FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Liquidating Agreements—Bridging the Privity Gap for Subcontractors

September 03, 2015 — Craig Martin – Construction Contractor Advisor
What is a subcontractor to do when the owner has demanded additional work, but has refused to pay for it? Typically, a subcontractor cannot sue the owner because the subcontractor doesn’t have a contract with the owner. Perhaps the subcontractor and general contractor should enter into a liquidating agreement through which the general contractor can pursue the claim on behalf of the subcontractor. Liquidating agreements bridge the privity gap between owners and subcontractors who sustain damages because of the others actions. Liquidating agreements or pass-through agreements grant the general contractor a release of its liability to the subcontractor after the general contractor prosecutes the subcontractor’s pass-through claim against the owner and gives the subcontractor any recovery. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Colorado HB 13-1090: Concerning Payment of Amounts Due Under a Construction Agreement

February 21, 2013 — David M. McLain — Higgins, Hopkins, McLain & Roswell, LLC
On January 17, 2013 Representative Fischer introduced House Bill 13-1090 into the Colorado House of Representatives. HB 1090 was assigned the House Business, Labor, Economic and Workforce Development Committee. The bill, sponsored by Senator Tochtrop in the Senate, sets the following requirements for both private and public construction contracts: The owner and contractor must make regular progress payments approximately every 30 days to contractors and subcontractors for work actually performed. To receive the progress payments, the contractor and subcontractor must submit a progress payment invoice plus any required documents. A contractor must pass on the progress payment to the subcontractor within 5 days or by the end of the billing cycle. Interest accrues on unpaid progress payments. A contract may extend a billing cycle to 60 days, but the contract must duly warn of this. Read the court decision
Read the full story...
Reprinted courtesy of David M. McLain
mclain@hhmrlaw.com

---

Understanding the California Consumer Privacy Act

March 02, 2020 — Kevin Bonsignore - Wilke Fleury
The recently enacted California Consumer Privacy Act (“CCPA” or the “Act”) goes into effect on January 1, 2020 and with it comes enhanced consumer protections for California residents against businesses that collect their personal information. Generally speaking, the CCPA requires that businesses provide consumers with information relating to the business’ access to and sharing of personal information. Accordingly, businesses should determine whether the CCPA will apply to them and, if so, what policies and procedures they should implement to comply with this new law. Application of the CCPA Importantly, the CCPA does not apply to all California business. The requirements of the CCPA only apply where a for-profit entity collects Consumers’ Personal Information, does business in the State of California, and satisfies one or more of the following: (1) has annual gross revenues in excess of twenty-five million dollars ($25,000,000); (2) receives for the business’s commercial purposes, sells, or shares for commercial purposes the personal information of 50,000 or more consumers, households, or devices; or (3) derives 50 percent or more of its annual revenues from selling consumers’ personal information. (California Code of Civil Procedure § 1798.140(c)(1)(A)-(C).) Thus, as a practical matter, small “mom and pop” operations will likely not be subject to the CCPA, but most mid-size and large companies should review their own books or consult with an accountant to determine whether the CCPA applies to their business. Rights Granted to Consumers “Consumers,” as the term is used in the CCPA, means “any natural person who is a California resident…” (California Code of Civil Procedure § 1798.140(g).) This broad definition makes no carve-outs or exclusions for a business’s employees and, despite the traditional definition of the term “consumer,” does not seem to require that the resident purchase any goods or services. This definition seems intentional and was likely designed to prevent businesses from attempting to circumvent the requirements of the CCPA by arguing that the personal information they collect does not belong to “consumers” under the traditional meaning of the word. Read the court decision
Read the full story...
Reprinted courtesy of Kevin Bonsignore, Wilke Fleury
Mr. Bonsignore may be contacted at kbonsignore@wilkefleury.com

---

National Infrastructure Leaders Visit Dallas' Able Pump Station to Tout Benefits of Water Infrastructure Investment

September 25, 2023 — American Society of Civil Engineers
DALLAS, TX. — An award-winning pump station in south downtown Dallas that protects residents from the Trinity River today was showcased by the national Engineering and Public Works Roadshow as an example of how infrastructure investment can improve the resilience of a community, protect residents, and encourage economic growth. The Able Pump Station in downtown Dallas, Texas won awards from both the American Council of Engineering Companies and the American Society of Civil Engineers since its completion in 2019 and has been credited with providing 100-year flood protection to approximately three square miles of high-profile land that was historically vulnerable to severe flooding events from the Trinity River. The Engineering and Public Works Roadshow is a joint project of the American Council of Engineering Companies (ACEC), the American Public Works Association (APWA), and the American Society of Civil Engineers (ASCE). The properties adjacent to the previous Able sump complex had experienced frequent flooding. The sump complex included nine separate and interconnected ponds that store stormwater, as well as two existing pump stations, constructed in the 1930s and 1950s, with a combined capacity of 220,000 gallons per minute. To help prevent the loss of life as a result of flooding, the City of Dallas hired HDR to design the new Able Pump Station, which increases the pumping capacity nearly fourfold, to 875,000 gallons per minute. It also lowers the 100-year flood elevation from 399.0 to a design elevation of 392.5 feet. As the federal government continues to implement this monumental legislation, the second year of the Bipartisan Infrastructure Law will not be fully realized without an expanded and robust workforce. It is imperative that students nationwide are educated on the rewarding careers of civil engineering and public works so that these professions have the necessary staffing to complete transformative projects. Read the court decision
Read the full story...
Reprinted courtesy of

---

No Coverage for Tenant's Breach of Contract Claims

April 05, 2017 — Tred R. Eyerly – Insurance Law Hawaii
The court granted summary judgment to the insurer, finding there was no duty to defend or indemnify a tenant/insured's contract-related claims. Erie Ins. Exch. v. Little Ducklings Daycare Associates, LP, 2017 Phila. Ct. Com. Pl. LEXIS 22 (Pa. D. Jan. 25, 2017). Little Ducklings Daycare Preschool ("tenant") leased from the Estate of Carmen Neri ("landlord") premises to run a day care center for five years. The lease identified two of tenant's members, Maryanne L. Hatzold and Thomas Hatzold, as guarantors for the lease. The Hatzolds ("Guarantors") delivered to the landlord a written lease guaranty agreement. The guarantee assured the full payment and satisfaction of the rent owed under the lease. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Between Scylla and Charybids: The Mediation Privilege and Legal Malpractice Claims

August 19, 2015 — Garret Murai – California Construction Law Blog
I attended a mediation earlier this month in a real estate case. I won’t say more through because . . . well . . . it’s confidential. The confidentiality of mediations and of settlement discussions generally – the idea being that parties are more likely to resolve their differences if they can speak honestly and frankly with one another without fear that their words or actions can later be used against them in trial – has long been a hallmark of California law. But that may not be the case for long. In 2012, the California State Legislature directed the California Law Review Commission (“Commission”), the state agency responsible for recommending reforms to California law, to review and make recommendations regarding the relationship between California’s laws which make mediation discussions confidential and attorney malpractice. And it appears that the Commission will be reaching a recommendation soon. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

SIGAR Report Finds +$15 Billion in “Waste, Fraud and Abuse” in Afghanistan

August 20, 2018 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel
Today, our colleagues Alex Ginsberg, Glenn Sweatt and Kevin Massoudi published their Client Alert on a recently issued Special Inspector General for Afghanistan Reconstruction (SIGAR) Report that finds over $15 billion in waste, fraud and abuse. In New SIGAR Report Identifies “Waste, Fraud and Abuse” in Afghanistan, our colleagues identify key takeaways from the Report include:

• The Report reviewed public spending for Afghanistan reconstruction efforts and identified at least $15.5 billion in waste, fraud and abuse.

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---