Fairfield Connecticut Building Expert Directory

Natural Disasters’ Impact on Construction in the United States

December 14, 2020 — Robert S. Peckar & Crystal T. Dang - Construction Executive
In these times of easy and instant access to news from around the globe, the effects of major earthquakes in Indonesia and Mexico, cyclones in Southeast Asia, Tsunamis around the world, volcanoes in Europe in unexpected places and, of course, raging forest fires and hurricanes in the United States are frequently in the news. Accompanying each of these disasters are immediate threats to construction projects, both physical and those affecting the safety and health of personnel. However, after the dust settles or the waters recede, myriad issues will become obstacles to the road to recovery for a contractor to navigate. In 2020 alone, the volume of strong storms and forest fires have focused so much attention on the impact of disasters. The purpose of this article is to provide guidelines in anticipation of disasters, for reviewing the impact of a disaster as it is happening, and developing a mitigation plan to limit losses. Anticipating Disasters The best time to prepare for a disaster on a project is before the project starts. Reviewing contract rights, insurance policies and company disaster response protocols while a category 3 hurricane is a day away is not a best practice. To avoid falling into that situation, a contractor should follow the following guidelines. Doing so facilitates proper action during the actual disaster itself and in the aftermath. Reprinted courtesy of Robert S. Peckar & Crystal T. Dang, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Peckar may be contacted at rpeckar@pecklaw.com Ms. Dang may be contacted at cdang@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

The Roads to Justice: Building New Bridges

August 23, 2021 — Aileen Cho - Engineering News-Record
Former U.S. Dept. of Transportation Secretary Anthony Foxx grew up on “the wrong side of the tracks.” “My home was a stone’s throw from Interstates 85 and 77,” recalls Foxx, who grew up in Charlotte, N.C., and served as DOT Secretary from 2013-17 under President Barack Obama. “The airport was nearby. Planes flew at low altitude over our house. Whether or not I was using the system, I sure heard and saw a lot of it.” Desirable areas to live were far away from transportation infrastructure, “and the property values of those living near these projects was diminished.” Reprinted courtesy of Aileen Cho, Engineering News-Record Ms. Cho may be contacted at choa@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Sureties do not Issue Bonds Risk-Free to the Bond-Principal

August 30, 2017 — David Adelstein - Florida Construction Legal Updates
If your construction company is bonded, then you have signed a General Agreement of Indemnity with your surety / bonding company. Stated another way, if a surety issued an obligee on behalf of your construction company, as the bond-principal, a payment or performance bond, then you have signed a General Agreement of Indemnity with your surety. The General Agreement of Indemnity is NOT to be taken lightly. Without the General Agreement of Indemnity, the surety is NOT issuing the bonds you need to work on a certain project. A bond is not insurance and sureties do not issue the bonds under a risk-free premise. Oh no! If a surety has to pay-out claims under a bond, the surety will be looking to recoup that loss from the indemnitors that executed the General Agreement of Indemnity. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Think Before you Execute that Release – the Language in the Release Matters!

June 17, 2024 — David Adelstein - Florida Construction Legal Updates
If you execute a release in exchange for payment or other consideration, remember the language in the release means something. THE RELEASE LANGUAGE MATTERS! And the meaning in the release may be way more than you intended so please make sure you truly digest and consider release language before executing. This sentiment could not be truer than in the 2009 decision Bell BCI Company v. United States, 570 F.3d 1337 (Fed. Cir. 2009). In this case, a contractor entered into a modification (change order) with the government. The modification included the following language: increase the contract amount by $2,296,963 … as full and equitable adjustment for the remaining direct and indirect costs of the Floor 4 Fit-out (EWO 240–R1) and full and equitable adjustment for all delays resulting from any and all Government changes transmitted to the Contractor on or before August 31, 2000. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Traub Lieberman Partner Lisa Rolle Obtains Summary Judgment in Favor of Defendant

November 15, 2022 — Lisa M. Rolle - Traub Lieberman
Traub Lieberman Partner Lisa M. Rolle obtained summary judgment in favor of defendant SRI Fire Sprinkler, LLC, a family-owned and operated fire sprinkler company which generally provides fire sprinkler installation, inspection, and maintenance services throughout the Northeast and New England. The judgment was determined pursuant to CPLR 3211(a)(5) on the grounds that Philadelphia Indemnity Insurance Company’s (Plaintiff) negligent construction claim accrued on the date when work was completed at the premises, not on the date of the incident as alleged in the Plaintiff’s complaint. In the underlying subrogation action, the Plaintiff commenced the action in subrogation of its insured, Bet Am Shalom Synagogue (Bet Am), to recover damages in excess of $173,390.86 which it allegedly paid to Bet Am for water damage cleanup and remodeling after certain sprinkler pipes froze and burst in the recently constructed wing of the Westchester synagogue on January 1, 2019 and January 7, 2019. The Plaintiff alleged that its subrogor, Bet Am, sustained interior water damage on the first floor and basement levels of the premises, including the carpets, drywall, insulation, bathroom, kitchen and appliances, dining room, hallways, closets, basement storage rooms and supplies, and basement classrooms. Read the court decision
Read the full story...
Reprinted courtesy of Lisa M. Rolle, Traub Lieberman
Ms. Rolle may be contacted at lrolle@tlsslaw.com

Nomos LLP Partner Garret Murai Recognized by Best Lawyers®

September 18, 2023 — Garret Murai - California Construction Law Blog
Nomos LLP Partner Garret Murai has been recognized by Best Lawyers® in its 30th edition of The Best Lawyers in America® in the area of Construction Law for 2024. This is the the first year Garret has been recognized by Best Lawyers®. Reprinted courtesy of Garret Murai, Nomos LLP Mr. Murai may be contacted at gmurai@nomosllp.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

What to Do Before OSHA Comes Knocking

December 19, 2018 — Parker Rains - Construction Executive
Every year, the U.S. Occupational Safety and Health Administration (OSHA) inspects workplaces around the country for safety and occupational hazards. In 2017 alone, OSHA conducted 32,408 inspections – more than half of which were unprogrammed inspections. There are six reasons OSHA might come knocking on the door. They are (in order of priority):

imminent danger situations;
severe injuries and illnesses;
worker complaints;
referrals;
targeted inspections; and
follow-up inspections.

Reprinted courtesy of Parker Rains, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Rains may be contacted at prains@fbbins.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES