Fairfield Connecticut Building Expert Directory

Condominium Exclusion Bars Coverage for Construction Defect

August 17, 2011 — Tred R. Eyerly - Insurance Law Hawaii

Coverage was denied under the policy’s condominium exclusion in California Traditions, Inc. v. Claremont Liability Ins. Co.,2011 Cal. App.LEXIS912 (Cal. Ct. App., ordered published July 11, 2011).

California Traditions was the developer and general contractor for a housing development. California Traditions subcontracted with Ja-Con to perform the rough framing work for 30 residential units. The project had 146 separate residences that were freestanding with no shared walls, roof, halls, or plumbing or electrical lines. To allow a higher density development, the project was developed, marketed and sold as condominiums.

The purchaser of one of the units filed a complaint against California Traditions alleging property damage from the defective construction. California Traditions cross-complained against Ja-Con.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

A Quick Checklist for Subcontractors

January 26, 2017 — Christopher G. Hill – Construction Law Musings
After the last two weeks’ analyses of a couple of big construction decisions that came out recently, I thought I’d keep this week’s post practical and short for those that are not construction lawyers. So without further ado, here is a short checklist of the top things (aside from calling their local experienced construction attorney) a construction subcontractor should do or look for when reviewing a construction contract from a general contractor (and for a couple of these that a general contractor can look for in its prime contract).

ALWAYS get a copy of the Prime Contract between the Owner and the General Contractor. This contract will contain terms that will “flow down” to you through the incorporation clause that almost every subcontract contains. You can’t do much to change these terms, but you will need to know them as the job progresses.
READ every provision of the subcontract. I know this sounds simple, but not all subcontracts hide the red flags in the same places. Remember the details of a subcontract can sink you later if you aren’t prepared.

Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Millennials Skip the Ring and Mortgage

June 26, 2014 — Megan McArdle – Bloomberg
They’re living at home in growing numbers. They're not buying homes, which creates ripple effects throughout the housing market. They’re having more babies out of wedlock than in it. Why can’t millennials get it together? The first and most obvious answer is “jobs.” If you can’t find a stable job, it’s hard to move out of Mom’s basement. It’s hard to commit to a mortgage or a spouse. It's hard, in other words, to launch into the middle-class life that constitutes the American Dream. Millennials are some of the biggest victims of the financial crisis. Those without a college degree face high rates of unemployment, while those who have a sheepskin are more and more likely to be underemployed in a job that doesn’t require their degree. Even if the student loan crisis has been overstated, the rising cost of college tuition certainly doesn’t help. Read the court decision
Read the full story...
Reprinted courtesy of Megan McArdle, Bloomberg
Ms. McArdle may be contacted at mmcardle3@bloomberg.net

Lake Charles Tower’s Window Damage Perplexes Engineers

October 05, 2020 — Autumn Cafiero Giusti - Engineering News-Record
When Hurricane Laura came onshore Aug. 27 as a Category 4 hurricane with sustained winds of 150 mph, it shattered windows on nearly every level of the 22-story Capital One Tower in the Lake Charles, La., business district. The glass damage is perplexing to engineers who study wind dynamics and window performance. Reprinted courtesy of Autumn Cafiero Giusti, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Forecast Sunny for Solar Contractors in California

June 06, 2018 — Amy Pierce - Gravel2Gavel Construction & Real Estate Law Blog
On May 9, the California Energy Commission announced that it has “adopted building standards that require solar photovoltaic systems starting in 2020.” The 2019 Building Energy Efficiency Standards are expected to “reduce greenhouse gas emissions by an amount equivalent to taking 115,000 fossil fuel cars off the road.” California will be the first in the nation to require solar. The new standards take effect on January 1, 2020. Read the court decision
Read the full story...
Reprinted courtesy of Amy L. Pierce, Pillsbury Winthrop Shaw Pittman LLP
Ms. Pierce may be contacted at amy.pierce@pillsburylaw.com

Contractors Admit Involvement in Kickbacks

December 09, 2011 — CDJ STAFF

Two New Jersey contractors have pleaded guilty to charges that they made false representations for a government contract in a case related to kickbacks for construction work done in two school districts. New Jersey is recommending that the two men, Martin Starr and Stephen Gallagher, will each pay $50,000 in penalties, serve up to a year in jail, and be unable to accept public contracts for five years.

Last month, another individual in the case, Kenneth Disko, who had been the engineer for the school district, pleaded guilty on a similar charge. In addition to a $50,000 penalty, he will be serving three to five years in prison. A fourth conspirator, Robert Berman, the former business administrator for one of the school districts, has to pay a $13,000 fine and cooperate with the investigation. He is also barred from public employment in New Jersey and has been terminated from his position.

Starr admitted to preparing fictitious quotes which appeared to be from other contractors in order that his firm would seem to be the lowest bidder. Gallagher helped in preparing the fictitious bids and also provided cash kickbacks to Disko.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Breach of a Construction Contract & An Equitable Remedy?

September 22, 2016 — David Adelstein – Florida Construction Legal Updates
In payment or collection-type lawsuits, the party suing for money sometimes asserts a claim for unjust enrichment or quantum meruit as an alternative equitable remedy to a breach of contract claim. Frankly, sometimes a party will do this as a means to throw everything against the wall hoping something, just something, sticks. However, if there is a contract by and between the parties, equitable claims such as unjust enrichment or quantum meruit will invariably fail. They will fail because a party cannot circumvent a contract simply because their recourse may prove better under an equitable theory. It doesn’t work like that! And, it should not! Read the court decision
Read the full story...
Reprinted courtesy of David M. Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES