Fairfield Connecticut Building Expert Directory

Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)

October 05, 2020 — Christopher G. Hill - Construction Law Musings
I’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:

White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Ten Firm Members Recognized as Super Lawyers or Rising Stars

July 13, 2017 — Ceslie Blass - Ahlers & Cressman PLLC
While we avoid using this blog as a platform for self-promotion, we recently received share-worthy distinctions, which both flatter and humble us. We invite you, our loyal readers, to celebrate in our success, which in great measure is due to you. John P. Ahlers, one of the firm's founding partners, was ranked third overall across all practicing industries in Washington 2017 Super Lawyers and founding partner Paul R. Cressman, Jr. was ranked in the Top 100. The following other firm members were also recognized as Super Lawyers: Founding partner Scott R. Sleight, Bruce A. Cohen (Partner), Brett M. Hill (Partner), and Lawrence Glosser (Partner). In addition, Ryan W. Sternoff (Partner), James R. Lynch (Partner), Tymon Berger (Associate), and Lindsay (Taft) Watkins (Associate) were selected as Super Lawyers Rising Stars. Over half of the firm's lawyers received Super Lawyers distinction. Super Lawyers selects attorneys using a patented multiphase selection process. Peer nominations and evaluations are combined with third party research. Each attorney candidate is evaluated on 12 indicators of peer recognition and professional achievement. Only five percent of the total lawyers in Washington State are selected for the honor of Super Lawyers and no more than 2.5 percent are selected for the honor of Super Lawyers Rising Stars. Read the court decision
Read the full story...
Reprinted courtesy of Ceslie Blass, Ahlers & Cressman PLLC
Ms. Blass may be contacted at cblass@ac-lawyers.com

CA Supreme Court Set to Rule on Important Occurrence Issue Certified by Ninth Circuit

March 22, 2018 — William S. Bennett – SDV Blog
The California Supreme Court recently heard oral arguments over whether an insurer is required to cover allegations that a builder negligently failed to supervise an employee who sexually assaulted a middle school student while working at the student’s school. The question was originally certified to the California Supreme Court by the Ninth Circuit in 2016, but nothing happened until the court heard arguments on March 6, 2018. Read the court decision
Read the full story...
Reprinted courtesy of William S. Bennett, Saxe Doernberger & Vita, P.C.
Mr. Bennett may be contacted at wsb@sdvlaw.com

The Hidden Dangers of Construction Defect Litigation: A Redux

January 17, 2013 — David McLain, Higgings, Hopkins, McLain & Roswell, LLC

I previously wrote an article entitled “The Hidden Dangers of Construction Defect Litigation” for the Common Interests magazine, the monthly periodical of the Rocky Mountain Chapter of the Community Associations Institute. In that article, I discussed the potential negative effects of homeowners associations bringing construction defect suits as anything other than a last resort. The purpose of this post is to bring to light, by way of a real life example, the problems discussed in my previous article.

I have recently seen a lawsuit filed by an individual homeowner within a common interest community against the homeowners association, its management company, and the attorneys retained by the association to represent it in a construction defect lawsuit against the original developer, general contractor, and one of the design professionals. In his suit, the homeowner complains that the association’s construction defect attorneys “neglected to amend [their] complaint to include only and specifically the claims for damages for those properties, those buildings or condominium units, either by owner or specific locations, which had sustained damages or had faulty construction for which damages were being sought.” As a result of claiming damages throughout the entire community, the homeowner alleged that the entire community was tarred “with the black brush of litigation.”

As the homeowner explained in his complaint, he purchased a condominium for his daughter-in-law when she moved to Colorado to care for him after the death of his wife.

Read the court decision
Read the full story...
Reprinted courtesy of David McLain
Mr. McLain can be contacted at mclain@hhmrlaw.com

Floating Crane on Job in NYC's East River Has a Storied Past of Cold War Intrigue

March 22, 2017 — Nadine M. Post – Engineering News-Record
The complex maneuver of lifting heavy prefabricated modules out of New York City's East River to build a university laboratory took careful planning and the work of one particular floating crane with a complicated past. Read the court decision
Read the full story...
Reprinted courtesy of Nadine M. Post, Engineering News-Record
Ms. Post may be contacted at postn@enr.com

#2 CDJ Topic: Valley Crest Landscape v. Mission Pools

December 30, 2015 — Beverley BevenFlorez-CDJ STAFF
In July of this year, Christopher Kendrick and Valerie A. Moore of Haight Brown & Bonesteel LLP analyzed the results of the Valley Crest Landscape v. Mission Pools case, in which “a California appeals court held that equities favor an insurer seeking equitable subrogation over a subcontractor that agreed to defend and indemnify claims arising out of its performance of work under the subcontract.” Read the full story... In the article, “General Liability Insurer Entitled to Subrogate Against its Insured’s Indemnitor,” Matthew S. Foy and Michael A. Pursell of Gordon & Rees LLP also discussed the details of the Valley Crest v. Mission Pools case that involved installing a swimming pool on a St. Regis hotel property: “In Valley Crest Landscape Development, Inc. v. Mission Pools of Escondido, Inc., the California Court of Appeal for the Fourth Appellate District held that an insurer was entitled to equitably subrogate a breach of express indemnity claim against its insured’s indemnitor.” Read the full story... This month, Graham C. Mills of Newmeyer & Dillion reported on the decision by the Court of Appeals regarding the Valley Crest case, which “reinforces the right of a general contractor to defense and indemnity by a subcontractor when the parties have contractually allocated risk to the subcontractor. To ensure compliance with that right, the Valley Crest court imposed a strong penalty against a subcontractor that defaulted on its obligation.” Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Andrea DeField Recognized In 2024 List of Influential Business Women By South Florida Business Journal

February 19, 2024 — Hunton Insurance Recovery Blog
We are pleased to announce that Hunton Andrews Kurth LLP insurance coverage partner Andrea DeField was named to the South Florida Business Journal’s 2024 list of Influential Business Women. The award celebrates 25 women who have a strong record of leadership, performance and innovation in their industry, as well as meaningful community involvement. This distinction is well-deserved given Andi’s leadership in the cyber insurance space, contribution to the firm’s pro bono efforts, and longstanding record of community involvement in South Florida. Andi and the other honorees will be featured in the March 15 special issue of the South Florida Business Journal introducing the Influential Business Women of 2024. Congratulations Andi! Read the court decision
Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

Indemnity Provision Prevails Over "Other Insurance" Clause

December 06, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The Second Circuit predicted that the New York appellate courts would find the contractual indemnity provision prevailed over the application of an "other insurance" provisions. Cent. Sur. Co. v. Metro. Transit Auth., 2021 U.S. App. LEXIS 29860 (2nd Cir. Oct. 5,2021). Long Island Railroad (LIRR) contracted with general contractor Rukh Enterprises, Inc. to complete a railroad bridge lead paint removal and repainting project on Metropolitan Transit Authority property. Rukh hired subcontractor, East Coast Painting & Maintenance to complete certain lead-related work on the project. An employee of East Coast suffered an injury while working on the project. The employee sued LIRR and Rukh. A settlement in the underlying case was reached, implicating three of four policies - Admiral (primary for LIRR), Arch (CGL for Rukh), and Harleysville (primary for East Coast). Century Surety (excess liability for Rukh) did not contribute to the settlement and disclaimed all coverage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES