Five Issues to Consider in Government Contracting (Or Any Contracting!)
September 02, 2024 —
David Adelstein - Florida Construction Legal UpdatesThe appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting.
Issue #1- Patently Ambiguous Specifications
The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Growing Optimism Among Home Builders
June 28, 2013 —
CDJ STAFFFor the first time since 2006, the number of home builders who are optimistic about home sales exceed those who are pessimistic, with 52 percent optimistic. Just last month, the builder confidence index was at 44. This eight-point jump was the largest change in more than a decade.
Their confidence has increased as economists and others have been seeing signs of an improved economy. There has been an increase in demand for new homes and even though sales are below what economists would like, homebuilders are finding buyers.
Read the court decisionRead the full story...Reprinted courtesy of
Hong Kong Property Tycoon Makes $533 Million Bet on Solar
April 02, 2014 —
Ehren Goossens and Benjamin Haas - Bloomberg NewsA Hong Kong real-estate tycoon has spent the past year accumulating stakes in failing solar companies, piecing together what may become the biggest collection of photovoltaic factories in the world.
Zheng Jianming, also known in Cantonese as Cheng Kin Ming, has spent or pledged about $533 million to buy assets that at their peak were worth almost $20 billion, according to regulatory filings in the U.S. and Hong Kong, where he has a home and office.
The transactions, if completed, would transform Zheng, a newcomer to the solar industry, into one of its most powerful leaders. Another Zheng solar investment in 2012, a 30 percent stake in Shunfeng Photovoltaic International Ltd. (1165), has surged more than 2,900 percent and is now worth more than $745 million.
Mr. Goossens may be contacted at egoossens1@bloomberg.net; Mr. Haas may be contacted at bhaas7@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
Ehren Goossens and Benjamin Haas, Bloomberg News
Meet the Forum's In-House Counsel: ERIN CANNON-WELLS
June 26, 2023 —
Jessica Knox - The Dispute ResolverCompany: Keller North America, Inc.
Email: ecannon@keller-na.com
Website: https://www.keller-na.com/
Under Grad: University of Delaware (Bachelor of Civil Engineering 2000)
Grad School: The University of Texas (Master of Civil Engineering 2002)
Law School: Howard University (JD 2008)
States Where Company Operates/Does Business: Throughout the US and Canada
Q: Describe your background and the path you took to becoming in-house counsel.
A: I studied civil engineering in undergrad and finally found my "calling" when I took a construction course, prompting me to pursue a master's in construction engineering. I started my career at Turner, holding various engineering positions, the last of which introduced me to the "contracting" side of construction. I was inspired to go to law school (in hopes of becoming an in-house lawyer there). After law school, I joined BigLaw, but maintained my desire to practice construction law. I then jumped to a small construction practice group at a mid-size firm, and the mentoring and experience there was everything I could hope for (but for the looming business development and billable hour requirements). From there, I became the sole in-house counsel for a large cement manufacturer and was a true construction generalist. Now I am part of a great legal team for a leading geotechnical specialty contractor. My moves were strategic, and I'm pleased to say that this is the very career I went to law school to have.
Read the court decisionRead the full story...Reprinted courtesy of
Jessica Knox, Stinson LLPMs. Knox may be contacted at
jessica.knox@stinson.com
Smart Construction and the Future of the Construction Industry
October 11, 2021 —
Caroline A. Harcourt, James W. McPhillips & Adam J. Weaver - Gravel2Gavel Construction & Real Estate Law Blog“Smart Construction” is a loose term but generally refers to the development and use of processes and applications that improve construction planning and the management of projects (thereby potentially streamlining costs of construction).
The increased deployment of collaboration tools (e.g., Zoom, Microsoft Teams, WebEx) and other cloud-based technology solutions during the COVID-19 pandemic will invariably result in more efficient project management in construction going forward. These type of efficiencies are sorely needed, especially as the industry is trying to recover from supply chain issues, lockdown challenges and social distancing requirements resulting from the pandemic.
However, smart construction goes well beyond those basic business efficiency and collaboration tools. For example, drones are regularly used on construction projects to monitor site conditions, detect problems, and assess conditions safely. Meanwhile, newer technologies such as “programmable” cement, “self-healing” concrete, and autonomous and robotic machinery are increasingly being deployed in construction projects. And yet, these current technology solutions are just the tip of the iceberg as researchers continue to look for new ways machines and technology can be used to solve complex engineering challenges.
Reprinted courtesy of
Caroline A. Harcourt, Pillsbury,
James W. McPhillips, Pillsbury and
Adam J. Weaver, Pillsbury
Ms. Harcourt may be contacted at caroline.harcourt@pillsburylaw.com
Mr. McPhillips may be contacted at james.mcphillips@pillsburylaw.com
Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Pulte Home Corp. v. CBR Electric, Inc.
