FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

A Few Things You Might Consider Doing Instead of Binging on Netflix

April 13, 2020 — Garret Murai - California Construction Law Blog
Governments throughout the world have issued “shelter in place” orders requiring that residents stay at home except for “essential” purposes. As a result, in the United States, more than a third of Americans have been ordered to stay at home. This, in turn, has had a direct impact on construction projects which have slowed or have been temporarily shuttered altogether, and it will (not may) have an impact on the flow of project funds. So what can project owners and contractors do? We’ve got a few tips. 1. Read Your Contract, Paying Particular Attention to Force Majeure, No Damages for Delay and Notice Provisions For the most part, with the exception of statutory rights and remedies which we will discuss below, your contract spells out your rights and remedies should the proverbial “S” hit the fan. It is, in other words, the rules you agreed to, and you should know what those rules provide. Three provisions you should look for, and if they’re in your contract, you should review carefully are: (1) Force majeure provisions; (2) No damages for delay provisions; and (3) notice provisions. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Gone Fishing: Tenant’s Insurer Casts A Line Seeking To Subrogate Against The Landlord

October 17, 2022 — William L. Doerler - The Subrogation Strategist
In J&J Fish on Ctr. Str., Inc. v. Crum & Forster Specialty Ins. Co., No. 20-cv-644-bhl, 2022 U.S. Dist. LEXIS 16361, the United States District Court for the Eastern District of Wisconsin (District Court) recognized that “[t]here will be no further fish fries on Center Street until someone pays to repair the collapsed floor at J&J Fish on Center Street, Inc. (J&J Fish).” The contenders were: 1) J&J Fish; 2) its’ insurer, Crum & Forster Specialty Insurance Company (Insurer); and 3) J&J Fish’s landlord, Vision Land, LLC (Vision). Recognizing Insurer’s right to subrogate against Vision based on the terms of the parties’ lease, the District Court held Insurer owed J&J Fish coverage for the losses it sustained, but that Insurer could subrogate against Vision for anything it had to pay J&J Fish. In J&J Fish, Vision and J&J Fish signed a lease (Lease) for a building (the Building) located in Milwaukee, Wisconsin. The Lease required Vision to “purchase and keep in full force and effect on the building(s) . . . insurance against fire and such other risks as may be included in all-risks policies . . .” Vision, however, never obtained any insurance on the Building. Pursuant to the Lease, Vision also agreed to “maintain and repair the structure including the slab floor and exterior walls of the Premises.” With respect to J&J Fish, the Lease required J&J Fish to maintain “Physical Damage insurance, including but not limited to fire . . . and all other risks of direct physical loss as insured . . . for the full replacement cost of all additions, improvements (including leasehold improvements) and alterations to the Premises.” J&J Fish purchased a commercial property and casualty insurance policy (the Policy) from Insurer. The Policy covered “additions, improvements . . . and alterations” as the Lease required. In addition, it insured the Building itself against “collapse,” subject to certain exceptions. Read the court decision
Read the full story...
Reprinted courtesy of William L. Doerler, White and Williams LLP
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com

---

UPDATE: ACS Obtains Additional $13.6 Million for General Contractor Client After $19.2 Million Jury Trial Victory

June 27, 2022 — Kristina Southwell - Ahlers Cressman & Sleight PLLC
In March 2022, ACS obtained a $19.2 million jury verdict in favor of its general contractor client after a lengthy trial against the project owner. Since that time, ACS has successfully obtained awards through post-trial motion practice for an additional $13.6 million in favor of the general contractor. These awards increased to total judgment to more than $32 million. When moving to enter judgment on the jury verdict, ACS successfully argued for and obtained more than $5 million in prejudgment interest on the jury verdict to compensate the general contractor for having to go years without payment for work performed. ACS also successfully obtained a decree of foreclosure on its construction lien and incorporated language in the judgment requiring the owner to pay an additional $1.9 million in Washington State sales tax on the jury award. Finally, under the authority of the Washington construction lien statute (RCW 60.04.181), ACS sought to recover the attorneys’ fees, costs, and expenses incurred by the general contractor client during the course of litigation. ACS succeeded in obtaining an award for more than $6.6 million for various expenses and costs including ACS’s attorney fees, all the costs of hiring expert witnesses, costs and expenses related to subcontractors’ presentation of pass-through claims against the owner, and other litigation costs and expenses. Read the court decision
Read the full story...
Reprinted courtesy of Kristina Southwell, Ahlers Cressman & Sleight PLLC
Ms. Southwell may be contacted at wendy.wheatmccoy@acslawyers.com

---

Construction Bright Spot in Indianapolis

March 01, 2012 — CDJ STAFF

The downtown Indianapolis area is the site of about 85 major building projects that are from groundbreaking to just complete. The Indianapolis Star reports that the cumulative worth of the projects is about $3 billion, a level of construction that Indianapolis has seen only once before.



About thirty of the projects are residential. The main commercial project is a $754 million hospital building. The boom in downtown Indianapolis is not matched elsewhere, with the Indianapolis Star reporting that in the rest of Central Indiana, construction has slowed.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

A Contractual Liability Exclusion Doesn't Preclude Insurer's Duty to Indemnify

November 05, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Traub Lieberman Straus & Shrewsberry LLP's blog, "[I]n Crownover v. Mid-Continent Cas. Co., 2014 U.S. App. LEXIS 20737 (5th Cir. October 29, 2014), the United States Court of Appeals for the Fifth Circuit withdrew its prior ruling and held that the contractual liability exclusion did not preclude an insurer’s duty to indemnify its insured for an award resulting from the insured’s defective construction." The case involved the Crownovers who were awarded damages for "Arrow's breach of paragraph 23.1 of the construction contract." However, Arrow then filed for bankruptcy. Mid-Continent, Arrow's insurer, denied Crownovers' demand for recovery, stating that "the contractual liability exclusion applied because the arbitrator’s award to the Crownovers was based only on Arrow’s breach of paragraph 23.1 of the construction agreement." The court agreed with Mid-Continent. Subsequently, the fifth court of appeals "reversed the district court’s ruling and awarded summary judgment in favor of the Crownovers." Read the court decision
Read the full story...
Reprinted courtesy of

---

Lawyer Claims HOA Scam Mastermind Bribed Politicians

June 28, 2013 — CDJ STAFF
The lawyer defending one of the accused in the Las Vegas HOA scam is now claiming that the FBI investigated bribery of public officials. Chris Rasmussen represents Edith Gillespie, the half-sister of Leon Benzer. Benzer has been accused of being one of the masterminds behind the scheme to pack homeowner boards with members who would make construction defect settlements that were beneficial to the scam’s participants. Rasmussen is trying to get his client tried separately from her half-brother. Rasmussen did not name any public officials. The Justice Department did not comment on his claims. Read the court decision
Read the full story...
Reprinted courtesy of

---

New Law Impacting Florida’s Statute of Repose

June 29, 2017 — Meredith N. Reynolds & K. Stefan Chin – Peckar & Abramson, P.C.
On June 14, 2017, Governor Scott signed House Bill 377 into law, clarifying that Florida’s ten-year Statute of Repose commences either when the work is completed or when final payment becomes due, whichever is latest. The new law resolves a problem for contractors created by a recent Florida court ruling that held the Statute of Repose to commence as late as when the owner made final payment. The applicable amendments to Florida Statute Section 95.11 take effect on July 1, 2017 and apply to all causes of action that accrue on or after that date. Perhaps the most critical component of a construction professional’s risk management program is the length of time that it is liable for the work performed on a project. While contractual warranty periods typically run one or two years from substantial completion, the true length of a contractor’s post-completion obligation is measured by the “Statute of Repose,” which establishes the period of time following the completion of construction that a lawsuit can be filed for construction defects. Reprinted courtesy of Meredith N. Reynolds, Peckar & Abramson, P.C. and K. Stefan Chin, Peckar & Abramson, P.C. Ms. Reynolds may be contacted at mreynolds@pecklaw.com Mr. Chin may be contacted at kschin@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---