Tennessee Looks to Define Improvements to Real Property
January 27, 2020 —
Lian Skaf - The Subrogation StrategistFor subrogation practitioners dealing with an installation-based statute of repose, knowing what is an improvement to real property is the first battle in what can, but does not have to be, a long fight. Like many other states, Tennessee’s statute of repose bars claims based on improvements to real property. Tennessee’s statute of repose runs four years after substantial completion of the improvement. See Tennessee Code Ann. § 28-3-202. In the case of Maddox v. Olshan Found. Repair & Waterproofing Co. of Nashville, L.P., E A, 2019 Tenn.App. LEXIS 464, 2019 WL 4464816, the Court of Appeals of Tennessee examined whether or not the work done by the defendant, Olshan Foundation Repair & Waterproofing Co. of Nashville, L.P., E.A. (Olshan) — which addressed bowing walls, cracks in the foundation and walls and water intrusion — qualified as improvements to real property for the purposes of the statute of repose. The court held that the work by Olshan essentially amounted to repairs, and did not qualify as improvements to real property.
In Maddox, the plaintiff, Rachel Maddox (Maddox), noticed cracking in her home in 2005 and hired Olshan to assess the issue and conduct necessary repairs. Olshan made several recommendations and the parties agreed on Olshan’s proposal for the price of $27,000. From their initial work in 2005 until late 2011, Olshan visited the property several times to address ongoing structural issues with the home. Eventually, eight months after Olshan told Maddox they could not fix the house and failed to return her phone calls, Maddox filed suit, alleging fraud against the company.
After a three-day bench trial, the trial court found in favor of the plaintiff for $187,000, plus $15,0000 in punitive damages. Among other holdings, the court rejected Olshan’s statute of repose defense. Olshan appealed, raising the statute of repose issue again.
Read the court decisionRead the full story...Reprinted courtesy of
Lian Skaf, White and Williams LLPMr. Skaf may be contacted at
skafl@whiteandwilliams.com
An Architect Uses AI to Explore Surreal Black Worlds
October 24, 2023 —
Kriston Capps - BloombergFor architect Curry Hackett, the appeal of using artificial intelligence to design projects isn’t to build the world of the impossibly distant future. Instead he wants to mine the near present, using machine learning to generate postcards from a world that is recognizably our own, but refracted through a lens of Black history and material design.
Hackett is the designer behind a series of provocations made using AI to remix Black vernacular architecture in kaleidoscopic Afrofuturist landscapes. Specifically, he’s assembling images with Midjourney, an AI tool favored by architects to imagine what buildings might look like. Hackett’s prompts result in straightforward yet surreal sets, including roadside Popeyes kiosks in rural North Carolina, homes with inflatable porches in the Florida panhandle and park benches made out of the couch from grandma’s living room. Quilts, basket weaving and other cultural modes associated with American South are the building materials for Hackett’s speculative futures.
Read the court decisionRead the full story...Reprinted courtesy of
Kriston Capps, Bloomberg
Indiana Court of Appeals Rules Against Contractor and Performance Bond Surety on Contractor's Differing Site Conditions Claim
April 03, 2013 —
Brian M. Falcon - Frost Brown Todd LLCEarlier this year, the Indiana Court of Appeals issued an important opinion that impacts contractors and sureties alike. The decision should give contractors in Indiana pause before ceasing work while a dispute with the owner is pending. Sureties also have been placed on notice that strict compliance with the terms of their bonds is amongst their best defenses to claims made by owners and bond claimants.
In Dave's Excavating, Inc. and Liberty Mutual Insurance Co. v. City of New Castle, Indiana, 959 N.E.2d 369 (Ind. Ct. App. 2012), the contractor (“Dave’s”) was the successful bidder on a public sanitary sewer and water main extension project. Dave's procured a performance bond from Liberty Mutual to guarantee its performance obligations to the owner (the "City"). After encountering what it deemed different subsurface conditions—and indeed after having been previously granted a change order to use excavated materials as backfill in light of the subsurface conditions on site—Dave’s placed the project engineer on notice of a differing site conditions claim. The total claim amounted to an 84% increase in the total contract price. With the claim, Dave's advised the project engineer it was ceasing further work until the project engineer provided direction.
While the project engineer reviewed the claim, it reminded Dave's of its contractual obligation to "carry on the work and adhere to the progress schedule during all disputes or disagreements with the OWNER." A dispute immediately occurred regarding whether Dave's was required to continue to work while the project engineer resolved the differing site condition claim. After Dave's maintained its position that it was not required to continue to work, the project engineer placed it on notice of default and copied the letter to Liberty Mutual.