August 24, 2020 —
Michael Velladao - Lewis BrisboisIn Pulte Home Corp. v. CBR Electric, Inc., 50 Cal.App.5th 216 (June 10, 2020), the California Court of Appeal reversed the trial court’s entry of judgment in favor of six subcontractors with respect to an equitable subrogation lawsuit filed by St. Paul Mercury Insurance Company (“St. Paul”). St. Paul filed the lawsuit after defending Pulte Home Corp. (“Pulte”) against two construction defect lawsuits. The lawsuit contended that St. Paul was entitled to seek recovery of defense costs incurred on behalf of Pulte based on equitable subrogation. St. Paul relied on the indemnity clauses in each of the subcontracts, and argued that the subcontractors had breached their contracts with Pulte. As such, each subcontractor was obligated to pay an equitable share of the defense of the construction defect lawsuits relating to their work on the homes at issue in such lawsuits. The trial court ruled against St. Paul and held that the subcontractors’ failure to pay defense costs did not “cause” the homeowners’ claims, such that there was no causal connection supporting a claim for equitable subrogation. In addition, the trial court found that “equitable subrogation was an all-or-nothing claim, meaning it required a shifting of the entire amount of defense costs to the subcontractors on a joint and several basis and did not allow for an apportionment of costs among the defendant subcontractors.”
In reversing the trial court’s decision, the Court of Appeal reasoned that St. Paul stood in the shoes of Pulte and was limited to pursuing recovery from the subcontractors based on the same rights as afforded to Pulte under the subcontracts. The Court of Appeal noted that St. Paul was seeking reimbursement of defense costs from the subcontractors based on the theory that they were contractually liable for paying an equitable share of defense costs. The Court of Appeal also noted that St. Paul’s claim was not premised on the contention that the subcontractors’ failure to pay defense costs caused the homeowners’ claims. Rather, St. Paul’s claim was premised on the subcontractors’ breach of their defense duty owed to Pulte under the indemnity clauses in their subcontracts.
Read the court decisionRead the full story...Reprinted courtesy of
Michael Velladao, Lewis BrisboisMr. Velladao may be contacted at
Michael.Velladao@lewisbrisbois.com
Florida Representative Wants to Change Statute of Repose
December 10, 2015 —
Beverley BevenFlorez-CDJ STAFFCurrently in Florida, the ten year clock for construction defect claims typically starts ticking after the final payment is made by the owner. However, WFSU reported, Representative Keith Perry wants to change it so that the completion of the construction triggers the statute of repose.
This change “could favor the construction industry, by shifting the power to start the clock from home owners to builders,” WFSU claimed. Representative Dwight Dudley worries about “what would happen if a contractor felt she was finished but the property owner didn’t agree.”
Read the court decisionRead the full story...Reprinted courtesy of
Three Recent Cases Strike Down Liquidated Damages Clauses In Settlement Agreements…A Trend Or An Aberration?
November 01, 2021 —
Adam M. Tuckman - ConsensusDocsBeginning more than one century ago, owners and contractors generally have adopted the convention of including liquidated damages in their contracts to fix potential liability for delay (and other losses) at the inception of the project. The proliferation of liquidated damages clauses in modern contracts can be attributed to economic and legal factors. From the owner’s standpoint, it may be exceedingly difficult to prove the actual cost impact of a delayed completion of the project. A properly calculated liquidated damages rate would save the owner the significant expense of quantifying its delay damages. On the contractor’s side, a reasonable amount of liquidated damages may be preferable to uncapped or unknown liability, allowing the contractor to more accurately price its bid and efficiently allocate risk.
Coinciding with, or perhaps a leading cause of, the industry’s embrace of liquidated damages provisions, was the shift in courts throughout the country from disfavoring such clauses to accepting them (within limits) as an appropriate exercise of contract rights. While some variation exists among the states, courts have generally recognized that liquidated damages clauses are a viable alternative to proof of actual loss so long as (i) actual losses were difficult to quantify, and (ii) the stipulated sum bears a reasonable relationship to the anticipated loss at the time of contracting. See, e.g., Restatement (Second) of Contracts § 356. Conversely, a clause that penalizes the breaching party rather than serving as an estimate of probable loss is likely to be found unenforceable.
Read the court decisionRead the full story...Reprinted courtesy of
Adam M. Tuckman, Watt, Tieder, Hoffar, & Fitzgerald, LLPMr. Tuckman may be contacted at
atuckman@watttieder.com
