Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion
October 04, 2021 —
David Adelstein - Florida Construction Legal UpdatesSometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS.
Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:
The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Confidence Among U.S. Homebuilders Declines to Eight-Month Low
March 19, 2015 —
Bloomberg News(Bloomberg) -- Confidence among U.S. homebuilders unexpectedly fell in March to an eight-month low as prospective buyers were in little rush to shop for properties ahead of the busier spring selling season.
The National Association of Home Builders/Wells Fargo sentiment gauge dropped to 53 from 55 in February, figures from the Washington-based group showed Monday. The median forecast in a Bloomberg survey called for a gain to 56.
Sales of single-family homes declined to a five-month low and builder optimism about the outlook failed to improve, the report also showed. Low mortgage rates and job creation may help spur homebuyer interest in coming months.
Read the court decisionRead the full story...Reprinted courtesy of
Bloomberg NewsMichelle Jamrisko may be contacted at
mjamrisko@bloomberg.net
Only Two Weeks Until BHA’s Texas MCLE Seminar in San Antonio
April 28, 2014 —
Beverley BevenFlorez-CDJ STAFFThere are just two weeks remaining to sign up for Bert L. Howe & Associate’s inaugural Texas MCLE seminar, “THE RESIDENTIAL CONSTRUCTION PROCESS & CONSTRUCTION DEFECT LITIGATION.” This activity will be presented on Friday, May 9th at noon in BHA’s San Antonio offices, located at 17806 IH 10, Suite 300, San Antonio, TX 78256. There is no cost for attendance at this seminar and lunch will be provided.
This course has been approved for Minimum Continuing Legal Education credit by the State Bar of Texas Committee on MCLE in the amount of 1.0 credit hours, of which 0.0 credit hours will apply to legal ethics/professional responsibility credit. The seminar will be presented by Don MacGregor, general contractor and project manager.
Water intrusion through doors, windows and roofing systems, as well as soil and foundation-related movement, and the resultant damage associated therewith, are the triggering effects for the vast majority of homeowner complaints today and serve as the basis for most residential construction defect litigation. The graphic and animation-supported workshop/lecture activity will focus on the residential construction process from site preparation through occupancy, an examination of associated damages most often encountered when investigating construction defect claims, and the inter-relationships between the developer, general contractor, sub trades and design professionals. Typical plaintiff homeowner/HOA expert allegations will be examined in connection with those building components most frequently associated with construction defect and claims litigation.
The workshop will examine:
* Typical construction materials, and terminology associated with residential construction
* The installation process and sequencing of major construction elements, including interrelationship with other building assemblies
* The parties (subcontractors) typically associated with major construction assemblies and components
* An analysis of exposure/allocation to responsible parties.
Attendance at THE RESIDENTIAL CONSTRUCTION PROCESS & CONSTRUCTION DEFECT LITIGATION seminar will provide the attendee with:
* A greater understanding of the terms and conditions encountered when dealing with common construction defect issues
* A greater understanding of contractual scopes of work encountered when reviewing construction contract documents
* The ability to identify, both quickly and accurately, potentially responsible parties
* An understanding of damages most often associated with construction defects, as well as a greater ability to identify conditions triggering coverage
Course #: 901290467 / Sponsor #: 14152.
To register for the event, please email Don MacGregor at dmac@berthowe.com. If you have any questions, please feel free to contact Don at (210) 540-9017 (office) or (714) 713-4956 (cell).
Read the court decisionRead the full story...Reprinted courtesy of
You’ve Been Suspended – Were You Ready?
April 20, 2020 —
Curtis W. Martin, Patrick J. Greene, Jr. & Levi W. Barrett - Peckar & Abramson“Effective tomorrow … the City is suspending all regular activity at construction sites in Boston.” This was just one of the surprises that greeted contractors last week. Contractors and owners with projects across the country are scrambling to comply with mandated governmental suspensions. Project participants should begin contingency planning for possible project shutdowns.
Reacting to Suspension
Your legal rights and remedies will be largely determined by your contract and the laws applicable to it. But some basic principles will be applicable depending on the source of the suspension.
Suspension by the Owner: An owner work suspension suggests review of the contract’s suspension of work clause. Federal contractors would look to the FAR Suspension of Work clause, FAR 52.242-14, but that is applicable if the suspension is by the Contracting Officer; the US would argue that a systemic suspension was a sovereign act and outside the FAR clause.
Contractors for private work and state or municipal work may have contractual suspension of work clauses. At least some suspension clauses provide relief for time and money.
Reprinted courtesy of Peckar & Abramson attorneys
Curtis W. Martin,
Patrick J. Greene and
Levi W. Barrett
Mr. Martin may be contacted at cmartin@pecklaw.com
Mr. Greene may be contacted at pgreene@pecklaw.com
Mr. Barrett may be contacted at lbarrett@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Pennsylvania’s Supreme Court Limits The Scope Of A Builder’s Implied Warranty Of Habitability
September 10, 2014 —
Edward A. Jaeger, Jr. and William L. Doerler – White and Williams LLPIn Conway v. Cutler Group, Inc., -- A.3d --, 2014 WL 4064261 (Pa.), the Supreme Court of Pennsylvania addressed the question of whether a subsequent home buyer can recover from a home builder pursuant to the builder’s implied warranty of habitability, a warranty that protects those who purchase a newly constructed home from latent defects. Concluding that a builder’s warranty of habitability is grounded in contract, the Court held that a subsequent purchaser of a previously inhabited home cannot recover damages from a builder-vendor based on the builder-vendor’s breach of the implied warranty of habitability. The Court’s decision leaves unanswered the question of whether a purchaser who is also the first user-purchaser of a new home can pursue a breach of warranty action against a builder with whom the purchaser is not in privity of contract.
In Conway, the Cutler Group, Inc. (Cutler) sold a new home to Davey and Holly Fields. The Fields subsequently sold the home to Michael and Deborah Conway. After the Conways discovered water infiltration problems in their home, they filed a one-count complaint against Cutler, alleging that Cutler breached its implied warranty of habitability. In response to the Conways’ complaint, Cutler filed preliminary objections, arguing that the warranty of habitability extends from the builder only to the first purchaser of a newly constructed home. The trial court sustained Cutler’s preliminary objections based on the lack of contractual privity between the parties and the Conways appealed the trial court’s decision. On appeal, the Superior Court reversed, stating that the implied warranty of habitability is based on public policy considerations and exists independently of any representations by the builder, and even in the absence of an express contract between the builder and the purchaser. Cutler appealed the Superior Court’s decision to the Supreme Court.
To address the question of whether the implied warranty of habitability extends to a subsequent purchaser of a used residence, the Court discussed the history of the implied warranty of habitability in Pennsylvania. As stated by the Court, the Court adopted the implied warranty of habitability in the context of new home sales to reject the traditional doctrine of caveat emptor (buyer beware) because the purchaser of a new home justifiably relies on the skill of the developer. Thus, as between the builder-vendor and the buyer, the builder should bear the risk that the home he builds is habitable and functional. In adopting the doctrine, the Court noted that the doctrine is rooted in the existence of a contract – an agreement of sale – between the builder-vendor and the buyer.
Reprinted courtesy of
Edward A. Jaeger, Jr., White and Williams LLP and
William L. Doerler, White and Williams LLP
Mr. Jaeger may be contacted at jaegere@whiteandwilliams.com; Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Quick Note: Not In Contract With The Owner? Serve A Notice To Owner.
August 13, 2019 —
David Adelstein - Florida Construction Legal UpdatesA subcontractor or supplier not in direct contract with an owner must serve a Notice to Owner within 45 days of initial furnishing to preserve construction lien rights. Of course, the notice of commencement should be reviewed to determine whether the subcontractor or supplier has construction lien or payment bond rights so that it knows how to best proceed in the event of nonpayment. Serving a Notice to Owner should be done as a matter of course — a standard business operation; no exceptions.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Congratulations to Nicholas Rodriguez on His Promotion to Partner
November 25, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPBremer Whyte Brown & O’Meara, LLP is very proud to announce that Nick Rodriguez has been promoted to the position of partner with the firm!
Nick has been with BWB&O since 2019 and is licensed to practice law in California and the U.S. District Courts. Nick’s practice focuses on complex construction defect matters, as well as personal injury and wrongful death claims. During his time with the firm, Nick has successfully represented numerous clients through alternative dispute resolution and has taken matters to trial where he has received favorable jury verdicts. He also supervises and manages a team of associates in the Newport Beach office.
Read the court decisionRead the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Gehry-Designed Project Seen Bringing NYC Vibe to L.A.
April 28, 2014 —
Nadja Brandt and John Gittelsohn – BloombergBillionaire Stephen Ross’s Related Cos. new project in the sleepy end of downtown Los Angeles is designed to invigorate Grand Avenue the way its Time Warner Center helped energize New York’s Columbus Circle.
“The notion of bringing together this diverse mix of uses, and allowing for a lot of public spaces and public events, has proven to be very powerful in the right locations and with the right planning.” said William Witte, president of Related’s California division.
The New York-based firm formed a joint venture with Los Angeles-based SBE Entertainment Group LLC to restart plans for a $650 million-to-$700 million complex with entertainment, shopping, apartments, condominiums and a luxury hotel, Witte said. After going back and forth with local officials for most of the past year, Related won approval in January for the Frank Gehry-designed project from Los Angeles County supervisors.
Ms. Brandt may be contacted at nbrandt@bloomberg.net; Mr. Gittelsohn may be contacted at johngitt@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
Nadja Brandt and John Gittelsohn, Bloomberg