Read the court decisionRead the full story...Reprinted courtesy of
Brian M. FalconBrian M. Falcon can be contacted at http://www.frostbrowntodd.com/contact.html
Traub Lieberman Attorneys Lisa M. Rolle and Vito John Marzano Secure Dismissal of Indemnification and Breach of Contract Claims Asserted against Subcontractor
November 24, 2019 —
Lisa M. Rolle & Vito John Marzano - Traub Lieberman PerspectivesOn August 7, 2019, TLSS Partner Lisa M. Rolle and associate Vito John Marzano obtained a dismissal of all claims on behalf of their client, the subfloor subcontractor at the worksite, in a severed action filed in the Supreme Court of the State of New York, County of Kings.
In April 2014, plaintiff commenced suit against several defendants, including the general contractor, after he sustained an injury when he fell through temporary plywood while installing a staircase at a worksite in Brooklyn. In May 2018, plaintiff filed a note of issue and certified the matter as ready for trial. Immediately thereafter, the general contractor initiated a second third-party action against the subcontractor seeking common-law and contractual indemnification and breach of contract. The Court subsequently granted Traub Lieberman’s motion to sever the second third-party action and instructed the general contractor to file a new action.
After the general contractor recommenced suit, Traub Lieberman, on behalf of its client, the subcontractor, immediately moved to dismiss for failure to state a cause of action. In relevant part, Traub Lieberman pointed to the deposition testimony of the general contractor’s principal to establish that the subcontractor had finished its work on the permanent subfloor no less ten months to over a year prior to plaintiff’s accident, and that the subfloor required no alteration, repair or maintenance prior to or as a result of plaintiff’s accident. Further, the general contractor’s testimony pointed to work performed by another subcontractor that directly resulted in plaintiff’s injuries. It was also brought to the Court’s attention that plaintiff had testified that he fell through a temporary plywood floor, and that the subcontractor had only installed a permanent subfloor.
Reprinted courtesy of
Lisa Rolle, Traub Lieberman and
Vito John Marzano, Traub Lieberman
Ms. Rolle may be contacted at lrolle@tlsslaw.com
Mr. Marzano may be contacted at vmarzano@tlsslaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Can Your Small Business Afford to Risk the Imminent Threat of a Cyber Incident?
November 28, 2018 —
Jeffrey M. Dennis & Heather H. Whitehead – Newmeyer & Dillion LLPCybersecurity incidents are occurring on a daily basis and at an increasingly growing rate. Yet, many small businesses still have not obtained adequate (or any) cyber insurance to address these risks and the costly impacts to the business that will result. In a recent study completed by the Insurance Information Institute1, only about a third of all small businesses polled responded that they have cyber insurance in place, with 70% of respondents replying that they have no plans to purchase a cyber insurance policy in the next 12 months. Most of the businesses indicated that they do not believe they have any need for cyber insurance, yet almost half of those same companies stated they are unprepared to handle cyber threats. A main reason for not purchasing cyber insurance was a lack of understanding about this type of insurance and coverages available.
The Risks for Small Businesses
These statistics are alarming considering that the average cost of a cyber-related loss for a small business has increased 250% in the past two years, and now totals $188,400. In determining whether insurance coverage should be purchased, companies typically assess the perceived risks to the company, the likelihood of such risks occurring, as well as any costs or expenses that may result. For example, most companies regularly obtain a property policy to cover a fire or other casualty that may damage its business location even though such an event is unlikely or unexpected. Yet, cyber incidents are just as likely, if not more likely to occur, and the impacts to a company in the event of an incident are far worse. Many incidents result in a complete suspension of the daily operations of the company for several days or longer.
In addition to financial loss, companies may face the following as a result of a cyber incident:
- Theft, breach or loss of information and data;
- Damage to the company's reputation, brand or image; and
- Regulatory, governance and legal issues.
- How Cyber Insurance can Help
Cyber insurance policies can be obtained to address the losses related to a data breach and may include costs for investigating a breach, notifying people affected by a breach of personally identifiable information, managing the potential damage to reputation and other crisis-management expenses, recovering lost or corrupted data, and related legal expenses. More importantly, well-drafted policies can afford coverage for business interruption losses; i.e. those expenses and lost revenue resulting from a breached system and a company's inability to continue its usual operations. Coverage may also be obtained for "cyber extortion", which covers costs resulting from an extortion event such as ransomware or fraudulent wire transfers.
It is important to keep in mind that cyber insurance is only one component to consider when developing and implementing an overall risk management strategy to prevent cyber incidents. However, taking into account the exposure to a company if and when a cyber incident occurs, it is highly advisable to have this coverage in place.
1Insurance Information Institute, "Small business, big risk: Lack of cyber insurance is a serious threat," October 2018.
Jeff Dennis is the head of the firm's Privacy & Data Security practice. Jeff works with the firm's clients on cyber-related issues, including contractual and insurance opportunities to lessen their risk. For more information on how Jeff can help, contact him at jeff.dennis@ndlf.com.
Heather Whitehead is a Partner in the firm's Privacy & Data Security practice. Heather also practices insurance coverage matters for commercial, retail, industrial, mixed-use, multi-family and residential projects. For more information on how Heather can help, contact her at heather.whitehead@ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Third Circuit Follows Pennsylvania Law - Damage Caused by Faulty Workmanship Does Not Arise from an Occurrence
May 10, 2013 —
Tred EyerlyThe Third Circuit followed Pennsylvania law in determining that damage caused by faulty workmanship did not arise from an occurrence. Zurich Am. Ins. Co. v. R. M. Shoemaker Co., 2013 U.S. App. LEXIS 6093 (3d Cir. March 27, 2013).
The County sued R. M. Shoemaker, alleging faulty construction of an addition to a correctional institution. The County alleged Shoemaker negligently supervised its subcontractor, thereby permitting the subcontractor to engage in willful misconduct, resulting in damage to structural elements of the correctional institution. The County alleged that Shoemaker's negligence permitted water to intrude, damaging the electrical systems, acoustic ceilings and miscellaneous equipment.
Zurich sought a declaratory judgment that it was not required to defend or indemnify Shoemaker. The district court granted Zurich summary judgment. Relying on Pennsylvania law, the district court found that the allegations in the underlying action did not arise from an occurrence.
Read the court decisionRead the full story...Reprinted courtesy of
Tred EyerlyMr. Eyerly can be contacted at
te@hawaiilawyer.com
Philadelphia Revises Realty Transfer Tax Treatment of Acquired Real Estate Companies
January 05, 2017 —
Nancy Frantz, Kevin Koscil & James Vandermark – White and Williams LLPOn December 8, 2016, the Philadelphia City Council voted unanimously to amend the ordinance governing realty transfer taxes in an effort to increase tax revenue. The current combined realty transfer tax rate in Philadelphia is 4.0% and will increase to 4.1% after December 31, 2016.[1] The amendment significantly impacts how taxes are imposed upon transfers of ownership in so-called “real estate companies” and effectively eliminates deals commonly referred to as 89-11 transactions. The amendment mainly focuses on transfers of real estate companies, rather than direct transfers of real estate, but it also affects certain direct transfers of real estate in exchange for noncash consideration.
Reprinted courtesy of White and Williams LLP
Nancy Frantz,
Kevin Koscil and
James Vandermark
Ms. Frantz may be contacted at frantzn@whiteandwilliams.com
Mr. Koscil may be contacted at koscilk@whiteandwilliams.com
Mr. Vandermark may be contacted at vandermarkj@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Liquidated Damages Clause Not Enforced
October 02, 2023 —
David R. Cook Jr. - Autry, Hall & Cook, LLPA liquidated-damages clause was not enforced in a recent case before the Georgia Court of Appeals. The clause did not contain standard provisions that would normally allow a trial court to enforce the clause as written. As a result, the trial court looked beyond the contract to determine whether the City satisfied the requirements for enforcement of the liquidated-damages clause. Below are the relevant excerpts.
City of Brookhaven v. Multiplex, LLC, A23A0843, 2023 WL 4779591 (Ga. Ct. App. July 27, 2023)
Here, the Contract provides for “Liquidated Damages at the rate of $1,000.00 per calendar day” in the last paragraph of the Scope of Work addendum. The Contract lacks, however, any language indicating that the liquidated damages were not intended to be a penalty. See Fuqua Const. Co. v. Pillar Dev., Inc., 293 Ga. App. 462, 466, 667 S.E.2d 633 (2008) (rejecting use of parol evidence where the parties “explicitly agreed” in “unambiguous contract language” that the liquidated damages were not a penalty). Absent such language, the court can look to parol evidence in the record to determine the effect the provision was intended to have. See J.P. Carey Enterprises, 361 Ga. App. at 391-392 (1) (b), 864 S.E.2d 588 (looking to “extrinsic evidence” such as emails, documents, and deposition testimony to determine whether the damages provision at issue was a penalty); see also Gwinnett Clinic, Ltd. v. Boaten, 340 Ga. App. 598, 602-603, 798 S.E.2d 110 (2017) (“Shah’s testimony also suggested that one purpose of the liquidated damages provision was to deter employees from breaching the agreement”).
Read the court decisionRead the full story...Reprinted courtesy of
David R. Cook Jr., Autry, Hall & Cook, LLPMr. Cook may be contacted at
cook@ahclaw.com
