Seattle Washington Building Expert Directory

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

Hundreds Celebrated the Grand Opening of the Associated Builders and Contractors of Southern California Riverside Construction Training Center

February 14, 2023 — Associated Builders and Contractors
RIVERSIDE, Calif., Feb. 10, 2023 (GLOBE NEWSWIRE) -- Today the Associated Builders and Contractors Southern California Chapter (ABC), hosted hundreds of community members as they cut the "ribbon" of their third training center in Southern California. "Today is a celebration, but it also represents a continued commitment by ABC and our membership to supply a skilled, trained, and safe construction workforce for Southern California," stated Nick McFayden, ABC SoCal's Board Chair. Jon Krystafik, Vice Chairman of the Training Trust commented, "Our training facility is unique. You may have toured other facilities but with ours you will see we don't just train one craft. Here Apprentices and Craft trainees are receiving cutting edge training in Electrical, Plumbing, Low Voltage and HVAC/Sheet Metal." Krystafik added, "Our trustees had a dream 10 years ago to train residents in the inland empire. Today it is a reality!" ABC Southern California Chapter is an association of contractors that believe in the Merit Shop Philosophy. Merit shop encourages open competition and a free enterprise approach that awards contracts and employment based solely on merit, safety, quality, and cost, regardless of labor affiliation. The chapter is one of 68 throughout the country and represents nearly 400 member companies. Read the court decision
Read the full story...
Reprinted courtesy of

New York’s Highest Court Weighs in on N.Y. Labor Law

September 23, 2024 — Bill Wilson - Construction Law Zone
N.Y. Labor Law § 241(6) requires owners and contractors to provide reasonable and adequate protection and safety to persons employed at or lawfully frequenting a construction site. If a worker is injured on a construction site and establishes a violation of a specific and applicable Industrial Code regulation, both the owner and contractor will be held vicariously liable for the worker’s injury, without regard to their fault and even in the absence of control or supervision of the worksite. The Court of Appeals of New York recently addressed the broad scope of the Labor Law in the context of slipping hazards. In Bazdaric v. Almah Partners, LLC, 41 N.Y.3d 310 (2024), the plaintiff, an injured painter, slipped and fell on a plastic covering placed over an escalator in an area he was assigned to paint. The plaintiff claimed that the plastic covering was a foreign substance for purposes of Industrial Code 12 NYCRR 23-1.7(d) because it was not part of the escalator. Industrial Code 12 NYCRR 23-1.7(d) states:

Slipping hazards. Employers shall not suffer or permit any employee to use a floor, passageway, walkway, scaffold, platform or other elevated working surface which is in a slippery condition. Ice, snow, water, grease and any other foreign substance which may cause slippery footing shall be removed, sanded or covered to provide safe footing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Morrison Bridge Allegedly Crumbling

February 05, 2015 — Beverley BevenFlorez-CDJ STAFF
The Portland Mercury reported that the Portland, Oregon Morrison Bridge’s structure is breaking into pieces. "The bridge is crumbling," Joel Mullin, attorney from Stoel Rives representing the county told a Multnomah County judge, according to the Portland Mercury. "The deterioration has accelerated more than anticipated." Newly released documents seem to imply that the bridge “project was doomed well before it started, and county officials should have known it,” the Portland Mercury reported. Read the court decision
Read the full story...
Reprinted courtesy of

Event-Cancellation Insurance Issues During a Pandemic

September 07, 2020 — Lorelie S. Masters & Latosha M. Ellis - Hunton Andrews Kurth
As the effects of coronavirus continue, organizations and companies now are considering whether events in late 2020 and early 2021 can take place or need to be converted to virtual events. What insurance effects will those changes and cancellations have? Consideration of these important decisions requires a review of both event-cancellation insurance and a consideration of force majeure and other such issues. On the insurance front, years ago, many policyholders purchased event-cancellation insurance for events in 2020, 2021, and even as far out as 2024. Such policies, purchased before the middle of March 2020, generally contain explicit coverage “buy-backs” for losses from “communicable disease.” That is, the policyholders paid an extra, specifically identified premium to remove any exclusion for communicable disease from these policies. Typically, these policies do not use the word, “virus”, but rather use “communicable disease”; and exclude neither. Those policies typically cover a specified amount of net profit and include additional coverages for “Cost of Remedial Action”, “Future Marketing Expense”, etc., over and above that specified amount of coverage. Reprinted courtesy of Lorelie S. Masters, Hunton Andrews Kurth and Latosha M. Ellis, Hunton Andrews Kurth Ms. Masters may be contacted at lmasters@HuntonAK.com Ms. Ellis may be contacted at lellis@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Not So Unambiguous: California Court of Appeal Finds Coverage for Additional Insured

October 11, 2017 — Malcom Ranger-Murdock - Saxe Doernberger & Vita, P.C.
California’s Fourth District Court of Appeal recently determined that manuscript additional insured endorsements (AIEs), which purportedly provided coverage for ongoing operations only, were ambiguous. The court also found the insurer that issued the policies, American Safety Indemnity Co. (American Safety), acted in bad faith due to its systematic efforts to deny coverage to general contractors as additional insureds. In Pulte Home Corp. v. American Safety Indemnity Co.,1 Pulte Home Corporation (Pulte Home), a general contractor, sued American Safety for failure to defend Pulte Home as an additional insured in connection with two underlying construction defect lawsuits. American Safety contended that it did not have a duty to defend Pulte Home because the loss occurred after the construction project was complete and the applicable AIEs did not provide coverage for completed operations, and/or because the policy’s faulty workmanship exclusions applied. The trial court awarded $1.4 million in compensatory and punitive damages to Pulte Home, and American Safety appealed. Read the court decision
Read the full story...
Reprinted courtesy of Malcom Ranger-Murdock, Saxe Doernberger & Vita, P.C.
Mr. Ranger-Murdock may be contacted at mrm@sdvlaw.com

Does a Broker Forfeit His or Her Commission for Technical Non-Compliance with Department of Real Estate Statutory Requirements?

September 14, 2020 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In a recent Arizona Court of Appeals case, CK Revocable Trust v. My Home Group Real Estate LLC, 2020 WL 4306183 (7/28/2020), the Court of Appeals addressed the distinction between “substantive” and “technical” statutory requirements for real estate broker commission agreements. The Court explained that failure to comply with a substantive requirement would preclude the broker from recovering a commission, but failure to comply with a technical requirement would not. As examples of such substantive requirements, the Court identified the statutory requirement that the broker be licensed at the time the claim for commission arose, and the statutory requirement that the listing agreement be signed by both the broker and the client. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

How is Negotiating a Construction Contract Like Buying a Car?

January 04, 2018 — Christopher G. Hill - Construction Law Musings
Originally Published by CDJ on March 1, 2017 I know, you’re probably looking for a punchline, and likely thinking something along the lines of “only a construction attorney would be sitting in his office and come up with such an analogy,” but I really do think it’s a good one. When you are buying a car, you look for priorities. Is the color what you want? Is the motor a hybrid or a v-6? Does it have Android Auto? What is the fuel mileage? All of these things may be more or less important to you. If you can get your priorities for a price that is attractive, you will likely let some other less important items, e. g. trunk space or rear seat leg room, slide and purchase the car anyway. Furthermore, you may use these minor items as negotiating points to either get one of the priorities or a lower price. Of course the dealership will want to get its priorities, likely a sale and a profit, when negotiating and will have certain items that it won’t move on just as you have terms that you won’t move on. Much like when you walk onto the car lot, and particularly as a subcontractor looking at a contract from a general contractor, or a GC looking at the contract from the owner of a project, a construction contract presented to you is the starting point. When looking at the contract, be sure to have some non-negotiable items in mind when taking a critical eye to the terms of that contract. Some of these terms may be more or less negotiable depending on your experience with the other party to the construction contract. For instance, striking a pay if paid clause may be less important with a paying party with whom you have a 10 year history without payment problems. On the other hand, if it is your first contract with the other party, a stricter list may be required. So, much like a dealer that you know will stand behind its cars, you may be more willing to take more “risk” in entering a construction contract with a trusted/known owner or GC. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES