Seattle Washington Building Expert Directory

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

A Trivial Case

November 07, 2022 — Garret Murai - California Construction Law Blog
Construction defect cases leading to physical injury are rarely trivial, at least in the eyes of the injured party, but alas sometimes they are as the next case, Nunez v. City of Redondo Beach, 81 Cal.App.5th 749 (2022), demonstrates. The Nunez Case Monica Nunez, Vice President of Finance and Accounting at a restaurant chain and a part-time fitness instructor at a gym, tripped and fell on a public sidewalk in Redondo Beach. Ms. Nunez, who was in her forties, tripped following a group run when her back foot hit a sidewalk slab that was elevated at its highest point approximately 11/16 inches. Ms. Nunez landed on her left knee and right arm and in the process fractured her kneecap and elbow. Ms. Nunez sued the City of Redondo Beach for her injuries alleging causes of action for dangerous conditions on public property under Government Code section 835, nuisance under Government Code section 815.2, and failure to perform a mandatory duty under Government Code section 815.6. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Dusseldorf Evacuates About 4,000 as World War II Bomb Defused

August 20, 2014 — Dorothee Tschampa – Bloomberg
Emergency services in the northern German city of Dusseldorf are preparing to evacuate more than 4,000 people, including residents of a retirement home, as work gets under way to disarm a World War II bomb discovered during construction work yesterday. A further 15,000 people, living within a 1 kilometer (0.6 mile) radius of the site, are being asked to stay indoors and keep away from windows, authorities said in a press release published on its website. The disposal is scheduled for 4 p.m. Roads in the vicinity are expected to remain closed until at least 5 p.m. The 500-kilogram (1,100 pound) U.S. aircraft bomb was unearthed on the site of the former Reitzenstein army barracks, which is being redeveloped as a residential area. It’s the fourth or fifth find since last year in the northeastern district of Moersenbroich, where new apartment buildings and houses are under construction, Tobias Schuelpen, a press spokesman for the local fire service, said by phone. Read the court decision
Read the full story...
Reprinted courtesy of Dorothee Tschampa, Bloomberg
Ms. Tschampa may be contacted at dtschampa@bloomberg.net

Defend Trade Secret Act of 2016–-Federalizing Trade Secret Law

October 07, 2016 — Erin M. Stines and Reed Cahill - Ahlers & Cressman PLLC
The Defend Trade Secret Act of 2016 (DTSA) was signed into law on May 11, 2016, and became effective immediately. The DTSA allows an owner of a trade secret to sue in federal court for trade secret misappropriation. Previously, only state law governed civil misappropriation of trade secrets. While the DTSA largely mirrors the current state of the law under the Uniform Trade Secrets Act (UTSA), adopted by 48 states, including Washington,[1] there are some additions found in the new law. The DTSA imposes the same three-year statute of limitations and authorizes remedies similar to those provided under the UTSA. The DTSA also offers new forms of relief, including a provision permitting ex parte seizure orders (that is, without a hearing or response from the opposing party) to prevent further misappropriation of the trade secret. The DTSA further provides for a new definition of trade secret. The UTSA's definition of a trade secret is a “formula, pattern, compilation, program, device, method, technique, or process.” Under the DTSA, the definition of a “trade secret” is broadened to include “all forms and types of financial, business, scientific, technical, economic, or engineering information...whether tangible or intangible...” [2] Read the court decision
Read the full story...
Reprinted courtesy of Erin M. Stines & Reed Cahill, Ahlers & Cressman PLLC
Ms. Stines may be contacted at erin.stines@ac-lawyers.com

Float-In of MassDOT Span Sails, But Delay Dispute Lingers

December 08, 2016 — Johanna Knapschaefer – Engineering News-Record
The Massachusetts Dept. of Transportation and a contracting team are in discussions regarding fabrication issues that caused a two-year delay in the completion of a key crossing between Quincy and Weymouth. The full completion of the $244-million Fore River Bridge replacement, originally slated for Jan. 5, 2017, is now projected for February 2019. Read the court decision
Read the full story...
Reprinted courtesy of Johanna Knapschaefer, Engineering News-Record
ENR may be contacted at enr.com@bnpmedia.com

Reversing Itself, West Virginia Supreme Court Holds Construction Defects Are Covered

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
The West Virginia Supreme Court previously held that construction defects were not covered under a CGL policy. The Court, however, reversed itself in Cherrington v. Erie Ins. Prop. & Cas. Co., 2013 W.Va. LEXIS 724 (W.V. June 18, 2013). The underlying complaint against the general contractor alleged various defects in the plaintiff’s recently constructed house, including an uneven concrete floor, water infiltration through the roof and chimney joint, a sagging support beam, and numerous cracks in the drywall walls and partitions throughout the house. Erie Insurance denied coverage. The insured general contractor sued, but the trial court found that faulty workmanship was not sufficient to give rise to an “occurrence.” The West Virginia Supreme Court reversed its prior rulings determining there was no coverage for construction defects. The court recognized its prior position was in the minority, as is Hawaii's position on coverage for construction defects. See Group Builders Inc. v. Admiral Ins. Co., 123 Haw. 142, 148, 231 P.3d 67, 73 (Haw. Ct. App. 2010). Now joining the majority position, the West Virginia Supreme Court found that defective workmanship causing property damage was an “occurrence” under a CGL policy. Further, the homeowner had demonstrated that she sustained "property damage" as a result of the allegedly defective construction of her home. The trial court also determined that the business risk exclusions barred coverage. Again, the West Virginia Supreme Court disagreed. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

BHA Expands Construction Experts Group

October 28, 2011 — Bert L. Howe & Associates, Inc. - Corporate Offices

Bert L. Howe & Associates, Inc., one of the nation’s leading construction forensics firms is pleased to announce the expansion of the company’s civil and structural engineering capabilities.

JERRY M. MILES, PE - Mr. Miles has been a licensed civil engineer in California since 1987 and has served as the lead civil engineer on many projects in several states. His experience includes contract administration services as the owner’s representative on a variety of projects including mastered planned communities, residential subdivisions, shopping centers and multi-family residential projects. He has also been involved in providing water quality management plans and storm water pollution prevention plans. Mr. Miles has also served on the Town of Apple Valley’s Building Department Dispute Resolution Board.

His more than 26 years of engineering experience includes geotechnical evaluations, structural design of wood-framed, masonry, and concrete tilt-up buildings, small and large subdivision engineering construction/improvements plans, hydrology/hydraulic reports and design, forensic investigation and expert witness testimony. Mr. Miles has qualified as an expert in numerous jurisdictions and Federal court. He has been called upon to provide deposition testimony on more than twenty-five occasions and has successfully testified at arbitration and trial. Click here to view Mr. Miles’ Current CV.

MATTHEW J. STIEFEL, PE - With a background that spans a multitude of design and new construction projects to catastrophic claims analysis, Mr. Stiefel brings a unique set of credentials and experience to the construction experts group at Bert L. Howe & Associates. Mr. Stiefel has more than 13 years’ experience in civil, structural, and geotechnical engineering; providing design and construction consulting services on a variety of projects that include multi-family and single family dwellings, commercial buildings, transportation facilities, industrial facilities, storm drain channels, water and wastewater pipelines. His engineering experience encompasses multiple disciplines of civil engineering including geotechnical design and evaluation, foundation design, structural design of wood-framed buildings, preparation of grading plans and site drainage analysis. He has provided cause and origin analysis for insurance adjusters on many residential and commercial sites related to issues involving moisture intrusion and mold, foundation movement, site drainage, soil movement, wind damage, and other various losses. Click here to view Mr. Stiefel’s Current CV.

Read the court decision
Read the full story...
Reprinted courtesy of

California MCLE Seminar at BHA Sacramento July 11th

June 11, 2014 — Kimberly Albarq-CDJ STAFF
There are just three weeks remaining to sign up for Bert L. Howe & Associate’s next California MCLE seminar, UNDERSTANDING CONSTRUCTION DEFECT LITIGATION. This activity will be presented on Friday, July 11th at noon, at BHA’s Sacramento office: 2520 Venture Oaks Way Suite 435 Sacramento, CA 95833 There is no cost for attendance at this seminar and lunch will be provided. This course has been approved for Minimum Continuing Legal Education credit by the State Bar of California Committee on MCLE in the amount of 1.0 credit hours, of which 0.0 credit hours will apply to legal ethics/professional responsibility credit. The seminar will be presented by Don MacGregor, general contractor and project manager. Water intrusion through doors, windows and roofing systems, as well as soil and foundation-related movement, and the resultant damage associated therewith, are the triggering effects for the vast majority of homeowner complaints today and serve as the basis for most residential construction defect litigation. The graphic and animation-supported workshop/lecture activity will focus on the residential construction process from site preparation through occupancy, an examination of associated damages most often encountered when investigating construction defect claims, and the inter-relationships between the developer, general contractor, sub trades and design professionals. Typical plaintiff homeowner/HOA expert allegations will be examined in connection with those building components most frequently associated with construction defect and claims litigation. The workshop will examine: * Typical construction materials, and terminology associated with residential construction * The installation process and sequencing of major construction elements, including interrelationship with other building assemblies * The parties (subcontractors) typically associated with major construction assemblies and components * An analysis of exposure/allocation to responsible parties. Attendance at THE UNDERSTANDING CONSTRUCTION DEFECT LITIGATION seminar will provide the attendee with: * A greater understanding of the terms and conditions encountered when dealing with common construction defect issues * A greater understanding of contractual scopes of work encountered when reviewing construction contract documents * The ability to identify, both quickly and accurately, potentially responsible parties * An understanding of damages most often associated with construction defects, as well as a greater ability to identify conditions triggering coverage To register for the event, please email Don MacGregor at dmac@berthowe.com. If you have any questions, please feel free to contact Don at (800) 482-1822 (office) or (714) 713-4956 (cell). Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES