Cambridge Massachusetts Building Expert Directory

Specification Challenge; Excusable Delay; Type I Differing Site Condition; Superior Knowledge

January 02, 2024 — David Adelstein - Florida Construction Legal Updates
An Armed Services Board of Contract Appeals dispute, Appeal of L.S. Black-Loeffel Civil Constructors JV, ASBCA No. 62402, 2023 WL 5827241 (ASBCA 2023), involved which party bore liability for delay—the federal government or the prime contractor–based on various legal theories. Without detailing the factual details, a number of interesting legal issues were raised in this dispute including (1) a defective specification challenge, (2) excusable delay, (3) Type I differing site condition, and (4) superior knowledge. These legal issues are discussed below. 1. Specification Challenge (Defective Specifications) The contractor claimed that the government’s specifications were defective in regard to a thermal control plan. The government countered that the specifications were not design specifications but performance specifications. The specifications were performance based because they did not tell the contractor how to achieve the performance-based criteria. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

2023 West Coast Casualty Construction Defect Seminar

March 27, 2023 — Beverley BevenFlorez – CDJ Staff
The 29th annual West Coast Casualty Construction Defect Seminar will return to the Disneyland Hotel in May. The event covers topics of interest to those in the construction defect field including prosecution, defense, insurance coverage, and science and technology. The seminar will also have networking opportunities. Attendees every year include professionals “from the legal, insurance, builder, contractor, subcontractor and numerous other communities.” May 18th-19th, 2023 Disneyland Hotel 1150 Magic Way Anaheim, CA 92802 Read the court decision
Read the full story...
Reprinted courtesy of

Can a Non-Union Company Be Compelled to Arbitrate?

August 02, 2017 — Wally Zimolong - Supplemental Conditions
Some of the most viewed topics on this blog are those concerning double breasted company. That is a two separate firms, commonly owned, one that is a signatory to a union and the other that is merit shop. An issue frequently encountered with double breasted construction companies is an union arbitrator’s jurisdiction over the non-signatory firm. The issue usually goes something like this. A signatory employer’s collective bargaining agreement contains language prohibiting double breasting (which could be invalid). The collective bargaining agreement also contains an arbitration provision requiring all disputes concerning a breach of the agreement (a grievance) be decided by an arbitrator in private arbitration. The union files a demand for arbitration claiming that the union signatory has breached the collective bargaining agreement’s anti-dual shop provision. The union names the non-union firm as a party to the arbitration based on its status as an alleged “single employer.” Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

PSA: Virginia Repeals Its Permanent COVID-19 Safety Standard

May 10, 2022 — Christopher G. Hill - Construction Law Musings
In January of 2021, Virginia was one of the first states to adopt a permanent workplace safety standard setting out employer requirements for COVID safety. Later that same year, the Virginia Department of Labor and Industry updated the standard to make it less confusing and more easily complied with. Now, as of March 21, 2022, DOLI has repealed that permanent standard in response to the changes in COVID guidance and other new information. Instead of a permanent standard, DOLI provides “Guidance for Employers to Mitigate the Risk of COVID-19 to Employees.” This guidance, along with the advice of counsel, should help you in moving forward during the next phase of the COVID pandemic. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Higgins, Hopkins, McLain & Roswell, LLC Announces Leadership Changes and New Vision for Growth

January 21, 2025 — David McLain - Higgins, Hopkins, McLain & Roswell, LLC
Higgins, Hopkins, McLain & Roswell, LLC (“HHMR”) is excited to announce several significant developments as the firm transitions into an exciting new chapter of growth and innovation. Sheri Roswell, one of the firm’s founding members, is stepping out of ownership to serve as “Of Counsel,” continuing her vital work with clients and strengthening relationships that have been the cornerstone of HHMR’s success. Her tireless contributions since the firm’s inception have helped establish HHMR as a leader in Colorado’s construction law landscape. “Sheri has been a pillar of HHMR since day one. Her commitment to our clients and her unwavering dedication to the firm’s success have left an indelible mark. We are excited for her to continue contributing her expertise and leadership in this new capacity,” said David McLain at the firm’s recent holiday celebration. Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

Navigate the New Health and Safety Norm With Construction Technology

August 03, 2020 — Jeremy Larsen - Construction Executive
Safety has always been a pressing issue in construction, and as states reopen and construction projects pick up steam once again, the industry will become even more closely scrutinized than before. Construction safety looks a lot different than it did six months ago. In addition to the concerns around keeping workers safe on construction sites, today’s contractors are faced with a whole new category of risk, and with new health and safety measures that may vary by county, state or region. New requirements range from social distancing and limits on the size of crews, to requiring masks and temperature checks for all workers. OPERATING IN THE NEW NORM This sudden onset of COVID-19 put otherwise healthy businesses into a state of chaos that, months later, is still hard to navigate. By March of 2020, reports indicated that nearly one-third of construction projects had come to a halt. Now, as the industry emerges, balancing business continuity efforts with trying to get crews back to work and jobsites moving again will no doubt present challenges. New health and safety measures, plus the fact that no one wants to touch paper in the field, will add another layer of administrative and procedural oversight to the construction process. Of course, these measures are absolutely needed, but construction businesses can’t ignore the fact that it changes the very way projects and jobsites are managed. And, without the right tools in place, it may be a bumpy ride. Reprinted courtesy of Jeremy Larsen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Larsen may be contacted at jeremy.larsen@viewpoint.com

Court Finds That $400 Million Paid Into Abatement Fund Qualifies as “Damages” Under the Insured’s Policies

November 21, 2022 — Lorelie S. Masters & Yaniel Abreu - Hunton Insurance Recovery Blog
In Sherwin-Williams Co. v. Certain Underwriters at Lloyd’s London, et al., the Court of Appeals for Ohio’s Eighth District reversed the lower court, finding that money paid by the insured into an abatement fund was “damages” as that undefined term was used in the policyholder’s insurance policies. 2022-Ohio-3031, ¶ 1. Sherwin-Williams is a cautionary tale about how insurers may try to narrow the meaning of undefined terms in their insurance policies. The dispute in Sherwin-Williams focused on coverage for $400 million that the policyholder and other defendants were ordered to pay into an abatement fund to be used by California cities and counties to mitigate the hazards caused by lead paint in homes. Id. ¶ 1. Although the underlying litigation proceeded in California, Ohio law governed coverage, which raised issues of first impression in Ohio. Id. Among other things, the insurers argued that the money paid into the abatement fund did not qualify as “damages” under the policies. Id. ¶ 57. The insured argued that, because the insurers did not define “damages” in the policies, the term had to be given its ordinary meaning. Id. ¶ 56. Reprinted courtesy of Lorelie S. Masters, Hunton Andrews Kurth and Yaniel Abreu, Hunton Andrews Kurth Ms. Masters may be contacted at lmasters@HuntonAK.com Mr. Abreu may be contacted at yabreu@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Resilience: Transforming the Energy Sector – Navigating Land Issues in Solar and Storage Projects | Episode 3 (11.14.24)

December 17, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In the latest episode of the Resilience podcast, colleague Shellka Arora-Cox and Laura Pagliarulo, CEO and founder of SolaREIT, get down to the nitty-gritty in a discussion of the interplay of solar power capacity, generation and land use. (Editor’s note: The following transcript has been edited for clarity.) Welcome to Resilience, the vodcast where we talk about the most pressing challenges and the biggest opportunities in the energy sector. I’m your host, Shellka Arora-Cox, a partner at Pillsbury Winthrop Shaw Pittman. I’m thrilled to have Laura Pagliarulo, the CEO and founder of SolaREIT, with me today. Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES