FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Less Than Perfectly Drafted Endorsement Bars Flood Coverage

January 21, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The court decided that the policy's flood exclusion, despite being poorly located within the policy, barred coverage for loss caused by flood. Great Lakes Int'l Trading Inc. v. Travelers Prop. Cas. Co., 2014 U.S. Dist. LEXIS 165378 (D. Conn. Nov. 26, 2014). Hurricane Sandy caused flood waters from the Hackensack River in New Jersey to inundate a warehouse where the insured had imported food products stored for sale in the United States. High winds also sheared open parts of the warehouse's roof, allowing extensive rainwater to enter the building. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

The Looming Housing Crisis and Limited Government Relief—An Examination of the CDC Eviction Moratorium Two Months In

December 14, 2020 — Zachary Kessler - Gravel2Gavel
Months after the Centers for Disease Control and Prevention (CDC) issued a nationwide eviction moratorium using its emergency pandemic powers under the Public Health Service Act, the efficacy of this unprecedented measure remains unclear. While the Order ostensibly protects tenants facing homelessness or housing insecurity due to the financial impacts of the COVID-19 pandemic through the end of 2020, legal challenges have been initiated in Ohio and Georgia, with additional lawsuits appearing likely. Further, even barring legal challenges, courts have not handled these cases in a uniform manner. With lawmakers unable to reach any stimulus or COVID-19 relief agreement before the election, the CDC Order appears likely to remain the only federal eviction moratorium through its expiration on December 31, 2020. Since the Order’s enactment, the CDC has since released new guidance, answering some of the open questions not covered by the initial Order. This guidance, while non-binding, is largely more favorable to landlords and property management companies than the initial text of the Order, as it provides that landlords are not required to make tenants aware of the Order’s protections and may challenge the truthfulness of the tenants’ declarations in any state or municipal court. The guidance also clarified the potential criminal penalties for violating the Order and the criminal penalties for perjury for bad faith submissions of the requisite declaration by tenants. Read the court decision
Read the full story...
Reprinted courtesy of Zachary Kessler, Pillsbury
Mr. Kessler may be contacted at zachary.kessler@pillsburylaw.com

---

New York Appellate Division Reverses Denial of Landlord’s Additional Insured Tender

December 07, 2020 — Eric D. Suben - Traub Lieberman
In Wesco Insurance Co. v. Travelers Property & Cas. Co. of America, 2020 WL 6572489 (1st Dep’t Nov. 10, 2020), the New York Appellate Division found that a commercial landlord was owed additional insured coverage in connection with an incident in which a plaintiff slipped and fell on the sidewalk while exiting the leased premises. The tenant, Capital One, was the named insured in a CGL policy issued by Travelers. The policy added the landlord as an additional insured, but “only with respect to liability arising out of the ownership, maintenance or use of that part of the premises leased to [Capital One] and shown in the Schedule.” The lease defined the demised premises to include the building and “all appurtenances.” Travelers denied the landlord’s tender on the basis that the sidewalk did not constitute “that part of the premises leased to” Capital One. In the ensuing declaratory judgment action brought by Wesco (the landlord’s insurer), the court granted Travelers’ motion for summary judgment on this ground. Read the court decision
Read the full story...
Reprinted courtesy of Eric D. Suben, Traub Lieberman
Mr. Suben may be contacted at esuben@tlsslaw.com

---

New York: The "Loss Transfer" Opportunity to Recover Otherwise Non-Recoverable First-Party Benefits

May 13, 2014 — Robert M. Caplan – White and Williams LLP
New York’s “no-fault” legislation reflects a public policy designed to make the insurer of first-party benefits absorb the economic impact of loss without resort to reimbursement from its insured or, by subrogation, from the tortfeasor. Country Wide Ins. Co. v. Osathanugrah, 94 A.D.2d 513, 515 (N.Y. 1st Dept. 1983). The no-fault concept embodied in New York’s Insurance Law modifies the common law system of reparation for personal injuries under tort law. Safeco Ins. Co. of Am. v. Jamaica Water Supply Co., 83 A.D.2d 427, 431 (N.Y. 2nd Dept. 1981). “[F]irst party benefits are a form of compensation unknown at common law, resting on predicates independent of the fault or negligence of the injured party.” Id. at 431. The purpose of New York’s no-fault scheme is “to promote prompt resolution of injury claims, limit cost to consumers and alleviate unnecessary burdens on the courts.” Byrne v. Oester Trucking, Inc., 386 F. Supp. 2d 386, 391 (S.D.N.Y. 2005). New York’s no-fault scheme—contained in Article 51 of its Consolidated Laws (“Comprehensive Motor Vehicle Insurance Reparations”)—requires owners of vehicles to carry insurance with $50,000 minimum limits which covers basic economic loss, i.e., first-party benefits, on account of personal injury arising from the use or operation of a motor vehicle. Basic economic loss includes, among other things: (1) medical expenses; (2) lost earnings up to $2,000 per month for three years; and (3) out-of-pocket expenses up to $25 per day for one year. N.Y. INS. LAW § 5102(a). Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Caplan, White and Williams LLP
Mr. Caplan may be contacted at caplanr@whiteandwilliams.com

---

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

---

Red Tape Is Holding Up a Greener Future

March 13, 2023 — The Editors - Bloomberg
Seven months on, Democrats are still celebrating the Inflation Reduction Act, even though a crucial determinant of its success — permitting reform for energy projects — remains undone. Recent data shows just how imperative it is for them to stop dragging their feet. What’s now called the IRA had little to do with inflation. It was a climate bill, and a big one: It provided $370 billion to improve energy efficiency, reduce emissions and smooth the path to a clean-power economy. It came on top of a 70% surge in private investment since 2017. But the biggest impediment to the US energy transition isn’t financing: It’s building. A decade ago, between 25% and 30% of proposed wind and solar projects moved from the drawing boards to completion. But as new projects and new funding have soared, utilities have been unable to keep up, leading to an immense backlog. A recent report by BloombergNEF found that over just six years, global clean-energy investment has gone from half the level of fossil-fuel investment to near parity, an extraordinary leap that reflects the market’s appetite for clean power. Yet America’s dysfunctional regulation is preventing many needed projects from even breaking ground. Read the court decision
Read the full story...
Reprinted courtesy of The Editors, Bloomberg

---

The Unthinkable Has Happened. How Should Contractors Respond?

May 11, 2020 — Bruce Orr - AEC Business
Any construction veteran expects the economy to contract and expand. However, the global pandemic presents contractors with a challenge unlike any in recent memory. How should they respond in an environment of such uncertainty? For some perspective, I chatted with Dr. John Killingsworth, a construction management professor at Colorado State University who has conducted extensive research on how contractors can weather economic downturns. BRUCE ORR: John, let’s say you’re in IT or are a c-suite executive at a contracting firm. This event has occurred. What are some of the questions you should be asking right now? JOHN KILLINGSWORTH: For starters, we have to acknowledge that the uncertainties are so tremendous that many contractors have no choice but to be reactive in the short term. They’re literally not sure whether particular job sites will be open or closed tomorrow or whether they’ll go to work next week. They’re also looking at predictions—from highly qualified statisticians, public health officials and others—that are just all over the map due to the limited nature of the data we have at hand. Read the court decision
Read the full story...
Reprinted courtesy of Bruce Orr, AEC Business
Mr. Orr may be contacted at bruce@pronovos.com

---

Court Retained Jurisdiction to Enforce Settlement Under Code of Civil Procedure Section 664.6 Despite Dismissal of Complaint

October 21, 2024 — Garret Murai - California Construction Law Blog
Attorneys will commonly add a Code of Civil Procedure section 664.6 provision in their settlement agreements to ensure that courts have continuing jurisdiction to enforce the terms of a settlement, as opposed to having to file a new complaint in the event of a breach of a settlement agreement. Oral settlements before a trial court are also enforceable under Section 664.6, but as discussed in Eagle Fire and Water Restoration, Inc. v. City of Danuba, Case No. F086052 (May 30, 2024), in cases involving a complaint and multiple cross-complaints, questions can arise as to whether a trial court has in fact retained jurisdiction under Section 664.6 to enforce an oral settlement and even what the terms of the settlement were. The Eagle Fire Case Eagle Fire and Water Restoration, Inc. was hired by the City of Dinuba to reroof the City’s police station and courthouse building. The contract was for approximately $500,000. Before completion of the project, a rainstorm caused significant water damage to the interior of the building. The City incurred over $330,000 in clean-up and repair costs and withheld approximately $319,000 from Eagle as an offset. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---