Seattle Washington Building Expert Directory

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Trump Abandons Plan for Council on Infrastructure

August 17, 2017 — Mark Niquette - Bloomberg
President Donald Trump will not move forward with a planned Advisory Council on Infrastructure, a person familiar with the matter said Thursday. The infrastructure council, which was still being formed, would have advised Trump on his plan to spend as much as $1 trillion upgrading roads, bridges and other public works. Its cancellation follows Trump’s announcement Wednesday that he was disbanding two other business advisory panels. Read the court decision
Read the full story...
Reprinted courtesy of Mark Niquette, Bloomberg

Buy Clean California Act Takes Effect on July 1, 2022

July 25, 2022 — Garret Murai - California Construction Law Blog
The Buy Clean California Act (BCCA) – Public Contract Code section 3500 et seq. – requires state agencies to consider the carbon content of the following products when awarding contracts:

Structural steel;
Concrete reinforcing steel;
Flat glass; and
Mineral wool board insulation.

It is anticipated that additional products may be added through future legislation. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Are You Ready For 2015?

January 07, 2015 — Craig Martin- Construction Contractor Advisor Blog
Last month’s Engineering News Record Magazine contained an editorial noting the worst projects of the year. Are you prepared if you have a bad project? As the editors aptly pointed out: "By their nature, bad projects disappoint owners, incite hostility among team members, slip months and years past scheduled completions and drain finances." ENR pointed noted a few projects from 2014 that did not go well. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Construction Litigation Roundup: “This Is Sufficient for Your Purposes …”

April 08, 2024 — Daniel Lund III - Lexology
… but just barely. Federal courts are “notice” pleading courts. One source writes: “Notice pleading refers to pleading standards that merely notify the opposing party and court of the general issues in the case. In contrast to fact pleading standards, notice pleading standards do not require pleadings to include hyper-detailed facts in support of each claim.” Some state courts – including Louisiana – are fact pleading courts. Ordinarily, no one practicing in Louisiana state courts would describe the fact pleading requirements for initiating a lawsuit as mandating “hyper-detailing” of the facts, but … why risk it? In a construction mechanics lien case – the jurisprudence for which requires that courts strictly construe the related law because liens empower lien holders with rights which are “in derogation” of common property ownership rights – the defendant was successful in having the trial court dismiss a lien suit for failing to affirmatively set forth in the complaint (a “petition” in Louisiana) the date of substantial completion. The lien claimant appealed. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Construction Problem Halts Wind Power Park

November 13, 2013 — CDJ STAFF
Engineers have yet to determine why a blade on a wind turbine broke at a wind power plant in Michigan, but as part of their investigation they are halting work on the final 10 turbines. The already completed 60 turbines have been taken out of operation. As a result, the Echo Wind Park is no longer generating power. Scott Simons, a spokesperson for the project, said “we’re not going to put anyone or anything at risk until we get to the bottom of this.” However, Dennis Buda, the project manager, attributed the broken blade to a manufacturing defect. Construction was planned to end in November. Read the court decision
Read the full story...
Reprinted courtesy of

University of California Earthquake Report Provides List of Old Concrete Buildings in LA

January 22, 2014 — Beverley BevenFlorez-CDJ STAFF
According to a list provided to the city of Los Angeles by the University of California, there are “about 1,500 old concrete buildings that are potentially at risk of collapse during an earthquake,” the Los Angeles Times reported. The list can help the city identify “concrete buildings most likely to fail in an earthquake.” The report, however, “does not amount to a list of dangerous buildings,” the university scientists told the Los Angeles Times. It is a list of concrete buildings built before 1980. Some of the “buildings are vulnerable, others are not.” Concrete buildings pose a potentially dangerous threat, reported the Los Angeles Times: “After the Northridge earthquake caused two concrete buildings to collapse and severely damaged others, structural engineers warned that the collapse of a single concrete building ‘has the potential for more loss of life than any other catastrophe in California’ since the 1906 San Francisco earthquake.” Eric Garcetti, Los Angeles Mayor, has asked Lucy Jones, a U.S. Geological Survey seismologist, to act as his science advisor on earthquake issues. Garcetti has asked Jones “to come up with recommendations by the end of the year on retrofitting issues, including how to get privately owned concrete buildings retrofitted.” Read the court decision
Read the full story...
Reprinted courtesy of

Anthony Garasi, Jared Christensen and August Hotchkin are Recognized as Nevada Legal Elite

July 06, 2020 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce Partners Anthony Garasi and Jared Christensen in our Las Vegas office, along with Associate August Hotchkin in our Reno office are being recognized as Nevada Legal Elites in the Nevada Business Magazine. The Nevada Legal Elite list includes the top 4 percent of attorneys in the state broken down by location. To qualify, each nominee goes through an extensive verification process resulting in the top attorneys in the state, chosen by their peers. Upon the nomination process closing, each ballot is individually reviewed for eligibility and every voting attorney is verified with the State Bar of Nevada. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES