Seattle Washington Building Expert Directory

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Building Materials Price Increase Clause for Contractors and Subcontractors – Three Options

June 21, 2021 — William L. Porter - Porter Law Group
With the arrival of inflation come concerns regarding increases in the price of building materials within the construction industry. Contractors, subcontractors and others who contract to perform construction work can suffer significant losses when the prices they must pay for materials rises significantly between the time they sign the contract and actually purchase the materials. The general rule is that, unless there exists a contract clause allowing contractors or subcontractors to pass significant price increases for materials on to others, contractors and subcontractors are stuck with the price stated in the contract or subcontract. When prices rise, the contractor or subcontractor eats the difference. Rising prices can thus turn a profitable project into a catastrophic failure. How are contractors and subcontractors to protect themselves? Once a contract is executed, there is usually little that can be done to change the document to address rising prices. Effort must therefore turn to future protection. The best technique for dealing with increasing future prices for building materials is by adding a price escalation clause to contracts and subcontracts. While this will not help for past contracts or subcontracts, it can certainly offer significant protection going forward. Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

Contractual Warranty Agreements May Preclude Future Tort Recovery

January 11, 2022 — Taylor Ostrowski - Colorado Construction Litigation Blog
When a buyer purchases a product that is later discovered to be defective, the court offers a remedy to make the buyer whole. Such remedies can arise either out of a contract, including express and/or implied warranties, or under common law through a tort theory. However, what happens when a buyer has already received the remedy specified in the contractual warranty, only to discover the product manufacturer misrepresented the quality of its product by failing to disclose a defect? Can the buyer subsequently recover for the same product under a tort theory of recovery? The Colorado Court of Appeals analyzed such questions in its December 2021 decision in Dream Finders Homes, LLC v. Weyerhaeuser NR Co., 2021 COA 143. In Dream Finders, the court examines the rights of sophisticated buyers who purchased defective products and received a warranty from the product manufacturer with purchase. The court specifically determines whether such buyers may recover under the tort theory product misrepresentation and failure to disclose when the buyers have already received the remedy specified and the warranty expressly excludes the type of damage the buyer now seeks. Read the court decision
Read the full story...
Reprinted courtesy of Taylor Ostrowski, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Ostrowski may be contacted at ostrowski@hhmrlaw.com

Treble Damages Awarded After Insurer Denies Coverage for Collapse

July 03, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The Fourth Circuit upheld the district court's decision that a collapse was covered, but reversed the denial of treble damages to the insured. DENC, LLC v. Phila. Indem. Ins. Co., 2022 U.S. App. LEXIS 10443 (4th Cir. April 18, 2022). The district court decision was summarized here. DENC owned The Crest, an apartment building leased to Elon University for student housing. Philadelphia Indemnity Company insured the property. In January 2018, students gathered on a second-floor breezeway for a party. Partygoers began jumping in the breezeway, which caused an abrupt collapse. Observers noticed that the breezeway was hanging down by more that a foot. DENC filed a claim with Philadelphia the next day. An adjuster was sent to inspect the breezeway. By that time, the city had condemned The Crest. The adjuster said that undiscovered "water damage which occurred over an extended period of time" caused the loss. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

BHA has a Nice Swing Benefits the Wounded Warrior Project

May 20, 2015 — Beverley BevenFlorez-CDJ STAFF
Bert L. Howe & Associates (BHA) would like to congratulate the winners of the BHA Has a Nice Swing golf game for charity at the 2015 West Coast Casualty Construction Defect Seminar. With the help of the participants, BHA was able to raise $1925 to benefit the Wounded Warrior Project. BHA would also like to congratulate the raffle winners. Prizes included a DJI Phantom 2 Vision+ Drone and Dodger baseball tickets. The Wounded Warrior Project’s purpose is to raise awareness and enlist the public’s aid for the needs of injured service members; to help injured service members aid and assist each other; and to provide unique, direct programs and services to meet the needs of injured service members. Learn more about the Wounded Warrior Project... Read the court decision
Read the full story...
Reprinted courtesy of

Power Point Presentation on Nautilus v. Lexington Case

July 23, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Here is our power point from today's presentation to the Hawaii State Bar Association's Litigation and Insurance Coverage Litigation sections. We discussed "other insurance" clauses as addressed by the Hawaii Supreme Court in Nautilus Ins. Co. v. Lexington Ins. Co., 132 Haw. 283, 321 P.3d 634 (2014). Read the full story and view the Power Point presentation... Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

BWB&O’s Los Angeles Office Obtains Major Victory in Arbitration!

July 25, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara Partner Patrick Au and Senior Associate Theresa Mallen recently achieved a major victory in binding Arbitration. The subject action involved a construction project in the backyard of homeowner’s residence. Homeowner maintained that BWB&O’s contractor client abandoned the project. Furthermore, homeowner alleged that the work performed by BWB&O’s client was deficient. The primary construction defect claim is that the pool deck is not properly sloped which is preventing surface water from running off the top of the retaining wall as designed. The Arbitrator ultimately sided with BWB&O’s client finding that BWB&O’s client did not abandon the project, but rather was terminated by homeowner. Additionally, BWB&O successfully proved that despite the fact that the three pertinent elevations that determine the slope of the concrete pool slab were pre-established before BWB&O’s client even got on the project, that BWB&O’s client properly installed the concrete pool slab and would have established the necessary slope of the pool deck had it not been terminated from the project. Homeowner asserted many other secondary construction defect claims and the Arbitrator found in BWB&O’s client’s favor on each and every issue. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Overview of New Mexico Construction Law

June 25, 2019 — Walter F. Crowson - Snell & Wilmer Under Construction Blog
We’ve seen an uptick in out-of-state companies working on construction projects in New Mexico. The following is an overview of some of the nuances of New Mexico construction law about which companies may want to be aware. Construction Contract Issues Limitation of Liability Clauses are usually Enforceable, but Anti-Indemnity Clauses Are Not New Mexico courts have enforced limitation of liability clauses included in construction contracts. See Fort Knox Self Storage, Inc. v. W. Techs., Inc., 140 N.M. 233, 237 (N.M. Ct. App 2006). New Mexico law recognizes the difference between contracts that insulate a party from any and all liability and those that simply limit liability. Fort Knox Self Storage, Inc., 140 N.M. 233 at 237. An exculpatory clause immunizes a party from liability, whereas a limitation of liability clause merely curtails liability. Id. A limitation of liability clause has been held not to violate New Mexico public policy because the party “still bears substantial responsibility for its actions.” Id.; see also Cowan v. D'Angelico, 2010 WL 11493789, *6 (D. N.M. Apr. 26, 2010). Read the court decision
Read the full story...
Reprinted courtesy of Walker F. Crowson, Snell & Wilmer
Mr. Crowson may be contacted at wcrowson@swlaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES