Fairfield Connecticut Building Expert Directory

No Damage for Delay? No Problem: Exceptions to the Enforceability of No Damage for Delay Clauses

October 18, 2021 — Chris Broughton, Jones Walker LLP - ConsensusDocs
Introduction: Under a no-damage-for-delay clause, the owner is not liable for any monetary damages resulting from delays on the project. In lieu of monetary recovery, the contractor’s remaining remedy is a non-compensatory time extension. These clauses are common at the contractor-subcontractor interface as well. While no-damage-for-delay clauses are enforced in most jurisdictions, some states, either by statute or case law, have limited the enforceability of no-damage-for-delay clauses. Other states have also limited the enforceability of these clauses on state government contracts, and a select few have outlawed them on all projects regardless if they are publicly or privately owned. Additionally, for subcontractors on federal projects, the Miller Act may provide a way to avoid no-damage-for-delay and recover against the general contractor’s payment bond. This article provides an overview of no-damage-for-delay clauses and the exceptions to enforcement of these clauses. However, due to the consequences of a no-damage-for-delay clause, it is important to know the terms of your contract and the law that governs your project. Read the court decision
Read the full story...
Reprinted courtesy of Chris Broughton, Jones Walker LLP
Mr. Broughton may be contacted at cbroughton@joneswalker.com

Inspired by Filipino Design, an Apartment Building Looks Homeward

May 22, 2023 — Sarah Holder - Bloomberg
Austerity and efficiency aren’t the first words that come to mind when you see the angled sawtooth bays of Tahanan Supportive Housing, or catch a glimpse of a rainbow through its lobby. But the dramatic exterior and joyful interior of this San Francisco building are both products of their constraints. When David Baker Architects was approached to design the six-story development, the goal was aggressive: Produce 145 units of permanent supportive housing at under $400,000 a unit, and have the operation up and running in less than three years. The firm accepted the challenge, and by 2022, Tanahan was fully leased to residents, all of whom are San Franciscans who have struggled with chronic homelessness. In a city where affordable units typically cost $600,000 to $700,000 each to construct, keeping in budget and meeting the deadline meant turning to the modular building company Factory OS. It also meant keeping variation at a minimum. The studios are identical, like Lego blocks; instead of being mirrored across a hallway, they’re just rotated 180 degrees. But nothing else about the building feels utilitarian. Read the court decision
Read the full story...
Reprinted courtesy of Sarah Holder, Bloomberg

American Council of Engineering Companies of California Selects New Director

January 22, 2014 — Beverley BevenFlorez-CDJ STAFF
Brad Diede has been selected as the new executive director of the American Council of Engineering Companies of California, according to GlobeSt.com. “ACEC California is dedicated to strengthening the engineering and surveying professions, protecting the general public and promoting the use of the private sector in building a better California.” Paul Meyer is retiring after 32 years as the executive director. Diede brings over ten years’ experience as executive director of the California Professional Association of Specialty Contractors. He will begin work at ACEC California January 27th. Read the court decision
Read the full story...
Reprinted courtesy of

Hold on Just One Second: Texas Clarifies Starting Point for Negligence Statute of Limitations

July 11, 2022 — Lian Skaf - The Subrogation Strategist
In construction or similar ongoing projects, problems often pop up. Sometimes they can pop up again and again. Making things even more complicated, one problem may affect another, seemingly new problem. When these construction problems result in property damage, timelines tend to overlap and determining when a statute of limitation begins to run for a particular claim can be difficult. Especially in states with short statute of limitations for tort claims like Texas, knowing when a statute begins to run is crucial for a subrogation professional. In Hussion St. Bldgs., LLC v. TRW Eng’rs, Inc., No. 14-20-00641-CV, 2022 Tex. App. LEXIS 2193, 2022 WL 1010313, the Court of Appeals of Texas provided clarity on when the two-year statute of limitations for tort claims begins to run. Reversing the judgment from the lower court, the appellate court denied summary judgment to the defendant, holding that, despite there being existing issues with the ongoing construction project, the negligence cause of action for Hussion Street Buildings, LLC (Hussion) did not begin to run more than two years prior to filing suit. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

Avoiding Lender Liability for Credit-Related Actions in California

October 27, 2016 — Anthony J. Carucci – Snell & Wilmer Real Estate Litigation Blog
Aside from general statutory prohibitions on lender discrimination, there are certain circumstances under California law in which lenders may be held liable for credit-related actions, such as negotiating or denying credit. See generally 11 Cal. Real Est. § 35:3 (explaining that the business of lending money is subject to the Unruh Civil Rights Act, Cal. Civ. Code § 51 et seq., the Fair Employment and Housing Act, Cal. Gov. Code § 12900 et seq., the Federal Fair Housing Act, 42 U.S.C. § 3601 et seq., and the Equal Credit Opportunity Act, 15 U.S.C. § 1691, et seq.). Specifically, lenders have been held liable for credit-related actions where, among other things, the lender (1) breached a loan commitment; (2) committed fraud; or (3) breached a fiduciary duty owed to the borrower. The Lender-Borrower Relationship As a general rule, a lender does not owe a duty of care to a borrower when the lender’s involvement in a transaction does not exceed the scope of its conventional role as a lender of money. Oaks Management Corp. v. Superior Court (2006) 145 Cal.App.4th 453, 466 (“[I]t is established that absent special circumstances . . . a loan transaction is at arms-length and there is no fiduciary relationship between the borrower and lender.”); Nymark v. Heart Fed. Savings & Loan Assn. (1991) 231 Cal.App.3d 1089, 1096 (holding lender owed no duty of care to a borrower in preparing an appraisal of the real property that was security for the loan when the purpose of the appraisal is to protect the lender by satisfying it that the collateral provided adequate security for the loan, and noting that “as a general rule, a financial institution owes no duty of care to a borrower when the institution’s involvement in the loan transaction does not exceed the scope of its conventional role as a mere lender of money”). Read the court decision
Read the full story...
Reprinted courtesy of Anthony J. Carucci, Snell & Wilmer
Mr. Carucci may be contacted at acarucci@swlaw.com

De-escalating The Impact of Price Escalation

August 10, 2021 — Brian C. Padove - ConsensusDocs
What happens when construction material prices abruptly rise by 15%, 35%, 50%? Moreover, what happens to a construction project when such volatility occurs? While there is no definite answer, delays in procuring such materials and associated cost overruns will likely impact the construction project. The last 15 months contractors have had to work through extraordinary construction material price increases, such as a 90% price increase for lumber from April 2020 to April 2021. While there is no statistic quantifying the impact these increases have had on the construction industry, the increases surely have had an influence, whether it has been through lost profits, delays, or damage to contractors’ otherwise strong reputation for timely performance. Considerations Prior To Contract Execution The first way to mitigate price escalation is identifying materials most susceptible to price volatility during the bidding process and then having an open discussion with upstream parties regarding the potential price volatility. Additionally, the bid may also include either (1) an allowance for the materials providing additional funds, if necessary, should the material price increase, or (2) a shortened timeframe in which the bid is open, which would lessen the time in which a price shift may occur. Read the court decision
Read the full story...
Reprinted courtesy of Brian C. Padove, Watt, Tieder, Hoffar & Fitzgerald, LLP
Mr. Padove may be contacted at bpadove@watttieder.com

Woman Files Suit for Property Damages

January 15, 2014 — Melissa Zaya-CDJ STAFF
Debra Lovejoy filed suit on December 5th 2013 in Virginias Kanawha Circuit Court claiming that her home sustained damaged after a highway was built near her property, according to The West Virginia Record. The West Virginia Water Company, Carpenter Reclamation Inc., and the West Virginia Department of Transportation-Division of Highways were named in the suit. “Lovejoy claims Carpenter disturbed the contours of the surface, thereby weakening the support for the bank extending along the highway,” reports Kyla Asbury of The West Virginia Record. Asbury continues: “As a result, the bank has slipped significantly over time, according to the suit.” Lovejoy claims the bank needs to be repaired in order to prevent it from further slips, and is pursuing compensation. Read the court decision
Read the full story...
Reprinted courtesy of

Florida’s “Groundbreaking” Property Insurance Reform Law

April 18, 2023 — Bradley S. Fischer & Laura Farrant - Lewis Brisbois
Fort Lauderdale, Fla. (April 18, 2023) – On December 16, 2022, Florida Governor Ron DeSantis signed into law Senate Bill 2-A (S.B. 2-A, or the Act). Widely touted as “groundbreaking,” S.B. 2-A reforms many aspects of the claims process, including the timing for paying and adjusting claims, eliminating one-way attorneys’ fee awards, and banning assignment-of-benefits agreements. This alert provides an overview of the key provisions of S.B. 2-A. Unless otherwise stated in each amended statute, December 16, 2022 appears to be the effective date of the Act. I. Assignment of Benefits – Section 627.7152 (effective January 1, 2023)

A policyholder may not assign any post-loss insurance benefits under any residential or commercial property insurance policy. Any attempt to assign such benefits is void, invalid, and unenforceable.

Reprinted courtesy of Bradley S. Fischer, Lewis Brisbois and Laura Farrant, Lewis Brisbois Mr. Fischer may be contacted at Bradley.Fischer@lewisbrisbois.com Ms. Farrant may be contacted at Laura.Farrant@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES