Fairfield Connecticut Building Expert Directory

Arizona – New Discovery Rules

May 16, 2018 — John Belanger - Bremer Whyte Brown & O'Meara LLP
Effective July 1, 2018 New Rules of Civil Procedure are taking effect in Arizona on July 1, 2018. The new Rules will change how discovery works in civil litigation in the state. Here is a sneak peek at the changes that will impact your file handling the most: Tiered Discovery

How much discovery is allowed in a case will now depend on the amount and type of relief sought
Cases will be assigned to one of three tiers
Parties can agree on a tier assignment, the court can assign a tier, or a tier can be assigned based on the amount of damages, or a combination of monetary and non-monetary damages

Read the court decision
Read the full story...
Reprinted courtesy of John Belanger, Bremer Whyte Brown & O'Meara LLP
Mr. Belanger may be contacted at jbelanger@bremerwhyte.com

COVID-19 Damages and Time Recovery: Contract Checklist and Analysis

April 27, 2020 — Patrick J. Greene, Jr. - Peckar & Abramson
This Alert explores the contract provisions and related rights that are likely to govern time and compensation adjustments for COVID-19 impacts. As parties begin analyzing such rights, this is intended to serve as a useful guide and checklist. Analysis of relevant contract provisions should start with careful consideration of the specific impacts that have been experienced and the causes of those impacts. The nature of the impact (delay, extra work, disruption, etc.) and the causes of such impacts (owner direction, government order, etc.) will generally govern the analysis and resulting course of action. Listing or creating a matrix of impacts and their causes may be an effective working tool. Essentially, there are five primary impacts that will likely require critical analysis under the relevant contract provisions, and notably, more than one impact may be present: a) complete or partial suspension of work, b) additional work or requirements, c) added cost, d) delay, and e) disruption. Read the court decision
Read the full story...
Reprinted courtesy of Patrick J. Greene, Jr., Peckar & Abramson
Mr. Greene may be contacted at pgreene@pecklaw.com

New Jersey Senate Advances Bad Faith Legislation

July 18, 2018 — TLSS Insurance Law Blog
New Jersey is the latest to join the list of states that have enacted or are considering enacting legislation that would authorize policyholders to file civil suits against first-party insurers for unfair business practices, such as unreasonably delaying or denying benefit payments, engaging in false advertising, or otherwise committing a wide range of unfair or deceptive practices. On June 7, the New Jersey Senate passed a bill entitled the New Jersey Insurance Fair Conduct Act. The Act would create a new statutory cause of action pursuant to which a first-party insurer would be liable for bad faith based on a single statutory violation, thereby entitling an aggrieved policyholder to collect triple damages and attorneys’ fees. The proposed legislation is now before the state’s General Assembly for further consideration. Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman Straus & Shrewsberry LLP

Hurricane Ian: Florida Expedites Road Work as Damage Comes Into Focus

October 10, 2022 — Derek Lacey - Engineering News-Record
Hurricane Ian’s devastation is coming into view days after the storm decimated southwest Florida. Work is underway to rebuild much of the state’s electrical, transportation and other infrastructure, with certain emergency road repairs expedited and restoration of power prioritized after the storm's devastation left millions in the dark and washed out roadways serving as the only access to barrier islands such as Sanibel Island and Pine Island. Reprinted courtesy of Derek Lacey, Engineering News-Record Mr. Lacey may be contacted at laceyd@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Illinois Town Sues over Construction Defects at Police Station

October 08, 2013 — CDJ STAFF
The Chicago suburb of Northlake has filed a lawsuit against the designers and builders of its police station, claiming that the building leaks due to design and construction flaws. The building was finished in 2009 and flooded in 2010, 2011, and 2013. Northlake mayor Jeffrey Sherwin said that “a building that’s flooded three times in three years is kind of extreme.” In addition to requiring the replacement of carpet and drywall, the flooding disrupted police service and damaged both police and personal property. Mr. Sherwin noted that the city has tried to settle with the architects and contractors, but no settlement had been Read the court decision
Read the full story...
Reprinted courtesy of

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

How to Mitigate Lien Release Bond Premiums with Disappearing Lien Claimants

May 20, 2019 — Scott MacDonald - Ahlers Cressman & Sleight PLLC
It is one of those dreaded business situations that plagues the construction industry, especially in times of economic downturn—what to do when a lower-tier entity files a lien against a property then disappears. It has happened to countless owners, general contractors, subcontractors, and even some particularly unlucky sub-tier subcontractors and suppliers. Here is how it arises: a project is moving along, then performance or payment issues arise, and a company that is over extended or unwilling to continue work stops performance, walks off the job, and files a lien against the property for whatever amounts were allegedly unpaid. Often, the allegedly unpaid sums were legitimately withheld due to a good faith dispute over payment/performance, and it is not unusual for the defaulting entity to not be entitled to any of the sums claimed in the lien. Regardless, the lien stays on the property, and pressure is applied from the “upstream” entities to the party who contracted with the defaulting entity to “deal” with the lien. Oftentimes, a contract will require the parties to “deal” with a lien by obtaining a lien release bond (“release bond”). For those lucky enough to not have encountered this issue, a release bond is a nifty statutory device whereby a surety agrees to record a release bond for the full claimed amount of the lien, with the release bond substituting in for the liened property, effectively discharging the property from liability under the lien. In other words, the lien is released from the property and attaches to the release bond. If the lien claimant recovers on its lien, it is technically satisfied by the surety providing the release bond (or the party who agrees to indemnify and defend the release bond). In exchange for delivering the release bond, the surety demands yearly premiums be paid on the release bond amount Read the court decision
Read the full story...
Reprinted courtesy of Scott MacDonald, Ahlers Cressman & Sleight PLLC
Mr. MacDonald may be contacted at scott.macdonald@acslawyers.com

Lewis Brisbois Listed as Top 10 Firm of 2022 on Leopard Solutions Law Firm Index

March 27, 2023 — Lewis Brisbois Newsroom
Los Angeles, Calif. (March 17, 2023) – Lewis Brisbois has been listed among the top 10 law firms on the 2022 Leopard Law Firm Index. Billed as "the legal industry's most inclusive and up-to-date firm rating system," the index, published by Leopard Solutions, is a dynamic rating system that is updated twice weekly and focuses on law firms' profitability, viability, growth, and potential opportunity. Each year, Leopard Solutions compiles a list of the index firms' overall scores for the previous year. For 2022, Lewis Brisbois ranked 8th, with an aggregate score of 446 out of a possible 500. Other firms in the top 10 include Kirkland & Ellis, Ropes & Gray, and DLA Piper. The Leopard Law Firm Index provides insights into law firm health and stability, using a robust list of criteria. This includes growth in attorney headcount, average attorney tenure, increases in revenue per lawyer (RPL) over a five-year period, relative success in lateral recruiting, and general retention of partners and associates, as well as the overall diversity within a firm. In an interview with Law360 Pulse, Leopard Solutions VP of Sales & Marketing Phil Flora noted that the top 10 firms are some of the largest firms with above average ethnic diversity. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES