FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

An Upward Trend in Commercial Construction?

March 28, 2012 — Melissa Brumback, Construction Law in North Carolina

Year-end economic indicators demonstrate that private commercial construction may be increasing in 2012, primarily as demand grows for new projects built in the United States.



According to an article in Businessweek, the Architecture Billings Index held at 52 in December, indicating a modest expansion in the market. The American Institute of Architects said that the commercial and industrial component of the number climbed to 54.1 in December, the highest in 10 months.



The monthly survey of U.S.-based architecture firms is one of the main indicators of nonresidential construction, and these numbers suggest that modest improvement may be on the horizon.



The information is confirmed by data from the Census Bureau that shows that spending on lodging, office, commercial and manufacturing buildings grew 8.2 percent in November to $9.2 billion from a year ago. These types of commercial and industrial projects are historically canaries in the mine and are usually the first part of the industry to improve as the economy expands.

Read the full story…



Reprinted courtesy of Melissa Dewey Brumback of Ragsdale Liggett PLLC. Ms. Brumback can be contacted at mbrumback@rl-law.com.

Read the court decision
Read the full story...
Reprinted courtesy of

---

Mediation v. Arbitration, Both Private Dispute Resolution but Very Different Sorts

January 24, 2018 — Christopher G. Hill - Construction Law Musings
I often get calls from clients, potential construction clients, and other construction and business professionals with questions about arbitration or mediation clauses in the contracts that they are reviewing or drafting. When I get these calls, it often becomes clear that, understandably, there is some confusion as to what each of these alternate dispute resolution processes entails. I thought I’d put together a quick primer on what each is and their differences. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Haight Welcomes Robert S. Rucci

August 26, 2015 — Robert S. Rucci – Haight Brown & Bonesteel LLP
Haight Brown & Bonesteel LLP welcomes new partner Robert S. Rucci. Mr. Rucci joins Haight’s San Diego office in the Construction Law, General Liability and Risk Management & Insurance Law Practice Groups. For 25 years, Mr. Rucci has specialized in defending design professionals, businesses and their employees in addition to representing clients against declaratory relief, breach of contract and bad faith litigation. During his career, he has tried 60 cases to defense verdict and successfully resolved countless matters via mediation, arbitration and settlement conference. His extensive litigation experience is invaluable to our clients. Haight Brown & Bonesteel LLP 402 West Broadway Suite 1850 San Diego, CA 92101 www.hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of Robert S. Rucci, Haight Brown & Bonesteel LLP
Mr. Rucci may be contacted at rrucci@hbblaw.com

---

ASCE Statement on The Partial Building Collapse in Surfside, Florida

June 28, 2021 — Tom Smith - American Society of Civil Engineers
The following is a statement by Tom Smith, Executive Director, American Society of Civil Engineers (ASCE): WASHINGTON, DC. – We are saddened by the tragic news coming out of Surfside, Florida, regarding the fatal partial building collapse of a condominium early Thursday morning. Safety is the top priority of every civil engineer, and protecting public health and safety is core to our mission at ASCE. We share our deepest condolences to all of those affected by this tragedy. Collapses like these are fortunately highly unusual and extremely rare. However, it is imperative to identify the root cause of failures when they do occur, and to ensure that proactive steps are taken to prevent future incidents. ASCE fully supports the need for continued engineering assessments to pinpoint the cause of the collapse, and we stand ready to support official investigations with technical expertise and advice available through our 150,000 civil engineer members worldwide. While rescue and recovery operations are underway, it is important that we support our first responders who are conducting essential rescue efforts and are operating as quickly as possible. We will also continue to keep those who have been injured and those who have not yet been accounted for in our hearts and thoughts, and we share our heartfelt sympathies to all of those affected. ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel. Read the court decision
Read the full story...
Reprinted courtesy of

---

Georgia Coal-to-Solar Pivot Shows the Way on Climate Regs

July 02, 2014 — Mark Drajem and Margaret Newkirk – Bloomberg
Georgia small-business owner Julian Smith keeps hearing that the Obama administration’s latest climate regulations will drive up local electric bills. He doesn’t believe the prediction, but he isn’t arguing: The fears are doing wonders for his solar-panel installation company. “My phone is blowing up with new customers,” Smith, owner of SolarSmith LLC of Savannah, said in an interview. “It turns out that if you tell everybody the amount they will spend on electricity will skyrocket, they will believe you.” In Smith’s home state, as in the rest of the nation, businesses and consumers are struggling to size up competing claims about the Environmental Protection Agency’s plan to cut carbon pollution from power plants, released June 2. The proposed regulations are among the most sweeping and complex in the EPA’s history, promising to revamp the way electricity has been generated and distributed for a century. Mr. Drajem may be contacted at mdrajem@bloomberg.net; Ms. Newkirk may be contacted at mnewkirk@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Mark Drajem and Margaret Newkirk, Bloomberg

---

Skyline Bling: A $430 Million Hairpin Tower and Other Naked Bids for Tourism

January 21, 2015 — Toluse Olorunnipa – Bloomberg
American cities are starting an architectural arms race to the sky with super-sized Ferris wheels, a 100-story observation tower and maybe even a mammoth golf ball atop a 300-foot tee planted in the Arizona desert. From Phoenix to Camden, New Jersey, city officials and developers are seeking to punctuate their skylines with exclamation points, vying for the world’s attention with the next Eiffel Tower or London Eye. Read the court decision
Read the full story...
Reprinted courtesy of Toluse Olorunnipa, Bloomberg
Mr. Olorunnipa may be contacted at tolorunnipa@bloomberg.net

---

Wisconsin “property damage” caused by an “occurrence.”

April 04, 2011 — CDCoverage.com

In American Family Mut. Ins. Co. v. American Girl, Inc., 673 N.W.2d 65 (Wis. 2004), the insured general contractor was hired by the owner to design and build a warehouse on the owner s property. The general contractor hired a soil engineer to do a soil analysis and make site preparation recommendations. The soil engineer determined that the soil conditions were poor and recommended a compression process which the general contractor followed. After the warehouse was completed and the owner took possession, excessive soil settlement caused the foundation to sink which in turn caused structural damage to the warehouse. The warehouse had to be torn down.



Read the full story...



Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---