Fairfield Connecticut Building Expert Directory

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the court decision
Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

General Contractor Supporting a Subcontractor’s Change Order Only for Owner to Reject the Change

December 09, 2019 — David Adelstein - Florida Construction Legal Updates
The opinion in Westchester Fire Ins. Co, LLC v. Kesoki Painting, LLC, 260 So.3d 546 (Fla. 3d DCA 2018) leads to a worthy discussion because it involves a common scope of work occurrence on construction projects involving a general contractor and subcontractor. The contractor submits a subcontractor’s change order request to the owner and the owner rejects the change order. What happens next is a scope of work payment dispute between the general contractor and subcontractor. Yep, a common occurrence. In this case, a general contractor hired a subcontractor to perform waterproofing and painting. A scope of work issue arose because the specifications did not address how the window gaskets should be cut and then sealed. The owner wanted the window gaskets cut at a 45-degree angle and the subcontractor claimed this resulted in increased extra work. The general contractor agreed and submitted a change order to the owner to cover these costs. The owner rejected the change order claiming it was part of the general contractor’s scope of work even though the cutting of window gaskets at a 45-degree angle was not detailed in the specifications. After the subcontractor filed a suit against the general contractor’s payment bond surety, the project architect further rejected the change order because gasket cutting was part of the specification requirements. (Duh! What else was the architect going to say? It was not going to concede there was an omission that resulted in a change order to the owner, right?) Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

New California Construction Laws for 2020

March 09, 2020 — Smith Currie
The California Legislature introduced more than 3,033 bills in the first half of the 2019-2020 session. This article summarizes some of the more important bills affecting contractors in their roles as contractors, effective January 1, 2020, unless otherwise noted. Not addressed here are many other bills that will affect contractors in their roles as businesses, taxpayers, and employers. Each of the summaries is brief, focusing on what is most important to contractors. Because not all aspects of these bills are discussed, each summary’s title is a live link to the full text of the referenced bills for those wanting to explore the details of the new laws. BIDDING & PREQUALIFICATIONS Disabled Veteran Preferences Strengthened (AB 230, Brough) The California Legislature intends that every state procurement authority meet or exceed a DVBE participation goal of a minimum of 3% of total contract value. State departments must require prime contractors to certify at the completion of each contract the amount each DVBE received from the prime contractor, among other information. This new law requires the prime contractor to provide upon request proof of the amount and percentage of work the prime contractor committed to provide to one or more DVBEs under the contract in addition to proof of payment for work done by the DVBE. Additionally, prime contractors must now obtain permission before they may replace a listed DVBE. County of San Joaquin Now Authorized to Establish Bid Preferences (AB 1533, Eggman) This new law extends to the County of San Joaquin existing law that authorizes local agencies to establish preferences for small businesses, disabled veteran businesses, and social enterprises in facilitating contract awards. Read the court decision
Read the full story...
Reprinted courtesy of Smith Currie

Roof Mounted Solar Panels: Lower Your Risk of Fire

September 25, 2023 — The Hartford Staff - The Hartford Insights
As the federal government, individual states, businesses and consumers take steps to address climate change, the use of renewable energy – including roof-mounted solar panels – has steadily increased. Over the past decade, the use of solar energy solutions has grown by 33% annually. This is driven by tax-based incentives for clean energy, combined with installation costs that are down more than 50% from 10 years ago.1 As more companies execute climate-focused goals to limit greenhouse emissions, reduce their carbon-footprint and lower energy costs, the use of solar power for commercial buildings is likely to increase. Currently, it's estimated that only 3.5% of commercial buildings have rooftop solar panels, but 70% are potential targets for solar.2 We know the use of solar power can have positive impacts on the environment and generate long-term energy cost savings. However, there are several considerations and potential risks that commercial property owners and facilities managers should consider prior to investing in solar, says Tracey Greene, underwriting director for Middle and Large Commercial Real Estate at The Hartford. Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

Will Future Megacities Be a Marvel or a Mess? Look at New Delhi

November 14, 2018 — Jill Ward - Bloomberg
The effects of unbridled urbanization are inescapable in India’s capital city. Smog blankets landmarks like India Gate in winter, delaying flights at the airport due to poor visibility. Traffic jams are part of the daily routine and slums abut New Delhi’s luxury hotels and private mansions, testifying to a growing wealth divide and chronic housing shortage. And every day, the problem gets bigger. More than 27 million people live in and around Delhi with about 700,000 more joining them each year, according to research firm Demographia. The United Nations forecasts that by 2028 the population could outstrip Tokyo’s to make Delhi the world’s biggest megacity. Read the court decision
Read the full story...
Reprinted courtesy of Jill Ward, Bloomberg

Lack of Workers Holding Back Building

May 10, 2013 — CDJ STAFF
Builders are hiring again, or at least they’re trying to. According to an article in the Los Angeles Times, many of the workers who were laid off during the construction bust have gone on to work in other areas. John Nunan of Unger Construction told the Times that “we’re starting to see spot shortages of labor.” One problem is that despite the boom, wages haven’t risen. Rising costs for materials and land have put an additional squeeze on builders. One building supervisor noted that during the boom, he was making $26 an hour and entry level workers $17. Now he earns $16 an hour. From bust to recovery was about five years, and its labor pool could not just wait those years. Industry representatives told the Times that it has created a perception that construction is not a stable form of employment. Brian Turmail of the Associated General Contractors of America cited “pretty consistent news coverage about the fact that there are no jobs in construction.” Read the court decision
Read the full story...
Reprinted courtesy of

Seven Proactive Steps to Avoid Construction Delay Disputes

September 29, 2021 — Michael Pink - Construction Executive
Delays, cost overruns and disputes have long been part of the commercial construction industry, making the work of reactive forensic analysis by consultants and attorneys a necessary component. Yet many internal practices and issues within construction companies strongly correlate with projects that result in legal disputes and financial losses. There are seven proactive steps that can help companies minimize losses and claims. Prepare a Cost- and Resource-Loaded Critical Path Method Schedule This is the first step any contractor can take to establish and document a manpower plan, a timeline and an intended flow for its work. Doing so is beneficial for two reasons: it will become the basis for measuring impacts and variances to both cost and schedule in a delay, dispute or claim setting; and it will serve as a great project management resource or tool. Without thinking through manpower, durations and workflow in great detail at the beginning of the project, contractors put themselves at risk of becoming delayed and blowing the budget. Reprinted courtesy of Michael Pink, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

California Supreme Court Finds Vertical Exhaustion Applies to First-Level Excess Policies

August 26, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Addressing issues left open in its seminal decision in Montrose, the California Supreme Court found that the language in the first-level excess policies meant that the insured could access the policies upon exhaustion of the directly underlying policies purchased for the same policy period. Truck Ins. Exchange v. Kaiser Cement & Gypsum Corp., 2024 Cal. LEXIS 3271 (Cal. June 17, 2024). From 1944 through the 1970's, Kaiser manufactured asbestos-containing products at numerous different facilities. By 2004, more than 24,000 claimants had filed product liability claims against Kaiser alleging that they had suffered bodily injury as a result of exposure to Kaiser's asbestos products. Kaiser tendered these claims to Truck, one of several primary insurers that had issued CGL policies to Kaiser. In 2001, Truck initiated this coverage action to determine its indemnity and defense obligations to Kaiser. Truck later amended its complaint to add a cause of action for contribution against several of Kaiser's excess insurers. The issue presently before the court was whether Truck was entitled to contribution from various coinsurers that issued first-level excess policies to Kaiser during the period in question. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES