Tips for Drafting Construction Contracts
May 04, 2020 —
Stuart Rosen - Construction ExecutiveWhen negotiating a construction contract, a contractor and its advisers must first determine the areas of greatest concern.
For example, if the contractor believes that the drawings that were prepared by the architect and other design professionals are deficient, the contractor may want to reference those deficiencies in the contract. The contractor should emphasize that it is not responsible for the drawings and to the extent the project schedule is extended to allow the parties to address such issues with the drawings, the contractor would be entitled to additional compensation.
This article provides contractors with additional tips, with a broad focus on project delays, for their protection when negotiating and drafting construction contracts, and helps contractors understand the rationale for such tips to better prepare contractors in such negotiations.
Contractor’s liability to the owner for delay damages
It is imperative that the contract include a waiver of claims for consequential damages. AIA Document A201TM – 2017 includes such a waiver, which provides, in pertinent part, “The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract … This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14.”
Reprinted courtesy of
Stuart Rosen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Rosen may be contacted at
srosen@proskauer.com
Florida’s Fourth District Appeals Court Clarifies What Actions Satisfy Florida’s Construction Defect Statute of Repose
November 14, 2018 —
Rahul Gogineni - The Subrogation SpecialistIn Gindel v. Centex Homes, 2018 Fla.App. LEXIS 13019, Florida’s Fourth District Court of Appeal recently concluded that the date on which the plaintiffs provided a pre-suit notice in compliance with §558.004 of Florida’s construction defect Right-to-Cure statute, Fla. Stat. §§ 558.001 to 558.005, et. seq., is the date on which the plaintiff commenced a “civil action or proceeding,” i.e. an “action,” within the meaning of Florida’s construction defect statute of repose, Florida Statue § 95.11(3)(c). Thus, reversing the decision of the trial court, the Fourth District held that the plaintiffs timely-filed their construction defect action against the defendants.
Read the court decisionRead the full story...Reprinted courtesy of
Rahul Gogineni, White and Williams LLPMr. Gogineni may be contacted at
goginenir@whiteandwilliams.com
New York Team Secures Appellate Win on Behalf of National Home Improvement Chain
September 26, 2022 —
Lewis BrisboisNew York, N.Y. (August 12, 2022) - New York Appellate Partner Nicholas P. Hurzeler, with New York Partners John J. Doody and David M. Pollack, obtained a significant appellate victory on behalf of a national home improvement chain when a New York Appellate Division panel for the Second Department reduced a jury verdict by more than half.
In this matter, which was
covered by Law360, the plaintiff was a customer at one of the chain's stores when he was involved in a confrontation with a man and his wife as they exited the store. The chain's loss prevention official told police that the plaintiff had assaulted the female customer. As a result of the incident, the plaintiff was arrested, spent the night in jail, and was arraigned at the same courthouse where he worked as a staff attorney while wearing only an undershirt and jogging shorts. He also had to disclose his arrest on his judgeship nomination application. The charges against him were ultimately dropped after the chain's loss prevention official told prosecutors that surveillance video showed that the female customer’s assault claims were false.
The plaintiff subsequently sued the home improvement chain and its loss prevention official for allegedly causing his false arrest and interfering with his career goal of securing a New York state court judgeship. At the close of the trial in this case, the jury determined that the defendant was liable for battery and false imprisonment, and awarded the plaintiff $1.8 million for pain and suffering.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
Standard of Care
December 16, 2019 —
Jay Gregory - Gordon & Rees Construction Law BlogOne of the key concepts at the heart of Board complaints and civil claims against a design professional is whether or not that design professional complied with the applicable standard of care. In order to prevail on such a claim, the claimant must establish (typically with the aid of expert testimony) that the design professional deviated from the standard of care. On the other side of the coin, to defend a design professional against a professional malpractice claim, defense counsel attempts to establish that – contrary to the claimant’s allegations – the design professional, in fact, complied with the standard of care. Obviously, it becomes very important in such a claim situation to determine what the standard of care is that applies to the conduct of the defendant design professional. Often, this is easier said than done. There is no dictionary definition or handy guidebook that identifies the precise standard of care that applies in any given situation. The “standard of care” is a concept and, as such, is flexible and open to interpretation. Traditionally, the standard of care is expressed as being that level of service or competence generally employed by average or prudent practitioners under the same or similar circumstances at the same time and in the same locale. In other words, to meet the standard of care a design professional must generally follow the pack; he or she need not be perfect, exemplary, outstanding, or even superior – it is sufficient merely for the designer to do that which a reasonably prudent practitioner would do under similar circumstances. The negative or reverse definition also applies, to meet the standard of care, a practitioner must refrain from doing what a reasonably prudent practitioner would have refrained from doing.
Although we have this ready definition of the standard of care, in any given dispute it is practically inevitable that the parties will have markedly different opinions as to: (1) what the standard of care required of the designer; and (2) whether the defendant design professional complied with that requirement. The claimant bringing a claim against a design professional typically will be able to find an expert reasonably qualified (at least on paper) who will offer an opinion that the defendant failed to comply with the standard of care. It is just as likely that the counsel for the defendant design professional will be able to find his or her own expert who will counter the opinion of the claimant’s expert and maintain that the defendant design professional, in fact, complied with the standard of care. What’s a jury to think?
The concept of standard of care is intertwined with the legal concept of negligence. In the vast majority of law suits against design professionals, a claimant (known as the plaintiff) will assert a claim for negligence against the design professional now known as the defendant.1 As every first year law student learns while studying the field of “Torts,” negligence has four subparts. In order for a defendant to be found negligent, the claimant must establish four elements: (1) duty; (2) breach; (3) causation; and (4) damages. In other words, to establish a claim against a defendant design professional, a plaintiff must demonstrate that the defendant owed the plaintiff a duty of care but breached that duty and, as a result, caused the plaintiff to suffer damages.
Read the court decisionRead the full story...Reprinted courtesy of
Jay Gregory, Gordon & Rees Scully MansukhaniMr. Gregory may be contacted at
jgregory@grsm.com
Supreme Court Grants Petition for Review Regarding Necessary Parties in Lien Foreclosure Actions
August 17, 2017 —
Lindsay K. Taft - Ahlers & Cressman PLLCFor several years, the requirements for which parties must be named in a lien foreclosure action when a release of lien bond is in place have been cloudy. RCW 60.04 et seq., the “mechanics’ lien” or “construction lien” statute, provides protection for a party or person who provides labor, materials, or equipment to a construction project. That person or party, if not paid, can file a lien against the construction project property to secure recovery. As the lien impacts the property by “clouding title” and could potentially result in foreclosure of the property, the statute sets forth strict requirements with respect to timing, notice, and parties. For example, the lien must be recorded within 90 days of the person or party’s last day of work or materials or equipment supplied, and the lien claimant must then give a copy of the claim of lien to the owner or reputed owner within 14 days of the lien recording. RCW 60.04.081.
The statute also allows a property owner or other party to “free” the property from the lien prior to the claim being resolved by issuing a release of lien bond. While the claim is still in dispute, the lien then attaches to the bond and not the property. The same rules about foreclosure, however, still apply but not without some confusion.
Read the court decisionRead the full story...Reprinted courtesy of
Lindsay K. Taft, Ahlers & Cressman PLLCMs. Taft may be contacted at
ltaft@ac-lawyers.com
These Are the 13 Cities Where Millennials Can't Afford a Home
June 10, 2015 —
Victoria Stilwell and Wei Lu – BloombergThere's no place like home — except when you can't afford one.
Millennials have been priced out of some of the biggest U.S. cities, with residential real estate prices rising even as wage growth remains elusive.
Bloomberg used data from the U.S. Census Bureau, Zillow Group Inc. and Bankrate.com to quantify how much more money millennials would need to earn each year to afford a home in the largest U.S. cities. The good news is that out of 50 metropolitan areas, 37 are actually affordable for the typical 18-34 year-old (scroll down to the end of the story to see the full results).
The bad news is that the areas that often most appeal to young adults are also the ones where homeownership is the most out of reach.
Reprinted courtesy of
Victoria Stilwell, Bloomberg and
Wei Lu, Bloomberg Read the court decisionRead the full story...Reprinted courtesy of
Insurance Firm Defends against $22 Million Claim
June 15, 2011 —
CDJ STAFFThe Houston law firm of Eggleston & Briscoe successfully defended their client, Colony Insurance Company, which was being sued for $22 million over roof hail damage. The Summer Hill Village Community Association did not convince a jury that the insurance company had violated state law or breached its contract when it denied coverage for the roofs. The homeowners association contended that the roof damage was due to a hail storm in 2007. The jury agreed with experts who contended the damage was already present at that time.
Mr. Eggleston noted that “when your client is sued for a claim of $22 million, it is very satisfying to hear a jury agree that they in fact acted honorably and owed nothing.”
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
Colorado Senate Bill 15-177: This Year’s Attempt at Reasonable Construction Defect Reform
February 18, 2015 —
Zach McLeroy – Colorado Construction LitigationOn February 10, 2015, Senators Scheffer and Ulibarri introduced Senate Bill 15-177, which is sponsored in the House by Representatives DelGrosso and Singer. SB 15-177 amends the prerequisites, found in the Colorado Common Interest Ownership Act (“CCIOA”), for an association to file a construction defect action. The bill has been assigned to the Senate Committee on Business, Labor, and Technology but not yet scheduled for hearing.
The major points of the bill include: 1) enforcement of a mediation or arbitration provision contained in the original governing documents of a common interest community, even if subsequently amended or removed; 2) the addition of a requirement that mediation take place before a construction defect action can be filed; 3) heightened requirements that an association board provide advanced notice to all unit owners, together with a disclosure of projected costs, duration, and financial impact of the construction defect claim; 4) the addition of a requirement that the board obtain the written consent of a majority of the owners of units, and; 5) a requirement that prior to the purchase and sale of a property in a common interest community, the purchaser receive notice that binding arbitration may be required for certain disputes.
Read the court decisionRead the full story...Reprinted courtesy of
Zach McLeroy, Higgins, Hopkins, McLain & Roswell, LLCMr. McLeroy may be contacted at
mcleroy@hhmrlaw.com
