Cambridge Massachusetts Building Expert Directory

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

Penalty for Failure to Release Expired Liens

April 02, 2024 — William L. Porter - Porter Law Group
I was recently contacted by a commercial building owner in the process of trying to sell his building. Two years prior to this, a subcontractor had recorded a mechanics’ lien with the local County Recorder’s office in relation to the owner’s property. The subcontractor recorded the mechanics lien after the subcontractor was not paid by a prime contractor for work the subcontractor had performed on the property. Unfortunately, the subcontractor then failed to file a lawsuit to foreclose on the lien within the requisite ninety (90) day time period for filing a lawsuit to foreclose on the mechanics’ lien. Since the subcontractor missed this 90 day deadline to file the mechanics lien foreclosure lawsuit, the mechanics lien expired and became unenforceable. Subject to certain exceptions, under California Civil Code Section 8460, a lawsuit to foreclose on a mechanics lien must be filed within ninety (90) days after the mechanics lien is recorded or the mechanics lien expires. Although the mechanics lien had expired, the title company and intended purchaser of the building and property were perhaps understandably insistent that the mechanics lien constituted a cloud on title to the property and must be removed from the official records for the property. The prospective purchaser would not buy the property unless the mechanics’ lien was removed. Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

Timely and Properly Assert Affirmative Defenses and Understand Statutory Conditions Precedent

August 05, 2024 — David Adelstein - Florida Construction Legal Updates
A recent case serves as a reminder to TIMELY and PROPERLY assert affirmative defenses and to understand statutory conditions precedent to construction lien claims. Failing to do one or the other could be severely detrimental to the position you want to take in a dispute, whether it is a lien foreclosure dispute, or any other dispute. In Scherf v. Tom Krips Construction, Inc., 2024 WL 3297592 (Fla. 4th DCA 2024), the president of a construction company and his wife were building a residence. They orally accepted the proposal from the concrete shell contractor and asked for invoices to be submitted to the president’s construction company. No written contract was memorialized. The president and his wife did not pay the concrete shell contractor and the contractor recorded a lien and sued to foreclose on the lien. Years later (the case had been stayed because the president and his wife filed for bankruptcy and the shell contractor had to get leave of the automatic bankruptcy stay to pursue the lien foreclosure), the shell contractor moved for summary judgment. The president and his wife moved for leave to file an amended answer and affirmative defenses. They claimed the oral contract was with the construction company and the shell contractor was required to serve a Notice to Owner under Florida Statute s. 713.06. Alternatively, they argued that if the oral contract was with the president and his wife, the shell contractor was required to serve a Final Contractor’s Payment Affidavit at least 5 days before filing its lien foreclosure claim, and did not, as required by s. 713.06. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Chimney Collapses at South African Utility’s Unfinished $13 Billion Power Plant

November 21, 2022 — Paul Burkhardt - Bloomberg
South Africa’s newest coal-fired power plant, which has been under construction since 2008 and will cost an estimated 232 billion rand ($12.7 billion), shut one of its six generating units after a duct collapsed. The unit at the Kusile plant could remain offline “for a few months” although a clearer estimate will be known over coming weeks, state-owned utility Eskom Holdings SOC Ltd. said in a statement late Wednesday. The outage comes as the country endures record blackouts -- locally known as loadshedding. The duct appeared to have sheared off from the unit’s main structure, a photo posted on Twitter by Anton Eberhard, a professor at the University of Cape Town’s Graduate School of Business, showed. Read the court decision
Read the full story...
Reprinted courtesy of Paul Burkhardt, Bloomberg

Daiwa House to Invest 150 Billion Yen in U.S. Rental Housing

March 07, 2014 — Kathleen Chu – Bloomberg
Daiwa House Industry Co. (1925), Japan’s biggest homebuilder by market value, plans to invest 150 billion yen ($1.48 billion) in U.S. rental housing, three times more than it had aimed to allocate to overseas investments, to boost revenue. Daiwa House will acquire and develop leasing properties in Texas and allocate the funds over the next three years, the Osaka-based company said in an e-mailed statement today. The homebuilder targets 50 billion yen of revenue in the U.S. by the year ending March 2019, it said. Japan’s shrinking population has prompted the country’s homebuilders such as Daiwa House to seek new revenue sources. Texas is the most that Daiwa House is investing overseas for rental housing and compares with the 50 billion yen the company had announced for investments abroad in its mid-term plan in November. Read the court decision
Read the full story...
Reprinted courtesy of Kathleen Chu, Bloomberg
Ms. Chu may be contacted at kchu2@bloomberg.net

Request for Stay Denied in Dispute Over Coverage for Volcano Damage

August 10, 2020 — Tred R. Eyerly - Insurance Law Hawaii
Although there were concurrent state and federal proceedings regarding the insureds' claims for damage caused by Kilauea Volcano, the federal district court refused to dismiss or stay the federal action. Aqulina v Certain Underwriters at Lloyd's Syndicate #2003, 2020 U.S. District Ct. LEXIS 101832 (D. Haw. June 10, 2020). Plaintiffs held homeowner's policies from Lloyd's that were brokered and underwritten by various defendants. Coverage from the May 2018 eruption of Kilauea Volcano was denied based upon an exclusion precluding coverage for lava-related damage. Plaintiffs sued Lloyds and various brokers in federal court, alleging that defendants had engaged in a deceptive scheme to defraud plaintiffs and deprive them of meaningful coverage. Lawsuits were also filed in state court, with plaintiffs arguing their losses were covered by their policies and that defendants wrongfully relied solely on the lava exclusion to deny claims. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Contract’s Definition of “Substantial Completion” Does Not Apply to Third Party for Purposes of SOL, Holds Court of Appeal

June 15, 2020 — Garret Murai - California Construction Law Blog
Those of you in the construction industry know that the two primary statutes of limitation are the 4-year year statute of limitations for patent defects and 10-year statute of limitations for latent defects. Both statutes begin to run on “substantial completion.” In Hensel Phelps Construction Co. v. Superior Court of San Diego, Case No. D076264 (January 22, 2020), the 4th District Court of Appeal examined whether the term “substantial completion,” as used in Civil Code section 941, which applies to residential construction, can be defined by the parties’ contract and applied to third-parties. The Hensel Phelps Case Hensel Phelps Construction Co. entered into a prime construction contract with the owner and developer of a mixed-use project in San Diego. Hensel Phelps was the general contractor on the project. The project included a residential condominium tower which would eventually be managed and maintained by Smart Corner Owners Association. Smart Corners was not a party to the contract. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Affordable Global Housing Will Cost $11 Trillion

October 08, 2014 — Flavia Krause-Jackson – Bloomberg
Replacing the world’s substandard housing and building affordable alternatives to meet future global demand would cost as much as $11 trillion, according to initial findings in a McKinsey & Co. report. The shortage of decent accommodation means as many as 1.6 billion people from London to Shanghai may be forced to choose between shelter or necessities such as health care, food and education, data disclosed at the 2014 CityLab Conference in Los Angeles show. McKinsey will release the full report in October. The global consulting company says governments should release parcels of land at below-market prices, put housing developments near transportation and unlock idle property hoarded by speculators and investors. The report noted that China fines owners 20 percent of the land price if property is undeveloped after a year and has the right to subsequently confiscate it. Read the court decision
Read the full story...
Reprinted courtesy of Flavia Krause-Jackson, Bloomberg
Ms. Krause-Jackson may be contacted at fjackson@bloomberg.net

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES