Cambridge Massachusetts Building Expert Directory

Michigan Finds Coverage for Subcontractor's Faulty Work

August 24, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The Michigan Supreme Court held that under a CGL policy, an "accident" may include unintentional subcontractor work that damages the insured's work product. Skanska USA Building Inc. v. M.A.P. Mechanical Contractors, Inc., et al., 2020 Mich. LEXIS 1194 (Mich. June 29, 2020). Skanska USA Building Inc. was the construction manager on a renovation project for a medical centre. The heatng and cooling portion of the project was subcontracted to M.A.P. Mechanical Contractors, Inc. (MAP). MAP installed a steam builder and piping for the heating system. The installation included several expansion joints. After completion, Skanska learned that MAP had installed some of the expansion joints backward. This caused significant damage to concrete, steel and the heating system. The medical center sent a demand letter to Skanska, who send a demand letter to MAP. Skanska did the repairs and replacement of the damaged property. Skanska then submitted a claim of $1.4 million for its work to Amerisure Insurance Company. The claim was denied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Investing in Metaverse Real Estate: Mind the Gap Between Recognized and Realized Potential

May 10, 2022 — Robert G. Howard, David W. Wright & Craig A. de Ridder - Gravel2Gavel Construction & Real Estate Law Blog
The Metaverse is an immersive world combining virtual reality and augmented reality, where users are represented by avatars and roam virtual spaces. It comprises a variety of platforms and environments that can be explored, experienced, and developed. Online social games like Second Life, Fortnite and Minecraft are among the first wave of successful Metaverse games. Now, Meta and Microsoft see the Metaverse as a place to play, live, and work. A JP Morgan white paper stated that opportunities in the Metaverse seem “limitless.” The bank predicted that virtual worlds will “infiltrate every sector in some ways in the coming years.” A March 31 report by Citi concluded that the Metaverse has the potential to become a $13 trillion opportunity by 2030, with total global users of between one and five billion. According to Citi, the Metaverse will become a significant part of the next iteration of the internet (referred to as Web3) enabled by a variety of existing and emerging technologies, including 5G connectivity, secure blockchain and payment platforms, crypto assets, cloud computing, artificial intelligence, 3D modeling tools and headset devices. A Land Rush, Virtually Speaking Not surprisingly, investors are speculating regarding the value and potential of “virtual land” within the Metaverse, where land sales in 2021 exceeded $500 million and attracted a lot of attention and hype. The Sandbox, Decentraland, Somnium Space and CryptoVoxels are the most active platforms and owners can build almost anything on their virtual parcels. The open-source Ethereum blockchain, with self-executing smart contract functionality, operates as the foundational layer for most platforms. Parcels of land in The Sandbox and Decentraland are purchased with cryptocurrencies (called SAND and MANA, respectively) on their platforms and can also be sold and purchased on secondary marketplaces like OpenSea. Reprinted courtesy of Robert G. Howard, Pillsbury, David W. Wright, Pillsbury and Craig A. de Ridder, Pillsbury Mr. Howard may be contacted at robert.howard@pillsburylaw.com Mr. Wright may be contacted at david.w.wright@pillsburylaw.com Mr. Deridder may be contacted at craig.deridder@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Roundup (4/10/24) – Hotels Integrate AI, Baby-Boomers Stay Put, and Insurance Affects Housing Market

May 06, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, DOT’s major grant programs, proptech’s solution to climate change risks, mortgage-locked sellers put their homes on the market, and more!

The U.S. Department of Transportation opened applications for four major grant programs for infrastructure and transportation projects, totaling about $7.5 billion. (Dan Zukowski, Construction Dive)
Hotel brands are integrating AI into their operational processes — such as virtual concierges — and working toward sustainability initiatives that accelerate more environmentally friendly practices industry-wide. (Noelle Mateer, Hotel Dive)
The housing market will soon exit its slowdown, thanks to a growing number of mortgage-locked sellers opting to put their homes on the market, according to JPMorgan Asset Management. (Jennifer Sor, Business Insider)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

MGM Seeks to Demolish Harmon Towers

September 01, 2011 — CDJ STAFF

Citing public safety concerns and the cost of repair, MGM Resorts International is seeking to demolish the unfinished hotel tower. The company has a few hurdles to go through before they start laying the charges to implode the structure. Any plans would have to be approved by not only Clark County officials, but also the district court has an order blocking any activity during litigation between MGM and the general contractor on the project, Perini Building Company.

Architectural Record reports that MGM states it would take “approximately 18 months to conduct test and come up with an approved, permitted design to fix the Harmon.” MGM feels that repairs would then take another two to three years. Perini contends that they could “provide stamped drawings detailing all necessary repairs within three months.” They attribute MGM’s desire to demolish the building as “buyer’s remorse.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

15 Wilke Fleury Lawyers Recognized in 2020 Northern California Super Lawyers and Rising Stars Lists

August 17, 2020 — Wilke Fleury LLP
Wilke Fleury is proud to announce that 15 of our astounding attorneys were featured in the Annual List of Top Attorneys in the 2020 Northern California Super Lawyers magazine. Super Lawyers rates attorneys in each state using a patented selection process; they also publish a yearly magazine issue that regularly produces award-winning features on selected attorneys. Wilke Fleury LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Commercial Construction in the Golden State is Looking Pretty Golden

August 26, 2015 — Garret Murai – California Construction Law Blog
If the $2.1 trillion erased from the U.S. stock market over the last week has you white knuckled, you might consider commercial construction in the Golden State, where things are looking . . . well . . . pretty golden. According to the Summer/Fall 2015 Commercial Real Estate Survey jointly published by Allen Matkins and the UCLA Anderson School of Management, commercial construction in California has risen to its highest level since 2001. The survey, conducted of commercial real estate developers and financiers and their outlook for seven metropolitan regions in California including the East Bay, the Inland Empire, Los Angeles, Orange County, San Diego, San Francisco and Silicon Valley, found that all respondents expressed optimism (characterized as an optimism sentiment above 50) that office, multifamily, industrial and retail construction would grow over the next three-years although it varied depending on the region and sentiment was at times lower than when the survey was last taken last year. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Protect Workers From Falls: A Leading Cause of Death

August 14, 2018 — Mark McGhiey - Construction Executive
One of the leading causes of death for construction workers is falls from elevated surfaces, according to the Bureau of Labor Statistics. In 2016, these accidents accounted for more than 30 percent of all construction fatalities. The top four causes of worker deaths (excluding highway collisions) in the private sector construction industry are:

falls: 384 (38.7%);
struck by object: 93 (9.4 percent);
electrocutions: 82 (8.3 percent); and
caught-in/between:1 72 (7.3 percent).

One of the most common — and costly — causes of claims occur when construction workers fall from elevated surfaces. These accidents represent more than 30 percent of all construction claim payments. Reprinted courtesy of Mark McGhiey, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES