Minnesota Addresses How Its Construction Statute of Repose Applies to Condominiums
April 27, 2020 —
William L. Doerler - The Subrogation StrategistCourts often struggle with the question of when the statute of repose starts to run for construction projects that involve multiple buildings or phases. In Village Lofts at St. Anthony Falls Ass’n v. Housing Partners III-Lofts, LLC, 937 N.W.2d 430 (Minn. 2020) (Village Lofts), the Supreme Court of Minnesota addressed how Minnesota’s 10-year statute of repose, Minn. Stat. § 541.051, applies to claims arising from the construction of a condominium complex. The court held that the statute of repose begins to run at different times for: a) statutory residential warranty claims brought pursuant to Minn. Stat. §§ 327A.01 to 327A.08, et. seq.; and b) common law claims arising out of the defective and unsafe condition of the condominium buildings.
As stated in Village Lofts, Housing Partners III-Lofts, LLC (Housing Partners) developed the Village Lofts at St. Anthony Falls, a condominium complex consisting of Building A and Building B. Housing Partners retained Kraus-Anderson Construction Company (Kraus-Anderson) as the general contractor for Building A. Kraus-Anderson retained Elness Sweeney Graham Architects, Inc. (ESG), Doody Mechanical, Inc. (Doody) and Kenneth S. Kendle, P.E. (Kendle) to work on Building A. In September 2002, the City of Minneapolis (City) issued a partial certificate of occupancy (CO) for Building A, including the building’s public spaces. On October 4, 2002, Housing Partners filed the declaration creating the Village Lofts at St. Anthony Falls condominium, to be operated by Village Lofts at St. Anthony Association (Village Lofts Association). On October 10, 2002, Housing Partners sold the first unit in Building A and in November of 2003, the City issued a CO for the entire building, excluding two units.
Read the court decisionRead the full story...Reprinted courtesy of
William L. Doerler, White and Williams LLPMr. Doerler may be contacted at
doerlerw@whiteandwilliams.com
Green Home Predictions That Are Best Poised to Come True in 2014 and Beyond (guest post)
July 16, 2014 —
Melissa Dewey Brumback – Construction Law in North CarolinaToday, a guest post on the green design issues that are becoming realities from Penny Olmos, who is associated with Holloway Houston, Inc. a leading industrial lifting equipment manufacturing company. Welcome, Penny!
The scorching heat singed us and the winter wave chilled us — more than ever before. What are we heading to? Earthquakes, volcanoes, tsunamis, tornadoes and extreme temperatures? Mother Nature is warning us in myriad ways. And the good news is that we are heeding her calls after long. Saving our natural resources and going green has found many takers. We have seen many eco-friendly homes and buildings designed and created in the last decade. Green homes are here to stay. We look at the popular green home design and construction trends in 2014 that are about to transform the landscape of green realty.
Rise of Net Zero Energy Homes
It seemed impossible until a couple of years ago but 2014 will witness a rise in net zero energy homes. These are homes with zero net energy consumption. The total amount of energy used by these buildings annually equals the amount of renewable energy created on the property. This is the greenest and the most energy efficient house you can possess. And you do not need to cut down on any of your comforts. There are heating, cooling, entertainment and utility appliances functioning in the house like they would in any other home.
Read the court decisionRead the full story...Reprinted courtesy of
Melissa Dewey Brumback, Construction Law in North CarolinaMs. Brumback may be contacted at
mbrumback@rl-law.com
Standard of Care
December 16, 2019 —
Jay Gregory - Gordon & Rees Construction Law BlogOne of the key concepts at the heart of Board complaints and civil claims against a design professional is whether or not that design professional complied with the applicable standard of care. In order to prevail on such a claim, the claimant must establish (typically with the aid of expert testimony) that the design professional deviated from the standard of care. On the other side of the coin, to defend a design professional against a professional malpractice claim, defense counsel attempts to establish that – contrary to the claimant’s allegations – the design professional, in fact, complied with the standard of care. Obviously, it becomes very important in such a claim situation to determine what the standard of care is that applies to the conduct of the defendant design professional. Often, this is easier said than done. There is no dictionary definition or handy guidebook that identifies the precise standard of care that applies in any given situation. The “standard of care” is a concept and, as such, is flexible and open to interpretation. Traditionally, the standard of care is expressed as being that level of service or competence generally employed by average or prudent practitioners under the same or similar circumstances at the same time and in the same locale. In other words, to meet the standard of care a design professional must generally follow the pack; he or she need not be perfect, exemplary, outstanding, or even superior – it is sufficient merely for the designer to do that which a reasonably prudent practitioner would do under similar circumstances. The negative or reverse definition also applies, to meet the standard of care, a practitioner must refrain from doing what a reasonably prudent practitioner would have refrained from doing.
Although we have this ready definition of the standard of care, in any given dispute it is practically inevitable that the parties will have markedly different opinions as to: (1) what the standard of care required of the designer; and (2) whether the defendant design professional complied with that requirement. The claimant bringing a claim against a design professional typically will be able to find an expert reasonably qualified (at least on paper) who will offer an opinion that the defendant failed to comply with the standard of care. It is just as likely that the counsel for the defendant design professional will be able to find his or her own expert who will counter the opinion of the claimant’s expert and maintain that the defendant design professional, in fact, complied with the standard of care. What’s a jury to think?
The concept of standard of care is intertwined with the legal concept of negligence. In the vast majority of law suits against design professionals, a claimant (known as the plaintiff) will assert a claim for negligence against the design professional now known as the defendant.1 As every first year law student learns while studying the field of “Torts,” negligence has four subparts. In order for a defendant to be found negligent, the claimant must establish four elements: (1) duty; (2) breach; (3) causation; and (4) damages. In other words, to establish a claim against a defendant design professional, a plaintiff must demonstrate that the defendant owed the plaintiff a duty of care but breached that duty and, as a result, caused the plaintiff to suffer damages.
Read the court decisionRead the full story...Reprinted courtesy of
Jay Gregory, Gordon & Rees Scully MansukhaniMr. Gregory may be contacted at
jgregory@grsm.com
Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor
September 09, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project.
In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Miller Act Payment Bond Surety Bound to Arbitration Award
December 29, 2020 —
David Adelstein - Florida Construction Legal UpdatesHere is an interesting case binding a Miller Act payment bond surety to an arbitration award against its prime contractor (bond principal) that it received sufficient notice of. Notice is the operative word. The surety could have participated in the arbitration, elected not to, and when its prime contractor (bond principal) lost the arbitration, it was NOT given another bite out of the apple to litigate facts already been decided.
In BRC Uluslararasi Taahut VE Ticaret A.S. v. Lexon Ins. Co., 2020 WL 6801933 (D. Maryland 2020), a prime contractor was hired by the federal government to make security upgrades and interior renovations to a United States embassy in the Czech Republic. The prime contractor hired a subcontractor to perform all of the installed contract work. The prime contractor terminated the subcontractor for default during the course of construction.
The subcontractor demanded arbitration in accordance with the subcontract claiming it was wrongfully terminated. The subcontractor also filed a lawsuit asserting a Miller Act payment bond claim against the prime contractor’s surety (as well as a breach of contract action against the prime contractor). The subcontractor made clear it intended to pursue its claims in arbitration and hold the payment bond surety jointly and severally liable. The parties agreed to stay the lawsuit since the facts were identical to those being arbitrated. The arbitration went forward and an award was entered in favor of the subcontractor and against the prime contractor for approximately $2.3 Million.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Traub Lieberman Partner Lisa Rolle Wins Summary Judgment on Behalf of Contract Utility Company in Personal Injury Action
April 25, 2023 —
Lisa M. Rolle - Traub LiebermanTraub Lieberman Partner Lisa Rolle obtained summary judgment on behalf of a contract utility company (“Utility Company”) in a matter brought before the New York Supreme Court, Queens County. In the complaint, the Plaintiff alleged that she sustained injuries as a result of a trip and fall accident where the Plaintiff’s foot allegedly went into a hole in the grass strip abutting the sidewalk adjacent to a premises located in Queens, NY. The Plaintiff claimed that the defect in the sidewalk was caused by the removal of a utility pole at the curb strip that was not correctly backfilled.
The Defendant Utility Company is in the business of inspecting, treating, and repairing utility and telecommunication structures, including wooden utility poles. TLSS was successfully able to establish that, three years prior to the accident, the Utility Company was retained to conduct a visual inspection of the subject pole. However, the Utility Company does not and has not owned, installed, removed or replaced in-service utility poles in New York or at the location of the alleged accident. Further, TLSS established that the Utility Company did not service or remove the subject pole at the accident site or backfill the curb strip.
Read the court decisionRead the full story...Reprinted courtesy of
Lisa M. Rolle, Traub LiebermanMs. Rolle may be contacted at
lrolle@tlsslaw.com
Receiving a $0 Verdict and Still Being Deemed the Prevailing Party for Purposes of Attorney’s Fees
May 24, 2018 —
David Adelstein - Florida Construction Legal UpdatesLow and behold, a party can be the prevailing party for purposes of attorney’s fees even if that party is awarded $0. That’s right, even if the party is awarded a big fat zero, they can still be the prevailing party for purposes of being entitled to attorney’s fees. This is because a party is the prevailing party if they prevail on the significant issues in the case. A party can prevail on the significant issues even if that party is awarded $0. Whoa!
For example, in Coconut Key Homeowner’s Association, Inc. v. Gonzalez, 43 Fla.L.Weekly D1045a (Fla. 4th DCA 2018), a homeowner sued her homeowner’s association claiming the association breached its governing documents. There was a basis for fees under Florida’s homeowner’s association law (and there likely was a basis under the governing documents). At trial, the jury held that the association breached its governing documents, but awarded the homeowner nothing ($0). The trial court also issued injunctive relief in favor of the homeowner. The homeowner claimed she should be deemed the prevailing party for purposes of attorney’s fees; however, this was denied by the trial court based on the $0 verdict and no fees were awarded to the homeowner.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
dadelstein@gmail.com
A Primer on Suspension and Debarment for Federal Construction Projects
August 10, 2020 —
Hal J. Perloff - Construction ExecutiveWe’ve all heard the expression that those who deal with the government must turn square corners. This is because the government has a broad array of tools at its disposal to motivate, coax and cajole contractors and federal grant recipients to play by the rules. Those tools include harsh measures such as criminal prosecution and civil false claims act enforcement on the one hand and poor CPARS ratings on the other. A seemingly less severe administrative option available to the government is suspension and debarment. However, any entity that has been suspended or debarred knows that these measures can prove harsh and disruptive.
While the numbers of suspensions and debarments have declined from the all-time high in 2011, there is still significant activity. In its FY 2018 report, the Interagency Suspension and Debarment Committee reported 2444 referrals, 480 suspensions, 1542 proposed debarments and 1334 debarments. The number of referrals for suspension and debarment in FY 2018 is almost exactly the same as the number of GAO bid protests filed that year.
WHAT IS SUSPENSION AND DEBARMENT?
Suspension and debarment are the government’s tools to avoid entities it views as a high risk for poor performance, fraud, waste and abuse. Suspension and debarment preclude a business entity or individual from contracting with the government or from receiving grants, loans, loan guarantees or other forms of assistance from the government. A suspension is a temporary exclusion when the government determines immediate action is necessary pending the completion of an investigation or legal proceeding. A debarment is an exclusion for a defined, reasonable period of time—often three years.
Reprinted courtesy of
Hal J. Perloff, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Perloff may be contacted at
hal.perloff@huschblackwell.com
