Seattle Washington Building Expert Directory

Is Your Design Professional Construction Contract too Friendly? (Law Note)

July 09, 2014 — Melissa Dewey Brumback – Construction Law North Carolina
My husband often travels the back roads between Chapel Hill and Fuquay Varina to visit friends. En route (a circuitous route that goes past Sharon Harris Nuclear Power Plant, among other places), he passes by the “Friendly Grocery.” [Sign] No *Loitering*Littering*Alcoholic Beverages on Premises*Bike*Skateboard* *10 minutes Parking Limit*Towing Enforced* I’m not sure which is the “friendly” part of that sign. In fact, the sign seems to be the antithesis of friendly. What does this have to do with your construction contracts? Sometimes, in an effort to please the client and/or secure the project, architects and engineers have the habit of being too friendly in their contract language. That is, you make promises or proposals that may promise too much of a good thing for the client. This can cause big problems. Bigger than being towed away from a rural grocery store in the middle of nowhere. You could be putting your insurance coverage at risk. Have you ever promised to use “best efforts” in your design or plans? Promised to design to a specific LEED standard? Guaranteed 100% satisfaction? You might be putting your errors & omission coverage at issue. By warrantying or guaranteeing something, you are assuming a level of liability well beyond the standard of care required by law. By law, you only need to conform to the standard of care, and your insurance will only provide coverage up to that standard of care. In other words, if you make guarantees or promise “best efforts,” you are contracting to something that will *not* be insured. If something goes wrong, you will be without the benefit of your professional liability coverage. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback may be contacted at mbrumback@rl-law.com

Recording “Un-Neighborly” Documents

April 03, 2019 — Bob Henry - Snell & Wilmer Real Estate Litigation Blog
In September 2018, in Baumgartner v. Timmins, 245 Ariz. 334, 429 P.3d 567, the Arizona Court of Appeals provided further clarification on what constitutes an “encumbrance” on a property for purposes of Arizona’s statutory scheme prohibiting the recording of “false documents.” The statute, A.R.S. § 33-420, prohibits the recording of documents that a person knows to be forged, are groundless, or that contain material misstatements (or false claims). A person who claims an “interest in, or a lien or encumbrance against” real property who records such documents can be held liable for $5,000 or treble the actual damages caused by the recording (whichever is greater), A.R.S. § 33-420(A), and perhaps even be found guilty of a class 1 misdemeanor, A.R.S. § 33-420(E). At issue in Baumgartner were neighbors fighting about CC&Rs—a typical neighborhood fight. In 2015, some of the neighbors filed suit against the Timminses for violating the CC&Rs. The Timminses did not contest the lawsuit, resulting in a default judgment. In what the Court of Appeals characterized as a lawsuit filed by the Timminses “in apparent response to the [first] lawsuit and resulting default judgment,” the Timminses created, signed, and recorded affidavits contending that the Plaintiffs in the original lawsuit were themselves “in violation of several provisions of the CC&Rs.” The Plaintiffs then filed suit again against the Timminses, this time contending that the Timminses had violated A.R.S. § 33-420 by recording the affidavits because the affidavits, the Plaintiffs contended, created encumbrances on their properties. The Apache County Superior Court agreed, and issued a final judgment nullifying the recorded documents and awarding the Timminses damages, along with their attorneys’ fees and costs. Read the court decision
Read the full story...
Reprinted courtesy of Bob Henry, Snell & Wilmer
Mr. Henry may be contacted at bhenry@swlaw.com

Huh? Action on Construction Lien “Relates Back” Despite Notice of Contest of Lien

May 01, 2023 — David Adelstein - Florida Construction Legal Updates
Not every case law you read makes sense. This sentiment goes to the uncertainty and grey area of certain legal issues. It is, what you call, “the nature of the beast.” You will read cases that make you say “HUH?!?” This is why you want to work with construction counsel to discuss procedures and pros / cons relative to construction liens. An example of a case that makes you say “HUH” can be found in Woolems, Inc. v. Catalina Capstone Creations, Inc., 2023 WL 2777506 (Fla. 3d DCA 2023) dealing with a construction lien foreclosure dispute. Here, a contractor filed a lawsuit against a subcontractor with a summons to show cause why the subcontractor’s construction lien should not be discharged. This is a specific complaint filed under Florida Statute s. 713.21(4). This statute requires the lienor to essentially foreclose on its construction lien within 20 days after it was served with a “show cause” summons. The subcontractor filed its answer and counterclaim but did NOT assert a claim to foreclose its construction lien. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

San Francisco Bucks U.S. Trend With Homeownership Gains

September 24, 2014 — Prashant Gopal – Bloomberg
Homeownership climbed in a small number of U.S. metropolitan areas last year including San Francisco; Nashville, Tennessee; and Austin, Texas, where strong job growth helped them buck the national trend. Of 100 metropolitan areas, 17 had an increase in the “true” ownership rate, which measures the number of owner-occupied households per 100 adult residents, according to an analysis by Trulia Inc. of Census Bureau data. Even in those areas, advances were small. San Francisco had the biggest gain in 2013, rising about 0.6 percentage points from a year earlier, the property-information company said today. The Gary, Indiana, region, made up mostly of suburbs, had a similar increase. The homeownership rate has been falling in much of the U.S. as incomes stagnate and rising prices make housing less affordable and more difficult to finance for entry-level buyers. The regions where the rate is up include strong job markets such as San Francisco and Austin, and areas with stable prices such as Albany, New York, that were spared the brunt of the nationwide foreclosure crisis, Trulia said. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg
Mr. Gopal may be contacted at pgopal2@bloomberg.net

Pennsylvania Homeowner Blames Cracks on Chipolte Construction

October 14, 2013 — CDJ STAFF
“Everything was shaking, like a big bomb went off.” That’s how Hersey, Pennsylvania resident Maria Yi described the situation during construction of a Chipolte restaurant next to her home. She and other people thought it was an earthquake, but then found it came from the construction site. She told the operator of the machine to stop. Yi and her husband later found cracks in their home which they attribute to the construction activity. Township supervisors were sympathetic to Yi, with Kelly Fedeli, the Supervisor Vice Chairwoman, told Yi that she feels “very badly about what happened to you.” And Chuck Emerick, the township code officer told Yi that “we’re doing everything we can to help you.” This is not Yi’s first conflict with the proposed restaurant. Yi was involved in a lawsuit that sought to stop the restaurant from being built at all. That suit is being appealed, but even if Yi were to win at the appeal, the restaurant would go forward. Said Yi of the supervisors, “they told me there would be no problem.” Read the court decision
Read the full story...
Reprinted courtesy of

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

Indiana Appellate Court Allows Third-Party Spoliation Claim to Proceed

August 01, 2023 — Ryan Bennett - The Subrogation Strategist
In Safeco Insurance Company of Indiana as Subrogee of Ramona Smith v. Blue Sky Innovation Group, Inc., et al, No. 22A-CT-1924, 2023 Ind. App. LEXIS 157, the Court of Appeals of Indiana (Appellate Court) reversed a trial court ruling that granted the motion to dismiss filed by Michaelis Corporation (Michaelis), a restoration company. The Appellate Court ruled that the trial court erred in dismissing the plaintiff’s spoliation and negligence claims against Michaelis, who discarded evidence relating to the cause of the fire at issue. The plaintiff’s insured owned a home in Indianapolis, Indiana. On Halloween night in 2019, a fire occurred at the property. The plaintiff’s representatives preliminarily determined that the fire may have been caused by a digital dehydrator within the kitchen. Michaelis had a representative present at the site inspection and was allegedly told to preserve the kitchen area. That area was taped off with “caution” tape. Michaelis also placed a tarp over the kitchen to prevent weather damage. Despite the instructions and precautions, Michaelis demolished the kitchen and discarded the dehydrator along with other fire debris. Read the court decision
Read the full story...
Reprinted courtesy of Ryan Bennett, White and Williams LLP
Mr. Bennett may be contacted at bennettr@whiteandwilliams.com

Improperly Installed Flanges Are Impaired Property

February 16, 2016 — Tred R. Eyerly – Insurance Law Hawaii
Answering certified questions from the Fifth Circuit, the Texas Supreme Court found there was no coverage for flanges that leaked after installation. U. S. Metals, Inc. v. Liberty Mutual Group, Inc., 2015 Texas LEXIS 1081 (Dec. 4, 2015). U. S. Metals sold Exxon 350 custom-made, stainless steel, weld-neck flanges for use in refineries. Testing after installation showed the flanges leaked and did not meet industry standards. Exxon decided to replace the flanges to avoid risk of fire and explosion. For each flange, this involved stripping the temperature coating and insulation, cutting the flange out of the pipe, removing the gaskets, grinding the pipe surfaces smooth for re-welding, replacing the flange and gaskets, welding the new flange to the pipes, and replacing the temperature coating and insulation. The replacement process delayed operation of the diesel units for several weeks. Exxon sued U.S. Metal for over $6 million as the cost of replacing the flanges and $16 million as damages for lost use of the diesel units during the process. U.S. Metals settled with Exxon for $2.2 million and then sought indemnification from its liability insurer, Liberty Mutual. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES