Fairfield Connecticut Building Expert Directory

Best Lawyers Honors 43 Lewis Brisbois Attorneys, Recognizes Three Partners as 'Lawyers of The Year'

September 14, 2020 — Lewis Brisbois
Best Lawyers has selected 43 Lewis Brisbois attorneys across 25 offices for inclusion in its list of 2021 Best Lawyers in America. It has also recognized three Lewis Brisbois partners as "Lawyers of the Year": Los Angeles Partner Jon P. Kardassakis (Mass Tort Litigation / Class Actions - Defendants); Roanoke Partner Paul C. Kuhnel (Medical Malpractice Law - Defendants); and Northwest Indiana Managing Partner Renee J. Mortimer (Personal Injury Litigation - Defendants). Please join us in congratulating these three partners and the following attorneys on their Best Lawyers recognition. Reprinted courtesy of Lewis Brisbois Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Creating a Custom Home Feature in the Great Outdoors

July 09, 2014 — Beverley BevenFlorez-CDJ STAFF
When a resort designer and a spa director join together to create a custom home, what do you get? An outdoor tub that resides on a balcony overlooking the San Francisco Bay. According to Custom Home, Scott Lee, president of SB Architects, and his wife had the “custom cast concrete tub…craned into place on the third-story deck while avoiding an established oak tree.” A radiant heat lamp makes the outdoor bathing area practical, while the curved backrest, remote controlled dimmable lights, and music make the experience luxurious. “Tubs are more about relaxing then getting clean,” Lee told Custom Home. “Being out here among the branches with views of San Francisco, it really is like a resort.” Read the court decision
Read the full story...
Reprinted courtesy of

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Considerations in Obtaining a Mechanic’s Lien in Maryland (Don’t try this at home)

February 23, 2016 — Christopher G. Hill – Construction Law Musings
For this week’s Guest Post Friday at Construction Law Musings I welcome Matthew Evans. Matt is the owner of Law Offices of Matthew S. Evans, III, LLC located in Annapolis, Maryland. He has practiced construction, real estate and land use law in Maryland and D.C. for thirteen years. Prior to opening his own firm in May 2011, Mr. Evans was a partner at a mid-sized firm in Anne Arundel County, Maryland. Mr. Evans lives in Historic Annapolis (only three short blocks from his office) with his wife Margaret, and three children, Matthew (5), Bo (4) and Peyton (2). Some of the most common calls I get are from irate contractor or subcontractor clients who have not been paid demanding that I “lien the property”. Many times after calming the client down, I determine, to their dismay, that they are not entitled to a mechanic’s lien. In Maryland, the mechanic’s lien law is driven by statute, which contains specific requirements which must be met before the client is entitled to a lien. The first question is whether the contractor or subcontractor is entitled to a lien for the work performed. Under Maryland law, “every building erected and every building repaired, rebuilt, or improved to the extent of 15 percent of its value is subject to establishment of a lien…for the payment of all debts.” It’s easy when dealing with new construction. No matter how small your portion of the work, the property is subject to the establishment of a lien. It is more difficult to determine entitlement when there is either a total or partial renovation or other work. The question becomes how do you determine the value of the building, and whether it has been improved “to the extent of 15 percent of its value.” Believe me, I have seen creative and some not so creative methods of calculation used by counsel to prove that certain work does or does not meet the requirement. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Supreme Court of New Jersey Reviews Statutes of Limitation and the Discovery Rule in Construction Defect Cases

July 18, 2018 — David Suggs – Bert L. Howe & Associates, Inc.
Robert Neff Jr. of Wilson Elser analyzed the recent case, Palisades at Fort Lee Condo. Ass’n v. 100 Old Palisade, LLC, 2017 N.J. Lexis 845, 169 A.3d 473 (Supreme Court of New Jersey, September 14, 2017), and states that this ruling “gives defendants the ability to defend against the assertion that the statute of limitations was tolled until the most recent owner (and plaintiff) discovered the cause of action.” Neff concludes that a statute of limitations test needs to be conducted at the beginning of each case: “In Palisades, the motions to dismiss based on the statute of limitations were filed at the conclusion of all discovery. While an initial analysis might yield the conclusion that certain discovery will be needed to ascertain the appropriate accrual date (or dates, in the case of multiple defendants), counsel will then know what discovery to seek during the discovery period.” Read the court decision
Read the full story...
Reprinted courtesy of

Big Builder’s Analysis of the Top Ten Richest Counties

June 26, 2014 — Beverley BevenFlorez-CDJ STAFF
Big Builder took Forbes’ 2014 top ten richest U.S. counties list (based on household median income) and researched who the top builders were in those regions, buyer requirements, among other categories. The top three richest counties according to Forbes and Big Builder are Falls Church, Virginia; Loudoun County, Virginia; and Los Alamos County, New Mexico. Information listed for each county include the median-closing price, price per square foot, living square feet, top builders, and an examination of what makes each region unique. Read the court decision
Read the full story...
Reprinted courtesy of

FDOT Races to Re-Open Storm-Damaged Pensacola Bridge

April 12, 2021 — Jim Parsons - Engineering News-Record
Buffeted by hurricanes, northwest Florida’s largest-ever infrastructure effort is finally seeing the light at the end of the storm. The three-mile-long bridge across Pensacola Bay is expected to reopen to traffic this spring after an ongoing replacement effort abruptly became an emergency repair job as well. Reprinted courtesy of Jim Parsons, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Drowning of Two Boys Constitutes One Occurrence

August 06, 2014 — Tred R. Eyerly – Insurance Law Hawaii
When two boys drowned at a summer camp, the issue arose as to whether there were one or two occurrences. Fellowship of Christian Athletes v. AXIS Ins. Co., 2014 U.S. App. LEXIS 13176 (8th Cir. July 11, 2014). The two boys could not swim, and their camp permission forms indicated that they were non-swimmers. One night, the Fellowship of Christian Athletes (FCA) had a pool party. After the party, the FCA staff realized the two boys were missing. They had drowned, and their bodies were found lying side-by-side at the bottom of the deep end of the pool. The death certificate for one boy listed the time of death as 10:44 p.m., while the other boy's time of death was listed as 10:42 p.m. The FCA was insured under three policies. AXIS Insurance Company insured FCA under a CGL policy with $1 million limits per occurrence and $5 million in the aggregate. The FCA also had two umbrella policies, one issued by Ironshore Speciality Insurance Company, which provided up to $10 million in coverage in excess of Axis's policy. Under the second umbrella policy, RSUI Indemnity Company covered up to $5 million in excess of the Axis and Ironshore policies. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES