The Little Ice Age and Delay Claims
January 24, 2018 —
Wally Zimolong - Supplemental ConditionsMuch of the Eastern United States is just now emerging from a historic two week cold snap. In much of the Northeast and Mid-Atlantic, the temperature stayed below freezing for 15 days straight. Cities recorded the lowest temperatures in a quarter century. Winter Storm Grayson reeked havoc along the Eastern Coast bringing snow to places like Charleston and a crippling blizzard to Boston.
The record cold snap also impacted the construction industry. Delivery delays, the inability to apply weather sensitive applications (like cast in place concrete), and the unavailability of labor are just a few things that extreme weather can cause on a construction project. If they happen at the wrong time, delays can destroy project schedules and make previous delays even worse. Delays cost money and can mean the difference between a profitable project from both the owner and contractors perspective.
Read the court decisionRead the full story...Reprinted courtesy of
Wally Zimolong, Zimolong LLCMr. Zimolong may be contacted at
wally@zimolonglaw.com
No Coverage for Restoring Aesthetic Uniformity
December 10, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe court found there was no coverage regarding aesthetic uniformity between new materials installed after water damage occurred and the rest of the building. Great Am. Ins. Co. of New York v. The Towers of Quayside No. 4 Condominium Assoc., Case No. 15-CV-20056-King (U.S. Dist. Ct., S.D. Fla., Nov. 5, 2015).
The insured's high rise condominium suffered water damage when a valve on the air conditioning unit damaged the drywall, carpeting, baseboards, insulation and wallpaper in the east hallways of the eleventh floor and the floors below. Floors three through twenty-five had a uniform appearance by design with respect to the carpet, wallpaper, and woodwork in the common area hallways.
The insured submitted a claim under its property policy with Great American. A payment of $170,291.84 was made for damage to the east hallways of the eleventh floor and the floors below. The insured sought coverage to repair or replace undamaged carpeting, wallpaper, baseboards, and woodwork in (1) the west hallways and elevator landings of the eleventh floor and the floors below and in (2) floors twelve through twenty-five.The insured contended that the loss of aesthetic uniformity devalued the building and constituted a loss to the building.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Insurer Must Defend General Contractor
April 03, 2023 —
Tred R. Eyerly - Insurance Law HawaiiInterpreting Massachusetts law, the federal district court determined consequential damage resulting from the insured's faulty work triggered a duty to defend. Capitol Spec. Ins. Corp. v. Dello Russo Enter. LLC, 2023 U.S. Dist. LEXIS 11627 (D. Mass. Jan. 24, 2023).
Peta-Gay and Michael Print sued the insured, Dello Russo, who they hired as the general contractor for extensive remodelling and renovation of their building. During the demolition work, certain structural load-bearing walls were removed, including a portion of an exterior bricked masonry wall. Shoring of other parts of the building was inadequate and removal of the masonry wall reduced the structural integrity of the building. Cracks began to appear in the remaining portion of the masonry wall and increased over the next few days. Soon thereafter, the City of Boston determined the building was dangerous and that salvage of the undamaged portions was not feasible. Therefore, the building was demolished.
Certain Underwriters at Lloyd's, London, filed suit against Dello Russo as subrogee of the Prinns. Dello Russo tendered the complaint to its insurer, Capitol Specialty Insurance Corporation, who defended under a reservation of rights,. Capitol then filed a suit seeking a declaratory judgment that it had no duty to defend or to indemnify. The parties cross-claimed for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
2023’s Bank Failures: What Contractors, Material Suppliers and Equipment Lessors Can Do to Protect Themselves
May 15, 2023 —
Garret Murai - California Construction Law BlogIt has been a tumultuous year for the banking industry. Since the beginning of this year the industry has seen the collapse of Silicon Valley Bank and Signature Bank, the shotgun marriage between failing Credit Suisse and USB, and, most recently, the collapse of First Republic Bank this past week and its purchase by JP Morgan Chase. Indeed, according to the New York Times, these three bank failures cum bailouts alone were bigger than the 25 banks that collapsed during the financial crises of 2008 and some are concerned that it is just the beginning.
This, of course, has impacted the stock market, with Forbes reporting that the banking industry lost more than $300 billion in market value as of the end of March. However, it also raises concerns regarding liquidity on construction projects.
While the failing banks have either been bought out by other banks or shored up by the federal government, which, in the case of Silicon Valley Bank and Signature Bank, involved the Federal Deposit Insurance Corporation (FDIC), the Treasury Department and the Federal Reserve stepping into to protect depositors by
guaranteeing deposits in excess of the current FDIC limit of $250,000, there continues to be concerns over access to cash. This can impact construction projects in several ways.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Economic Loss Rule Bars Claims Against Manufacturer
November 02, 2020 —
David Adelstein - Florida Construction Legal UpdatesThe economic loss rule lives to bar a claim against a product manufacturer in a real estate transaction. In a products liability action, there needs to be personal injury or property damage, other than to the property itself, in order to recover economic damages. Otherwise, the economic loss rule will bar the recovery of such economic losses when the economic losses deal to the product itself. This is important to keep in mind in any product liability action against a manufacturer.
In a recent case, 2711 Hollywood Beach Condominium Assoc’n, Inc., v. TRG Holiday, Ltd., 45 Fla. L. Weekly D2179a (Fla. 3d DCA 2020), a condominium association purchased the condominium from the developer. Subsequently, it noticed leaks with the fire suppression system in the condominium and sued multiple parties for damages for repairs due to the leaks and the replacement of the fire suppression system. One of the parties sued in negligence and strict liability was a manufacturer of pipe fittings used in the fire suppression system. The manufacturer moved for summary judgment based on the economic loss rule and relying on the 1993 Florida Supreme Court opinion in Casa Clara Condominium Assoc’n v. Charley Toppino & Sons, Inc., 620 So.2d 1244 (Fla. 1993), holding “the economic loss rule limited a defendant’s tort liability for allegedly defective products to injuries caused to persons or damage caused to property other than the defective product itself.” 2711 Hollywood Beach Conominium Assoc’n, supra. The trial court agreed with the manufacturer and granted summary judgment. On appeal, the Third District affirmed based on the economic loss rule:
The Association bargained for, purchased and received a building; [the manufactuer’s] fittings were only a component of the FSS [fire suppression system], incorporated into the building. Applying the rule set forth in Casa Clara, the Association purchased a completed building from the developer. [The manufactuer’s] fittings were “an integral part of the finished product and, thus, did not injure ‘other’ property.” Injury to the building itself is not injury to “other” property because the product purchased by the Association was the building. See Casa Clara, 620 So. 2d at 1247. The economic loss rule therefore bars the Association’s recovery as to [the manufacturer] to the extent that it sought damages to replace the FSS [fire suppression system] and repair damage to the building.
2711 Hollywood Beach Conominium Assoc’n, supra (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Walmart Seeks Silicon Valley Vibe for New Arkansas Headquarters
June 18, 2019 —
Matthew Boyle - BloombergWalmart Inc. took inspiration from McDonald’s Corp., Apple Inc. and locations like Stanford University when designing the new headquarters that will start taking shape this summer.
The 350-acre campus will be located just a few blocks east of Walmart’s current home, a patchwork of more than 20 buildings in Bentonville, Arkansas. It will feature bike paths, food trucks and outdoor meeting areas -- part of an effort to lure younger, digitally-savvy workers to northwestern Arkansas.
Read the court decisionRead the full story...Reprinted courtesy of
Matthew Boyle, Bloomberg
A Sample Itinerary to get the Most out of West Coast Casualty’s Construction Defect Seminar
May 03, 2018 —
Beverley BevenFlorez-CDJ STAFFWith so many worthwhile events stretched across three days, as well as wanting to get out and explore the many attractions in Orange County, California, Construction Defect Journal has come up with a sample itinerary that balances work with recreation.
Day One: Wednesday, May 16th
9:00 a.m. – Breakfast at
Steakhouse 55 (Disneyland Hotel)
Meet up with colleagues at Disney’s Steakhouse 55 where you will find a more peaceful and upscale venue, perfect for networking or just catching up with friends.
10:00 a.m. -
Madara Spa at Disney’s Grand Californian Hotel
With a free morning, this is the perfect time to take advantage of one of the Disneyland Resort’s pools or schedule a massage at the Madara Spa located within the Grand Californian Hotel.
11:30 a.m. – Grab and Go Lunch at
The Coffee House (Disneyland Hotel)
Refuel with a salad or sandwich from one of Disneyland Resort’s quick service restaurants.
12:00 p.m. – Seminar Registration and Schwag Hunting
Start heading over to the seminar to register and be one of the first to check out the amazing exhibitors and grab the free items they have to offer. You don’t want to miss BHA’s golf challenge, where if you sink a putt you win a $25 Amazon gift card for yourself and BHA will match the $25 to the worthwhile WCC charities!
1:00 p.m. – Seminar Begins!
The afternoon starts with a not-to-be-missed panel, “Struggles and Successes of the Past 25 Years.” Next, you’ll learn about “Unwrapped and Unraveled - An insightful (or inciteful?) play at the
changing nature of the relationships between the parties in a wrap program who thought the wrap was supposed to take care of everything.”
3:00 p.m. – Afternoon Break
Get a cup of coffee or water, and head out into the exhibit hall. Don’t forget to go to BHA’s booth to enter to win Dodger tickets.
3:30 p.m. – Seminar Panels Continue
The seminar returns with two more amazing panels: “East Coast Meets West Coast –Hot Construction Defect Issues and Coverage Cases from the Other Coast” and “How to Conduct Your Claim Investigation and Early Claims Handling To Avoid Bad Faith Traps.”
6:00 p.m. – Attend an After Party
After taking a few minutes to unwind and freshen up, go and network as well as have some at one of the reception’s thrown by attending firms. No after party? Head over to the
Uva Bar at Downtown Disney for a cocktail and some people watching.
8:00 p.m. - Late Dinner at
Catal Restaurant (Downtown Disney)
Enjoy a relaxing and sumptuous meal at Catal in Downtown Disney, one of the famed Patina Group’s restaurants.
Day Two: Thursday, May 17th
7:30 a.m. – Breakfast in the Exhibit Hall
Take advantage of West Coast Casualty’s free breakfast, and peruse more exhibits. Check out BHA’s data process collection process and discover meaningful cost improvements that translate to reduced billing while providing superior accuracy and credibility.
8:30 a.m. – Seminar Panels
The seminar returns with more panels you won’t want to miss: “Recent Important Appellate Decisions in California, Nevada, and Arizona” and “Litigating In The Western States - A Judge’s Perspective.”
10:30 a.m. – Morning Break
Grab a cup of coffee or water and chat with your colleagues about the panels you just heard.
10:45 a.m. – Seminar Panel
Another important panel to finish the morning, “Subrogation is not the type of intervention I need. How a subrogated insurer affects construction defect matters.”
11:45 a.m. – Award Presentation
Find out this year’s winners of the Ollie, Legend of the Era and Silver Stars.
12:15 p.m. – WCC Luncheon
Network and chat with your colleagues at one of the meals provided by the seminar.
1:30 p.m. – Seminar Panel
Now that you’ve recharged, you’re ready for another incredible WCC panel: “What Comes Around (Sometimes) Goes Around: Dealing with Recalcitrant Carriers.”
2:30 p.m. – Afternoon Break
Stretch your legs in the exhibit hall and get yourself more schwag. Learn about BHA’s expanding market presence and full range of services in Texas, Florida, and across the Southeast United States.
3:00 p.m. – Seminar Panels Continue
Don’t miss the last two panels of the day: “Effective Use of Experts” and “Claims Managers Speak - A Retrospective & Prospective Discussion.”
5:30 p.m. – Cocktail Reception
With your glass of Cabernet, network with colleagues and then try your hand again at BHA’s golf challenge to win an Amazon gift card and earn money for WCC charities.
6:30 p.m. – Hit the Pool or Jacuzzi
Take those tired feet and soak them in one of the Disneyland Resort’s many pools and jacuzzi’s. Or schedule a spa treatment at
Madara in the Grand Californian Hotel.
7:00 p.m. – After Party or Ball Game
Now that you’ve given yourself some time to rejuvenate, you’re ready to meet up with friends and colleagues at one of the after parties and receptions. Or if you’re a sports fan and want a break from work, go cheer on the
Angel’s as they play Tampa Bay.
8:30 p.m. –
Uva Bar
Unless you chose to go to the game, enjoy a late supper and cocktail under the beautiful southern California sky at the Uva Bar in Downtown Disney.
Day Three: Friday, May 18th
7:30 a.m. – Breakfast at the Seminar
Take advantage of another free meal, and take the time to check out more exhibits as the last day of the seminar begins. Don’t forget to enter BHA’s raffle for Dodger tickets!
8:30 a.m. – Breakout Sessions I
Choose between one of three breakout sessions: “Known Knowns and Known: Unknowns, the Ins and Outs of Extrapolation,” “Risk Transfer Alphabet Soup - A twelve year lookback on legislative tinkering with anti-indemnity statutes - where are we now?” or “Florida – Opening Pandora's Box and How to Close It.”
9:30 a.m. – Breakout Sessions II
Three additional breakout sessions to choose from: “An Update on California’s Right to Repair Act, featuring McMillin Albany et al. v. Superior Court,” “Finding Evidence for your Coverage Case,” or “Northwest Insurance Coverage and Extra-Contractual Issues.”
10:30 a.m. – Morning Break
Refuel with coffee or water before the next group of exciting breakout sessions begins.
11:00 a.m. – Breakout Sessions III
You’ll want to go to one of these three breakout sessions: “Subcontractor Wars: The Last AI,” “Mediating the Luxury Single Family Home Construction Defect Case,” or “Creative Solutions to the Florida Problem: Making No Contribution and No State Law Work for You.”
12:00 p.m. – Breakout Sessions IV and the End of the Seminar
The seminar closes with the last trio of breakout sessions: “Everyone is a Small Player,” “Real World Solutions to the Real Problems Presented By Wrap Up Programs,” or “When Mother Nature Attacks, Are you Covered?”
1:30 p.m. – Lunch at
Corn Dog Castle in California Adventure Park OR
Hollinghead’s Delicatessen in Orange
If you’re a Disney lover, you’ll want to take advantage of the day by going to one of the Disney Resort Parks, of course. Get one of Disney’s amazing corn dogs at Corn Dog Castle in California Adventure Park.
Or if you would rather explore the greater Anaheim area, then head over to Hollinghead’s Delicatessen for a homemade sandwich and a glass of beer on tap.
3:00 p.m. –
Disney Entertainment OR Museum Exploring
If you chose to go to California Adventure, check out the event schedule for the day. Catch the show Frozen – Live at the Hyperion or get a
Fastpass for the Radiator Springs Racers and ride Soarin’ Around the World. If you purchased a two-park pass, don’t forget about Space Mountain or Star Tours located in the Disneyland Park.
North Orange county has many interesting museums. Head to the
Bowers Museum in Santa Ana or the
Muzeo in Anaheim.
7:00 p.m. – Dinner at the
Blue Bayou Restaurant OR the
Summit House Restaurant
Have a one-of-a-kind eating experience at the Blue Bayou in Disneyland Park. Enjoy a dinner in the midst of the Pirates of the Caribbean ride! If you wish to remain in the California Adventure Park, try an alfresco dinner at
Wine Country Trattoria or an indoor, upscale meal at
Carthay Circle.
After an afternoon perusing museums, enjoy a truly superb meal with attentive service at one of Anaheim’s premier restaurants, Summit House. Feeling like having some fun rather than a sedate meal? Head over to the
House of Blues in Anaheim for their Party Like It’s 1999! A Prince Tribute Party.
8:30 p.m. – Paint the Night Parade/Together Forever OR The Blind Rabbit Speakeasy
Head over to watch the
Paint the Night Parade at the California Adventure Park or the fireworks display,
Together Forever — A Pixar Nighttime Spectacular at the Disneyland Park. Be sure to check out the daily
event schedule for up to date information.
End your evening at Anaheim’s only speakeasy,
the Blind Rabbit, located in the Anaheim Meat Packing district. Be sure to check out their “rules” and reserve a table at this popular spot.
Read the court decisionRead the full story...Reprinted courtesy of
Construction Mezzanine Financing
March 29, 2017 —
Tim Davis & Steven Coury - White and Williams LLPConstruction mezzanine lending is on the rise and more development deals are getting done with a capital stack that includes mezzanine debt in addition to the traditional components of sponsor equity and senior mortgage debt. Below are important issues and concepts to bear in mind when structuring the financing of a construction project that includes a mezzanine debt component.
Funding Sequence
Funding Sequence
When will the proceeds of the mezzanine loan be advanced? In some instances, the mezzanine loan proceeds will be advanced only after all of the borrower’s equity has been contributed to the construction of the project. In other instances, the borrower’s equity and the mezzanine loan proceeds go in either pari passu or simultaneously at another ratio. If the equity is not entirely contributed in advance, the mezzanine lender may require that the uncontributed equity be held by the mezzanine lender or held in a pledged account. The mezzanine lender may also further mitigate the risk of non-funding of the equity by requiring an equity funding guaranty (as discussed below).
Additionally, when will the mezzanine loan proceeds be advanced in relation to the senior mortgage loan proceeds? Will the entire mezzanine loan be advanced prior to any senior mortgage loan advance or will they be advanced pari passu? Depending on the business deal, the mezzanine loan agreement will need to reflect how and when the equity, the mezzanine debt, and the mortgage debt will be advanced.
Reprinted courtesy of
Tim Davis, White and Williams LLP and
Steven Coury, White and Williams LLP
Mr. Davis may be contacted at davist@whiteandwilliams.com
Mr. Coury may be contacted at courys@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
