Fairfield Connecticut Building Expert Directory

BofA Said to Near Mortgage Deal for Up to $17 Billion

August 06, 2014 — Tom Schoenberg – Bloomberg
Bank of America Corp. is nearing a $16 billion to $17 billion settlement with the U.S. Justice Department to resolve probes into sales of mortgage-backed bonds in the run-up to the financial crisis, a person familiar with the matter said. Under the proposed terms, the bank would pay about $9 billion in cash and the rest in consumer relief to settle federal and state claims, according to the person, who asked not to be named because the negotiations are private. Details of the proposed accord, such as the relief and a statement of facts, are still being negotiated, the person said. The outlines of the deal were reached last week after a phone call between Attorney General Eric Holder and Bank of America Chief Executive Officer Brian T. Moynihan, the person said. During the July 30 call, Holder said that the government was ready to file a lawsuit in New Jersey if the bank didn’t offer an amount closer to the department’s demand of about $17 billion, according to the person. Read the court decision
Read the full story...
Reprinted courtesy of Tom Schoenberg, Bloomberg
Mr. Schoenberg may be contacted at tschoenberg@bloomberg.net

The Future of Construction Work with Mark Ehrlich

February 19, 2024 — Aarni Heiskanen - AEC Business
In this episode of the AEC Business podcast, I had the pleasure of speaking with Mark Ehrlich, a veteran of the construction industry from the USA and the author of “The Way We Build: Restoring Dignity to Construction Work.” Our conversation delved into the evolving landscape of construction work and the challenges faced by construction workers today. Mark shared his extensive background, starting as a carpenter and rising through the ranks to become the head of a 25,000-member union organization. His experience spans decades, and he has authored three books and numerous articles on labor issues. The historical labor shifts We discussed the historical shift from a predominantly unionized construction workforce to the current bifurcated system in the US, where union strongholds in the north contrast sharply with the non-union, lower-wage environments in the south and other regions. Mark highlighted the issues of wage theft, declining safety standards, and the exploitation of undocumented workers. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Retroactive Application of a Construction Subcontract Containing a Merger Clause? Florida’s Fifth District Court of Appeal Answers in the Affirmative

September 07, 2017 — Sanjo S. Shatley - Florida Construction Law News
Florida’s Fifth District Court of Appeal recently addressed the issue of retroactive application of a construction subcontract on the basis of a merger clause in Don Facciobene, Inc. v. Hough Roofing, Inc.[1] In the case, in late 2010, Don Facciobene, Inc. (“DFI”), a licensed general contractor, contracted with Digiacinto Holdings, LLC, an owner of a home built in 1905 in Melbourne, Florida, known as the Nannie Lee House or the Strawberry Mansion, to perform various renovations in preparation for a restaurant to be opened on the premises. One of the renovations included a new roof. DFI subcontracted the roofing work to Hough Roofing, Inc. (“HRI”), a licensed roofing subcontractor. In mid-March 2011, HRI submitted an estimate and proposed statement of work to DFI. DFI’s project manager signed HRI’s proposal on April 5, 2011, as well as an additional expanded proposal six days later. According to the proposals, payment was due on completion. HRI began work on the roof on April 15, 2011, without a signed subcontract. However, DFI and HRI ultimately executed a subcontract on June 8, 2011, even though HRI had mostly finished its work by the end of May. Read the court decision
Read the full story...
Reprinted courtesy of Sanjo S. Shatley, Cole, Scott & Kissane, P.A.
Mr. Shatley may be contacted at sanjo.shatley@csklegal.com

Jason Poore Receives 2018 Joseph H. Foster Young Lawyer Award

July 21, 2018 — Jason Poore - White and Williams LLP
Jason Poore, an associate in the General Litigation Group, recently received the 2018 Joseph H. Foster Young Lawyer Award during the Philadelphia Association of Defense Counsel’s annual meeting. The Joseph H. Foster Young Lawyer Award honors “a young lawyer who best exemplifies the qualities of professionalism and dedication as defense counsel in the practice of law and in the promotion of the highest ideals of justice in the community." Jason continues to make significant contributions to the local bar and community. In addition to serving on the Executive Committee of the Philadelphia Bar Association Young Lawyers Division, he is the creator and Chair of the PBA's Youth Courts Committee. Read the court decision
Read the full story...
Reprinted courtesy of Jason Poore, White and Williams LLP
Mr. Poore may be contacted at poorej@whiteandwilliams.com

Contractors: A Lesson on Being Friendly

April 06, 2016 — Garret Murai – California Construction Law Blog
I know. You’re just trying to be friendly. Don’t. Particularly when you’re a contractor bidding on a public works project. Those dinners at swanky restaurants, tickets to The Jersey Boys, and all expense paid trips to the Napa Valley have a way of appearing less “friendly” in hindsight, and more like bribery, or as they say, “pay to play.” In Sweetwater Union High School District v. Gilbane Building Company, California Court of Appeals for the Fourth District, Case No. D067383 (February 24, 2016), three contractors, Gilbane Building Company (“Gilbane”), The Seville Group, Inc. (“Seville”) and Gilbane/SGI Joint Venture (“Gilbane/SGI”) (collectively “Contractors”) were sued by the Sweetwater Union School District (“District”) to void their contracts with the District and for disgorgement of all monies paid to them under Government Code section 1090 after it was discovered that the Contractors had engaged in a “pay to play” scheme involving several officials of the District. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Is the Event You Are Claiming as Unforeseeable Delay Really Unforeseeable?

September 26, 2022 — David Adelstein - Florida Construction Legal Updates
Is the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question. Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair. For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Recent Supreme Court Decision Could Have Substantial Impact on Builders

January 23, 2023 — Cassidy Ingram - Ahlers Cressman & Sleight
On October 27, 2022, the Washington State Supreme Court issued a decision which could have a substantial impact on the enforceability of contract clauses that require litigation to be commenced within a stated period of time from project completion. In Tadych v. Noble Ridge Construction, Inc.,the Supreme Court held that the contractual one-year statute of limitations for bringing claims against the contractor was substantively unconscionable and reversed the Court of Appeals. In Tadych, plaintiff owners (the Tadychs) contracted with defendant contractor (Noble Ridge Construction, Inc., or NRC) for the construction of a custom home in 2012. The contract included a one-year claim limitations clause that required claims to be raised within a one year period from project completion and that any claims not raised during the one-year period would be waived. In December 2013, as the project neared completion, the Tadychs met with NRC to identify any outstanding project issues. The Tadychs noted several, including rainwater pools at the landing at the bottom of the stairs and several nicks and cracks on the stucco exterior walls. The Tadychs moved into the home on April 8, 2014, and the City of Seattle Department of Planning and Development conducted its final site inspection on April 15 and approved the residence for occupancy on April 23. In January or February of 2015, the Tadychs began to notice a shift in their home. In February of 2015, the Tadychs engaged the Construction Dispute Resolution (CDR) to review NRC’s work. CDR raised concerns about the adequacy of the home’s construction and prepared a written report in March 2015 indicating several deviations from the architectural plans and building codes. The Tadychs sent this report to NRC, who assured the Tadychs that NRC’s work followed all requirements and rejected any claims that there were deviations from the plans. The Tadychs continued to notice issues with the home through October 2016. Read the court decision
Read the full story...
Reprinted courtesy of Cassidy Ingram, Ahlers Cressman & Sleight
Ms. Ingram may be contacted at cassidy.ingram@acslawyers.com

Fundamental Fairness Trumps Contract Language

September 24, 2014 — Craig Martin – Construction Contractor Advisor
The Texas Supreme Court recently ruled that a “no-damages-for-delay” clause would not be enforced where the delay was caused by the owner. The court’s ruling flies squarely in the face of the contract language that attempted to insulate the owner from any delay claims, even those it caused. In the case of Zachary Construction v. Port of Houston underlying contract, proposed by the Port of Houston, was heavy handed, to say the least. The contract provided: “[Contractor] shall receive no financial compensation for delay or hindrance to the Work. In no event shall the Port Authority be liable to [Contractor] … for any damages arising out of or associated with any delay or hindrance to the Work, regardless of the source of the delay or hindrance, including events of Force Majeure, AND EVEN IF SUCH DELAY OR HINDRANCE RESULTS FROM, ARISES OUT OF OR IS DUE IN WHOLE OR IN PART, TO THE NEGLIGENCE, BREACH OF CONTRACT OR OTHER FAULT OF THE PORT AUTHORITY. [Contractor’s] sole remedy in any such case shall be an extension of time.” Wow, that’s some one-sided language. If the contract was enforced, the contractor could not get any damages for delay, even those damages caused by the active interference of the Port of Houston. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES