed or abandoned.” The decision illustrates how timing can be a critical factor when it comes to triggering coverage for work and completed operations. In Southern-Owners Insurance Company v. MAC Contractors of Florida, LLC, a pair of trustees hired MAC Contractors (doing business as KJIMS Construction) to serve as the general contractor for a custom residence. After construction began, disputes between the trustees and KJIMS caused the contractor to abandon the job before completing the project. The trustees followed with a lawsuit alleging, among other things, that KJIMS had damaged wood floors and a metal roof, which KJIMS had promised to remediate but never did. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and David Costello, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Costello may be contacted at dcostello@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

California Fears El Nino's Dark Side Will Bring More Trouble

September 17, 2015 — Brian K. Sullivan – Bloomberg
A group of drought experts gathered in California this week, and it wasn’t long before the conversation turned to El Nino. They weren’t touting it as the savior that will end the state’s four-year drought. Instead, they were looking at a darker scenario where the weather-changing phenomenon adds another year of dryness in the north while ravaging the south with floods. “What do you say when the governor asks you what to do? ‘You prepare for flood and drought because there is a possibility you can get both,”’ said Mike Anderson, state climatologist. Read the court decision
Read the full story...
Reprinted courtesy of Brian K. Sullivan, Bloomberg

War-Torn Ukraine Looks to Europe’s Green Plans for Reconstruction Ideas

July 18, 2022 — Laura Millan Lombrana - Bloomberg
Ukrainian officials and architects are already thinking about how to rebuild cities torn by the Russian invasion in a way that is also respectful to the environment and helps fight climate change. Mariupol city hall officials have started to assess the damage caused by Russian shelling as a first step to rebuild the city once the war is over, Deputy Mayor Sergei Orlov told an audience in Brussels at the New European Bauhaus festival, running through Saturday in several European cities. A coalition of Ukrainian and international experts in urban planning, heritage, energy and the circular economy are working toward the same goal. “We will reconstruct Ukraine, we have to do that and we will do that,” European Commission President Ursula von der Leyen said at the festival. “It’s not only in our interest, it’s our moral obligation to do that — but when we are reconstructing Ukraine, let’s do it the right way, let’s do it in the spirit of the New European Bauhaus.” Read the court decision
Read the full story...
Reprinted courtesy of Laura Millan Lombrana, Bloomberg

Plehat Brings Natural Environments into Design Tools

May 01, 2019 — Aarni Heiskanen - AEC Business
Natural elements are an essential part of the built environment. However, BIM tools offer almost no support to landscape architecture. Plehat is introducing a new solution that helps architects and decision-makers to understand the dynamics of nature and make smart design choices. Plehat used photogrammetric 3D models of Uunisaari islands, to the south of Helsinki. The experimenters modeled the buildings and the plants on the island and used game engine software to create a virtual reality (VR) experience. They called the app the “Landscape Time Machine”. The technology solution they developed paved the way for new software that the company will launch later this year. In 2018, Plehat, a landscape design startup, received funding from the Finnish national KIRA-digi digitalization project to carry out a test. The experimentation demonstrated how seasonal changes and weather conditions affect plants, and how the environment can be visualized and analyzed virtually. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Jason Poore Receives 2018 Joseph H. Foster Young Lawyer Award

July 21, 2018 — Jason Poore - White and Williams LLP
Jason Poore, an associate in the General Litigation Group, recently received the 2018 Joseph H. Foster Young Lawyer Award during the Philadelphia Association of Defense Counsel’s annual meeting. The Joseph H. Foster Young Lawyer Award honors “a young lawyer who best exemplifies the qualities of professionalism and dedication as defense counsel in the practice of law and in the promotion of the highest ideals of justice in the community." Jason continues to make significant contributions to the local bar and community. In addition to serving on the Executive Committee of the Philadelphia Bar Association Young Lawyers Division, he is the creator and Chair of the PBA's Youth Courts Committee. Read the court decision
Read the full story...
Reprinted courtesy of Jason Poore, White and Williams LLP
Mr. Poore may be contacted at poorej@whiteandwilliams.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES