Cambridge Massachusetts Building Expert Directory

Georgia Passes Solar CUVA Bill

April 20, 2017 — David R. Cook Jr. - Autry, Hanrahan, Hall & Cook, LLP
Georgia House Bill 238 authorizes the withdrawal of property from a conservation use covenant for purposes of developing a solar generation plant. Before the law was passed, subject to certain limited exceptions, properties under a conservation use covenant generally could not be developed without breaching the covenant. The new law permits the removal of a portion of the property to be used for solar development without breaching the covenant for the rest of the property. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Building Stagnant in Las Cruces Region

November 20, 2013 — CDJ STAFF
There was an increase in the number of building permits issued in Las Cruces, New Mexico through the first ten months of 2013, but the 2,162 permits represent only a minimal increase over last year’s 2,158 permits. To make matters worse for building suppliers and workers, builders can “pull all the permits for a subdivision at one time but might not start some of those for six months,” said Lee Rawson, the owner of Rawson Builders Supply. For a comparison, during the building boom of 2006, Las Cruces issued 3,529 building permits. The values are down too. Although fewer permits were issued in 2012, their valuation was $147 million, while the marginally larger number in 2013 is worth only $128 million. As a result, the area is losing skilled labor. After 25 consecutive months of declining construction, workers are leaving the construction industry. Mr. Rawson noted that “you can’t just go find that skilled labor, it doesn’t exist.” Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Changes to Va. Code Section 43-13: Another Arrow in a Subcontractor’s Quiver

November 02, 2020 — Christopher G. Hill - Construction Law Musings
As is always the case here in Virginia, our General Assembly has made some legislative changes that affect construction contracting. One of these changes is an amendment to Va. Code 43-13 found in the mechanic’s lien section of the Virginia Code. This section of the code has always required that any money paid to a contractor must first go toward paying its subcontractors, suppliers and laborers prior to being used for any other purpose. Prior to 2020, the only remedy for violaiton of Va. Code 43-13 was to go to the local Commonwealth’s Attorney and request a prosecution of the wrongdoer. For various reasons, including that such action did not get the subcontractor or supplier that remained unpaid under this section paid, this remedy was not often pursued except in the most egrigious cases. A key change in the statute occurred during the 2020 legislative session states as follows:

Any breach or violation of this section may give rise to a civil cause of action for a party in contract with the general contractor or subcontractor, as appropriate; however, this right does not affect a contractor’s or subcontractor’s right to withhold payment for failure to properly perform labor or furnish materials on the project. Any contract or subcontract provision that allows a contracting party to withhold funds due under one contract or subcontract for alleged claims or damages due on another contract or subcontract is void as against public policy.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

One World Trade Center Tallest Building in US

November 13, 2013 — CDJ STAFF
It’s official! The tallest building in the United States is in New York. For forty years, the tallest building in the United States has been the Willis Tower in Chicago (better known by its former name, the Sears Tower). Now, the Council on Tall Buildings and Urban Habitat has decreed that One World Trade Center edges it out with its 1,776 feet of height, surpassing the Willis by 325 feet. There is a caveat. The antennas on the top of the Willis building aren’t counted in. The mast on the top of One World Trade Center is, and it adds 441 feet to the height of the building. If the mast weren’t counted, One World Trade Center would be 116 feet shorter than the building in Chicago. Read the court decision
Read the full story...
Reprinted courtesy of

Stay-At-Home Orders and Work Restrictions with 50 State Matrix

April 27, 2020 — Smith Currie
As each day of the coronavirus pandemic passes, more and more states, cities and counties across the country are implementing stay-at-home (or shelter-in-place) orders and restrictions on individuals and businesses. These restrictions are impacting numerous persons and businesses, including those working in the construction industry. Smith Currie is keeping abreast of these restrictions and has developed the matrix below identifying statewide and local restrictions in place. This matrix is by no means complete, and we will continue updating it as we become aware of additional orders. In the write ups included with the PDF below, you will find links to the applicable orders with more detailed information. Consult legal counsel for advice on the impact of a particular restriction or restrictions to your business. Read the court decision
Read the full story...
Reprinted courtesy of Smith Currie
The firm Smith Currie may be contacted at info@smithcurrie.com

Guessing as to your Construction Damages is Not the Best Approach

November 18, 2019 — David Adelstein - Florida Construction Legal Updates
Arbitrarily guessing as to your construction damages is NOT the best approach. Sure, experts can be costly. No doubt about it. Having an expert versus guessing as to your construction damages caused by another party’s breach of contract is a no brainer. Engage an expert or, at a minimum, be in a position to competently testify as to your damages caused by another party’s breach of contract. Otherwise, the guessing is not going to get you very far as a concrete subcontractor found out in Patrick Concrete Constructors, Inc. v. Layne Christensen Co., 2018 WL 6528485 (W.D. New York 2018) where the subcontractor could not competently support its delay-related damages or change orders and, equally important, could not support that the damages were proximately caused by the general contractor’s breach of the subcontract. In this case, the concrete subcontractor entered into a subcontract to perform concrete work for a public project. The project was delayed and the general contractor was required to pay liquidated damages to the owner. Not surprisingly, the subcontractor disputed liability for delays and sued the general contractor for all of its delay-related damages “in the form of labor and materials escalation, loss of productivity, procurement and impact costs, field and home office overhead, idle equipment, inability to take on other work, lost profits, and interest.” Patrick Concrete Constructors, 2018 WL at *1. The general contractor moved for summary judgment as to the plaintiff’s delay-related damages – the subcontractor’s damages were nothing but guesses and the subcontractor could not prove the general contractor was the cause of the subcontractor’s damages. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Liability policy covers negligent construction: GA high court

October 31, 2010 — Michael Bradford in Business Insurance

ATLANTA—Negligent construction that results in damage to surrounding property constitutes an occurrence under a commercial general liability policy, the Georgia Supreme Court has ruled.

In a 6-1 opinion Monday in American Empire Surplus Lines Insurance Co. Inc. vs. Hathaway Development Co. Inc., the Georgia high court upheld a lower court ruling that the general contractor’s claim for damage caused by a subcontractor’s faulty plumbing work was covered.

The ruling on construction defects is the latest in number of such cases across the United States

Read Full Story...

Reprinted courtesy of Michael Bradford of Business Insurance.

Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES