Fairfield Connecticut Building Expert Directory

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Equitable Lien Designed to Prevent Unjust Enrichment

November 09, 2020 — David Adelstein - Florida Construction Legal Updates
There are instances where a party does not have construction lien rights but, nevertheless, feels the need to pursue an equitable lien against the real property. No different than a construction lien, an action to enforce an equitable lien has a one-year limitations period if it arises from the “furnishing of labor, services, or material for the improvement of real property.” Fla. Stat. s. 95.11(5)(b). In other words, an equitable lien–not nearly as powerful as a construction lien because a construction lien is recorded in the official public records whereas an equitable lien is not–is tied to an analogous one-year limitations period for those liening for construction improvements. (Notably, if the equitable lien arises outside of the construction improvement context, the one-year statute of limitations would not apply. See Gabriji, LLC v. Hollywood East, LLC, 45 Fla. L. Weekly D2251a (Fla. 4th DCA 2020) (one-year statute of limitations period does not apply to all equitable liens such as those that do not arise from furnishing labor, services, or material for the improvement of real property)). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Co-Housing Startups Fly in the Face of Old-School NYC Housing Law

December 18, 2022 — Amelia Pollard & Diego Lasarte - Bloomberg
A room in an eight-bedroom Bed-Stuy brownstone with “charming views.” A five-bedroom “modern Manhattan” home. In a housing market as hot as New York City’s, these units advertised on co-housing companies’ websites sound promising. According to the city’s housing regulations, however, neither is legal. That hasn’t stopped companies from offering the rooms, as renters clamor for affordable living space. With the average studio apartment in Manhattan going for nearly $3,100 a month, newcomers to the city often find living with multiple roommates to be their best affordable-housing option. It’s a trend that startups have jumped on, and one some experts endorse as a way to quickly scale up affordable housing — even though municipal housing laws aren’t on board yet. The reality is that in many cities, housing laws that limit the number of unrelated individuals in a dwelling are still in place. New York, for instance, doesn’t allow more than three unrelated people to live in the same unit. To be sure, New Yorkers often break that law, as expensive housing forces people to find roommates through friends or on sites like Craigslist. But multimillion-dollar companies breaking that law is new. Reprinted courtesy of Amelia Pollard, Bloomberg and Diego Lasarte, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Construction and Contract Issues Blamed for Problems at Anchorage Port

August 27, 2013 — CDJ STAFF
A third-party audit of the construction at the Port of Anchorage has found fault with the design provided by the engineers. In response, PND, the engineering firm involved, has claimed that it was not their design, but faulty construction of it that lead to an interruption in the construction project. Separately, the Office of the Inspector General has called into question how MARAD, the agency which oversaw the port construction, handled the planning and contracts for the project. Control of the project has been taken over by the Municipality of Anchorage, and they have called into question PND’s open cell sheet pile design and PND’s design of the dock infrastructure. Simpson, Gumpertz and Heger reviewed the design, comparing it to a design provided by CH2M Hill, and found that the PND design was inadequate. A contract was subsequently awarded to CH2M Hill. Read the court decision
Read the full story...
Reprinted courtesy of

Granting Stay, Federal Court Reviews Construction Defect Coverage in Hawaii

January 06, 2012 — Tred R. Eyerly - Insurance Law Hawaii

The federal district court ultimately stayed a construction defect case, but offered comments on the current status of coverage disputes for such defects in Hawaii. See National Union Fire Ins. Co. of Pittsburgh, Pa. v. Simpson Mfg. Co., 2011 U.S. Dist. LEXIS 128481(D. Haw. Nov. 7, 2011).

National Union filed a complaint for declaratory relief to establish it had no duty to defend or to indemnify Simpson Manufacturing Company in four actions pending in the Hawaii state courts. The state court actions concerned allegedly defective hurricane strap tie hold downs that were manufactured and sold by Simpson. The hurricane ties allegedly began to prematurely corrode and rust, causing cracking, spalling and other damage to homes.

National Union contended the underlying allegations did not constitute "property damage" caused by an "occurrence," as defined in the policies.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

Excess Carrier's Declaratory Judgment Action Stayed While Underlying Case Still Pending

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court determined the excess carrier's declaratory judgment action to establish it had no coverage obligations should be stayed while the underlying case was still pending. Scottsdale Ins. Co. v. Ortiz & Assocs., 2014 U.S. Dist. LEXIS 64286 (D. Ore. May 9, 2014). The subcontractor's employee was killed on the job site when struck by a dump truck owned by the general contractor, Inland Asphalt Co. Island was sued for wrongful death. Island was an additional insured under the subcontractor's primary policy and excess policy with Scottsdale. Inland put Scottsdale on notice of the underlying wrongful death lawsuit, but did not tender its defense to Scottsdale. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

No Coverage For Construction Defects When Complaint Alleges Contractual Damages

September 01, 2011 — Tred R. Eyerly - Insurance Law Hawaii

The underlying plaintiff’s allegations contended the contractor was in breach of contract for construction defects caused in building her home. Accordingly, the court found no coverage.See Nat’l Builders and Contractors Ins. Co. v. Slocum, 2011 U.S. Dist. LEXIS 81694 (S.D. Miss. July 26, 2011).

Slocum Construction LLC sold a home it built to Laura Peterson. Subsequently, Peterson filed suit, alleging a breach of the contract and seeking rescission and cancellation of the contract. Peterson further alleged at least thirty-three specific defects in the construction of the house.

Slocum tendered to its insurer, National Builders and Contractors Insurance Company (NBCI). NBCI filed suit for a declaratory judgment.