Seattle Washington Building Expert Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

The G2G Year in Review: 2020

January 18, 2021 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
As we say goodbye to 2020, we wanted to share our top five most-read articles of 2020 from Gravel2Gavel. The most-read blog posts covered real estate and construction industry trends ranging from proptech trends like blockchain tokenization to COVID-specific rent carveouts and management disclosures to trends and market updates. Our posts provided deep industry insight and summarized hot topics that addressed the legal implications and disruptions that affected the market. Our 2020 roundup:

Blockchain-Based Tokenization of Commercial Real Estate by Josh Morton and Matt Olhausen. Josh and Matt discuss the increasing interest in technology applications for real estate assets, or “Proptech,” and tokenization’s potential.
Real Estate Trends: Looking Ahead to 2021 by Adam Weaver. Adam discussed the pandemic’s influence and future trends for the real estate market.

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Flow-Down Clauses Can Drown Your Project

August 26, 2015 — Craig Martin – Construction Contractor Advisor
Flow-Down or pass-through clauses obligate downstream contractors to certain provisions contained in the up up-stream contractor contracts, such as the contract between the general contractor and the owner. These clauses are contained in every major form subcontract and they can expand the scope of your potential liability. This blog will look at typical language of a flow-down clause, what it means and how you can deal with them. Typical Flow-Down Clause A simple flow down clause might provide:

“The Subcontractor agrees to be bound to the Contractor by the terms of the prime contract and to assume to the Contractor all the obligations and responsibilities that the Contractor by those documents assumes to the Owner, except to the extent that the provisions contained therein are by the terms or by law applicable only to the Contractor.”

Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

The Creation of San Fransokyo

June 17, 2015 — Garret Murai – California Construction Law Blog
Some of the most awe inspiring buildings and urban environments started off on paper and, these days, on computer screens. Think Babylon or even Pierre Charles L’Enfant’s Washington, D.C.. Most of those structures and cityscapes were designed for human habitation, but not all. Some were designed purely for our imaginations, like Minecraft, which those of you with young ones might be familiar with. Another more recent example though is Big Hero 6, about a science-whiz named Hiro (pronounced “hero,” get it) who journeys from boyhood to manhood and saves the world along the way with his robot pal Baymax. The movie is set in foreign-yet-familiar “San Fransokyo.” Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Safety Accusations Fly in Dispute Between New York Developer and Contractor

July 01, 2019 — Richard Korman - Engineering News-Record
The developer of a New York City high rise and the project's former prime contractor are trading unusually nasty safety related accusations in a dispute over the contractor's exit from the project. The contractor, New York City-based Pizzarotti, claims the settlement of the structure in soft soils creates hazards in future work that could send building components crashing to the streets. In reply, developer Fortis Property Group says the contractor’s uneven pace of work is to blame for what it sees as only slab misalignments that don’t compromise safety in any way. Read the court decision
Read the full story...
Reprinted courtesy of Richard Korman, ENR
Mr. Korman may be contacted at kormanr@enr.com

Construction Demand Unsteady, Gains in Some Regions

June 29, 2011 — CDJ STAFF

The Associated General Contractors of America reported Tuesday, June 28 that construction employment increased in 120 of the 337 metropolitan areas surveyed between May 2010 and May 2011.

‘While construction employment has stopped plunging, any sign of a recovery remains spotty at best,” said Ken Simonson, the association’s chief economist. ‘The close to even split between areas adding and losing jobs is a reminder that for every market doing well, there is another market that is still hurting.”

The largest number of jobs created was in the Dallas, Texas region, with 5,600 new jobs, a five percent increase. The northern Massachusetts/southern New Hampshire region near Haverhill saw the greatest percentage increase, although that twenty-two percent increase represents only 800 new jobs. The Chicago, Illiinois area added 4,600 jobs, a four percent increase.

Other regions were not so lucky. The Atlanta, Georgia area saw a loss of 7,400 jobs, an eight percent loss. Las Vegas also lost 7,400 jobs, which there represented a sixteen percent decline. The New York City area lost 6,700 jobs, a six percent reduction. The Riverside, California area lost 5,300 jobs, a nine percent loss.

Stephen E. Sandherr, the association’s chief executive officer, blamed a combination of regulation and budget squeezes. "Some in Washington never met a regulation they didn’t like and others never found a penny they didn’t want to pinch. Together that makes for a bad way to boost employment and a great way to stifle the private sector and neglect critical economic infrastructure.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

The Choice Is Yours – Or Is It? Anti-Choice-of-Laws Statutes Applicable to Construction Contracts

October 03, 2022 — Tiffany Raush & Tanya McGill - ConsensusDocs
During contract negotiations and review, the parties make choices about what risks they are willing to accept and at what cost. But one often overlooked choice—the choice of law applicable to the contract—can undermine carefully negotiated construction contracts and expose contractors to risks they never intended to accept. Choice-of-law provisions are standard provisions in most contracts. These provisions allow the parties to the contract to decide which state’s laws will apply to their contract. Often, choice-of-law in the construction contract is the law of the state where the project is located and there will be no issue. But, if the project is located in an unfamiliar, the owner or prime contractor may prefer the laws of the state where the owner or prime contractor is primarily located over the laws of the state where the project is located. Generally, most states will enforce the parties’ choice of law in a contract. But that may not be the case for construction contracts. States like Texas, California, New York, Florida, Louisiana, and others may prohibit parties from agreeing to the application of another state’s law for construction projects in their states. Reprinted courtesy of Tiffany Raush, Jones Walker LLP (ConsensusDocs) and Tanya McGill, University of Mississippi School of Law Student, 2023 Graduate (ConsensusDocs) Ms. Raush may be contacted at traush@joneswalker.com Read the court decision
Read the full story...
Reprinted courtesy of

Asbestos Confirmed After New York City Steam Pipe Blast

July 21, 2018 — Eydie Cubarrubia - Engineering News-Record
Asbestos has been found at the site where an underground steam pipe exploded early Thursday morning near the Flatiron building in midtown Manhattan. Read the court decision
Read the full story...
Reprinted courtesy of Eydie Cubarrubia, ENR
Ms. Cubarrubia may be contacted at cubarrubiae@enr.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES