Seattle Washington Building Expert Directory

Coverage Found for Faulty Workmanship Damaging Other Property

January 06, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The district court found that under Illinois law, the damage caused by the insured's faulty workmanship to portions of building beyond the scope of its own work was covered under a CGL policy. Westfield Ins. Co. v. Nat'l Decorating Serv., 2015 U.S. Dist. LEXS 159140 (N.D. Ill. Nov. 25, 2015). 200 North Jefferson, LLC was the owner and developer of a 24- story condominium building. 200 North Jefferson retained as the general contractor McHugh Construction Co. McHugh Construction retained National Decorating Service, Inc. as the subcontractor to perform all painting work on the project. The Condominium Association sued 200 North Jefferson, McHugh Construction, MCZ/Jameson Development Group, LLC, National Decorating for faulty workmanship. The alleged damages included:(1) cracking of the exterior concrete walls, interior walls and ceilings; (2) significant leakage through the exterior concrete walls, balconies, and windows; (3) defects to the common elements of the building; and (4) damage to the interior ceilings, floors, interior painting, drywall and furniture in the units. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Civil RICO Case Against Johnny Doc Is Challenging

October 20, 2016 — Wally Zimolong – Supplemental Conditions
News that a non-union contractor had filed a Lawsuit against IBEW Local 98 and its leader, John Dougherty, made headlines this week. While making fodder for local media, the plaintiffs must bound several legal hurdles before IBEW Local 98 and “Johnny Doc” face any threat of liability. Background on RICO The lawsuit was filed under a set of laws known as the Racketeer Influenced and Corrupt Organizations Act (RICO). I have written about RICO’s impact on labor unions on this blog before and predicted that recent federal court cases made RICO claims against more viable. RICO is a Nixon era set of laws that were originally passed to combat organized crime. There is both a civil and criminal component to RICO. (Interestingly, the RICO act remained relatively dormant until then U.S. Attorney Rudy Giuliani began effectively using it to prosecute the mob in the 1980’s.) Although recent decisions have made RICO claims against unions more viable, any RICO claim is still challenging. Indeed, some courts require a plaintiff in civil RICO cases to file a separate RICO case statement detailing its allegations. RICO claims are powerful. Some have called RICO claims a “thermonuclear” litigation device because the law permits the award of trebel (triple) damages and attorneys fees. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Hurricane Harvey Victims Face New Hurdles In Pursuing Coverage

September 07, 2017 — Tred R. Eyerly - Insurance Law Hawaii
Just as Hurricane Harvey departs the state, a new law in Texas, effective September 1, 2017, is going to make it more difficult for home and business owners to pursue claims against their insurance companies. Prior Texas law imposed liability on an insurer who violated the Insurance Code for the amount of the claim, interest on the amount of the claim at an annual interest rate of 18 percent, and reasonable attorney fees. H.B. 1774 was recently enacted to address legal actions for claims arising from damage to or loss of property due to hailstorms, lightening, wind, hurricane, rainstorm and other natural events. The bill creates additional procedural hurdles before a policy holder can file a lawsuit against the insurer. A written notice must be provided to the insurer at least 61 days before filing a lawsuit. The notice must include a statement of the acts giving rise to the claim, the specific amount alleged to be owed, and amount of reasonable and necessary attorney's fees already incurred by the policy holder. Once notice is received, the statute allows the insurers to send a written request to inspect, photograph, or evaluate the property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Application Of Two Construction Contract Provisions: No-Damages-For-Delay And Liquidated Damages

February 14, 2022 — David Adelstein - Florida Construction Legal Updates
A recent Florida opinion between a prime contractor and a Florida public body touches upon two important issues: (1) the application of a no-damage-for-delay provision; and (2) the application of a liquidated damages provision. Both provisions find there way into many construction contracts. Unfortunately, the opinion is sparse on facts. Nevertheless, the application of these provisions is worthy of consideration. In this opinion, Sarasota County v. Southern Underground Industries, Inc., 2022 WL 162977 (Fla. 2d DCA 2022), a county hired a contractor to install sanitary and water piping underneath a waterway. During construction, a nearby homeowner complained that vibration from the drilling caused damage to his home. As a result, the county stopped the contractor’s work to address a potential safety issue, as it was contractually entitled to do. The contractor hired a structural engineer to inspect the house and the engineer issued a report determining that any alleged damage was cosmetic and that there was sufficient monitoring of the vibrations to prevent future damage. The contractor also had an insurance policy to cover any homeowner claim for damage. However, upon receipt of the engineer’s report, the county did not lift its stop work order. Rather, the stop work order remained in place for an additional 71 days. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Eighth Circuit Rejects Retroactive Application of Construction Defect Legislation

September 17, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Eighth Circuit refused to retroactively apply an Arkansas statute establishing coverage for faulty workmanship. J-McDaniel Const. Co., Inc. v. Mid-Continent Cas. Co., 2014 U.S. App. LEXIS 14911 (8th Cir. Aug. 4, 2014). The homeowners sued J-McDaniel for faulty workmanship in constructing their home. The defective construction work was performed by subcontractors. Mid-Continent refused to defend or indemnify J-McDaniel. The insured sued Mid-Continent. The district court dismissed the claim pursuant to Essex Ins. Co. v. Holder, 261 S.W. 3d 456, 460 (Ark. 2008). In Essex, the Arkansas Supreme Court held that defective workmanship resulting in damages only to the work product itself was not an occurrence. Although The Arkansas legislature overruled Essex by statute, the district court found that the Arkansas case law barred retroactive application of the statute. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Haight’s John Arbucci and Kristian Moriarty Selected for Super Lawyers’ 2020 Southern California Rising Stars

July 20, 2020 — T. Giovanni “John” Arbucci & Kristian B. Moriarty - Haight Brown & Bonesteel
Congratulations to attorneys T. Giovanni “John” Arbucci and Kristian Moriarty who were selected to the Super Lawyers 2020 Southern California Rising Stars list. Each year, no more than 2.5% of the lawyers in the state are selected by the research team at Super Lawyers to receive this honor. Reprinted courtesy of T. Giovanni “John” Arbucci, Haight Brown & Bonesteel and Kristian B. Moriarty, Haight Brown & Bonesteel Mr. Arbucci may be contacted at jarbucci@hbblaw.com Mr. Moriarty may be contacted at kmoriarty@hbblaw.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Couple Perseveres to Build Green

August 27, 2013 — CDJ STAFF
Most homeowners don’t want to make their way through the mountain of paperwork required for LEED certification. But according to the Patriot News, Jens and Donna Damgaard aren’t most homeowners. The Damgaards set out to build a LEED-certified home, and struck with it to the end. The Damgaards started out by assembling a team so there wouldn’t be any questions down the road. They also kept going green as a goal, no matter what. Don Park, their contractor, said that “it worked out well. There was never a cost issue.” Jens Damgaas is an attorney in Harrisburg, and he put his skills as a lawyer to work in going through the paperwork, as if he were the projet’s LEED consultant. One further takeaway from the contractor, “everyone wants two-button toilets.” Read the court decision
Read the full story...
Reprinted courtesy of

Is Ohio’s Buckeye Lake Dam Safe?

March 12, 2015 — Beverley BevenFlorez-CDJ STAFF
According to Columbus Business First, a report by the U.S. Army Corps of Engineers that “assessed the structural integrity of the Buckeye Lake Dam [located in Ohio] and found serious problems that present significant risks to the public.” Problems arose, allegedly, from “construction of homes [and] pools and patios that have been built into the earthen embankment.” The U.S. Army Corps of Engineers report stated (according to Columbus Business First) “there was a potential for an eight-foot wave of water, mud and debris that would inundate an area as far as Hebron, more than two miles away.” Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES