CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

1 De Haro: A Case Study on Successful Cross-Laminated Timber Design and Construction in San Francisco

November 06, 2023 — Cait Horner, Adam J. Weaver & Allan C. Van Vliet - Gravel2Gavel Construction & Real Estate Law Blog
At the intersection of San Francisco’s SOMA, Potrero Hill and Showplace Square districts, a first-of-its-kind building offers an example of the potential widespread success of mass timber construction in the United States. 1 De Haro, a 134,000-square-foot, 4-story office and light industrial project built by Bay Area developer SKS Partners is not only the first cross-laminated timber (CLT) building in the San Francisco, it is also the first multistory mass timber building of its type to be fully executed in California and the first CLT project in the United States to be delivered via railways. We recently sat down with Yvonne Fisher and Lee Ishida of SKS to discuss the unique design process, marketing success and overall industry buzz surrounding one of their latest projects. Reprinted courtesy of Cait Horner, Pillsbury, Adam J. Weaver, Pillsbury and Allan C. Van Vliet, Pillsbury Ms. Horner may be contacted at cait.horner@pillsburylaw.com Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com Mr. Van Vliet may be contacted at allan.vanvliet@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Partner Denis Moriarty and Of Counsel William Baumgaertner Listed in The Best Lawyers in America© 2017

September 08, 2016 — Haight Brown & Bonesteel LLP
Partner Denis Moriarty and Of Counsel William Baumgaertner were selected by their peers for inclusion in The Best Lawyers in America© 2017. This marks the fifth consecutive year Mr. Moriarty has been listed for his work in insurance law, and this marks the eleventh year Mr. Baumgaertner has been listed for his defendants’ and plaintiffs’ work in personal injury and product liability litigation. Read the court decision
Read the full story...
Reprinted courtesy of

---

South Carolina Legislature Redefining Occurrences to Include Construction Defects in CGL Policies

April 01, 2011 — Beverley BevenFlorez CDJ STAFF

The question of what circumstances must be in place for construction defects to be covered in a general commercial liability (CGL) policies is being raised by the courts and the legislature in South Carolina. The Insurance Journal reports that the American Insurance Association as well as the Property and Casualty Insurers Association of America are speaking out on the issue.

The problem seems to be centered on what defines an “occurrence.” CGL policies were not meant to cover faulty workmanship, according to the filing by the South Carolina Supreme Court. In January of this year, the South Carolina Supreme Court reversed the ruling in Crossmann Communities v Harleysville Mutual declaring that “Respondents cannot show the damage here was the result of an occurrence. Rather, the damage was a direct result and the natural and expected consequence of faulty workmanship; faulty workmanship did not cause an occurrence resulting in damage.” They focused their attention on the word “accident,” stating that there is a fortuity element that is not diminished.



The South Carolina legislature reacted by producing a bill that would add new language directly negating the ruling by the Supreme Court. The South Carolina bill S-431 would change the definition of an occurrence in regards to construction defects as follows: “For a liability insurance policy issued to a construction professional, an ‘occurrence’ means, at a minimum: (1) an accident; or (2) continuous or repeated exposure to substantially the same general harmful condition or substance. No additional requirement of a fortuitous event is needed to constitute an ‘occurrence.’”



S-431 is currently residing in the House Committee on Labor, Commerce and Industry.



Read the full story...

Read the court decision
Read the full story...
Reprinted courtesy of

---

A Top U.S. Seller of Carbon Offsets Starts Investigating Its Own Projects

April 19, 2021 — Ben Elgin - Bloomberg
Following concerns that it is facilitating the sale of meaningless carbon credits to corporate clients, the Nature Conservancy says it’s conducting an internal review of its portfolio of carbon-offset projects. The nonprofit owns or has helped develop more than 20 such projects on forested lands mostly in the U.S., which generate credits that are purchased by such companies as JPMorgan Chase & Co., BlackRock Inc., and Walt Disney Co., which use them to claim large reductions in their own publicly reported emissions. The self-examination follows a Bloomberg Green investigation last year that found the world’s largest environmental group taking credit for preserving trees in no danger of destruction. The internal review is a sign that it’s at least questioning some practices that have become widespread in the environmental world, and could carry implications for the broader market for carbon credits. Read the court decision
Read the full story...
Reprinted courtesy of Ben Elgin, Bloomberg

---

Mortgage Firms Face Foreclosure Ban Until 2022 Under CFPB Plan

April 05, 2021 — Alex Wittenberg - Bloomberg
Millions of homeowners who’ve fallen behind on mortgage payments due to the pandemic would have more time before facing foreclosure under rules proposed Monday by the Consumer Financial Protection Bureau. The revamp would generally prohibit mortgage servicers from starting foreclosures until after Dec. 31, the CFPB said in a statement. The goal is to give the nearly 3 million borrowers who’ve delayed or stopped making payments a chance to resume them before lenders initiate forced home sales. A key reason why the CFPB said the change is necessary is because an estimated 1.7 million consumers will exit U.S. forbearance relief programs in September and the ensuing months, meaning they will have to start making payments again. Read the court decision
Read the full story...
Reprinted courtesy of Alex Wittenberg, Bloomberg

---

Competent, Substantial Evidence Carries Day in Bench Trial

February 26, 2024 — David Adelstein - Florida Construction Legal Updates
A number of construction disputes, if tried, are tried through a bench trial meaning the judge is serving in the role of the jury in the construction trial. In a bench trial, two points are important. First, “the factual findings of the judge are entitled to the weight of a jury verdict.” Q.G.S. Development, Inc. v. National Lining Systems, Inc., 2024 WL 357984 (Fla. 3d DCA 2024) (internal quotation and citation omitted). Second, “[t]he appellate court is only authorized to reverse if such findings are not supported by competent, substantial evidence.” Id. These two points need to be appreciated when participating in any construction dispute that will be resolved through a bench trial. A recent construction dispute highlights these two points. In Q.G.S. Development, a contractor was hired to refurbish a golf course which included constructing a lake. The contractor was going to construct the lake, prepare the subgrade, perform dewatering, and it hired a subcontractor to install a reservoir liner at the bottom of the lake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

In Personal Injury Actions, Prejudgment Interest on Costs Not Recoverable

March 12, 2015 — Elizabeth P. Trent and Leah B. Mason – Haight Brown & Bonesteel LLP
In Bean v. Pacific Coast Elevator Corporation, 2015 DJDAR 2864 (“Bean”), the California Court of Appeal, Fourth Appellate District, held in the published portion of its opinion that courts may not award prejudgment interest on costs in personal injury actions. In Bean, an employee of defendant Pacific Coast Elevator Corporation (Pacific Coast) drove his vehicle into plaintiff Daniel William Bean’s truck while Bean was stopped at a red light. Bean suffered serious injuries and sued Pacific Coast. A jury found Pacific Coast negligent and awarded Bean $1,271,594.74 in damages. This amount exceeded Bean’s $999,999.00 statutory offer to compromise issued to Pacific Coast prior to trial, which Pacific Coast rejected. Reprinted courtesy of Elizabeth P. Trent, Haight Brown & Bonesteel LLP and Leah B. Mason, Haight Brown & Bonesteel LLP Ms. Trent may be contacted at etrent@hbblaw.com Ms. Mason may be contacted at lmason@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---