Fairfield Connecticut Building Expert Directory

Falling Tree Causing Three Injuries/Deaths Is One Occurrence

September 28, 2017 — Tred R. Eyerly - Insurance Law Hawaii
In a decision by Judge Sutton, the Sixth Circuit affirmed the district court's ruling that a falling tree causing one injury and two deaths was the result of a single occurrence. Evanston Ins. Co. v. Housing Auth. of Somerset, 2017 U.S. App. LEXIS 15199 (6th Cir. Aug. 15, 2017). A large tree fell on cousins Kaitlyn Griffin and Joshua Thacker. Kaitlyn died within minutes. She was pregnant at the time. Doctors delivered her baby, but the baby died shortly thereafter. Joshua survived but suffered serious injury. In December 2013, a state court jury found the Housing Authority liable for the accident and awarded $3.7 million in damages. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

S&P Suspended and Fined $80 Million in SEC, State Mortgage Bond Cases

January 21, 2015 — Keri Geiger and Matt Robinson – Bloomberg
Standard & Poor’s (MHFI) agreed to be suspended from rating the biggest part of the commercial-mortgage bond market and pay almost $80 million to state and federal authorities over claims it bent criteria to win business. S&P misled investors about the methodology it used in 2011 to rate eight commercial-mortgage backed securities, the U.S. Securities and Exchange Commission said in a statement today. The company will pay about $58 million to the SEC and an additional $19 million to attorneys general for New York and Massachusetts to settle the matter. Ms. Geiger may be contacted at kgeiger4@bloomberg.net; Mr. Robinson may be contacted at mrobinson55@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Keri Geiger and Matt Robinson, Bloomberg

Forethought Is Key to Overcoming Construction Calamities

February 10, 2020 — Mitch Cohen - Construction Executive
Without warning, an under-construction structure in the southern United States suffered a catastrophic collapse. The tragedy resulted in the death of several people. As a result, engineering and construction post-collapse forensics experts engaged in an 18-month investigation. Those involved in the design and build project included the general contractor hired by the owner, a prime engineer, a consulting peer-review engineer and a prime structural design firm supported by a sub-consulting structural engineer. Although significant cracking was noticed several weeks before the failure, no one sounded the alarm or deemed the cracking worthy of corrective action. In their findings, forensic experts found the collapse resulted from the combined failure of the general contractor, engineers and even the owner, who all failed to shut down the work once the cracking reached unacceptable levels and/or take the appropriate actions needed to secure the public safety and mitigate the risk. This was even after the general contractor requested that the engineer-of-record and design manager assess the structure’s extreme cracking. Consequently, the choice to not seriously investigate the crack or seek an independent peer review to design a rectification plan contributed directly to the tragedy. This is typically referred to within the industry as a “negligent professional design error.” Reprinted courtesy of Mitch Cohen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Cohen may be contacted at mitch.cohen@rtspecialty.com

Making the Construction Dispute Resolution Process More Efficient and Less Expensive, Part 2

July 16, 2014 — Beverley BevenFlorez-CDJ STAFF
John P. Ahler, on the Ahlers & Cressman PLLC blog, has posted the second part of his two-part series on Ways to Make the Construction Dispute Resolution Process More Efficient and Less Expensive. In this post, Ahler discussed “tips on how lawyers and stakeholders can make things move quicker in arbitration.” For example, Ahler looked at the arbitration clause in the initial contract, various options for arbitration, evidence decisions, and others. Read the court decision
Read the full story...
Reprinted courtesy of

Ahlers Cressman & Sleight PLLC Recognized Among The Top 50 Construction Law FirmsTM of 2023 by Construction Executive

June 26, 2023 — Ahlers Cressman & Sleight PLLC
ACS is proud to announce that it has once again been ranked among The Top 50 Construction Law Firms in the Construction Executive 2023 rankings. Since its first publication in 2003, Construction Executive magazine has served as the leading source for news, market developments, and business issues impacting the construction industry, and its articles are designed to help owners and top managers run a more profitable and productive construction business. Construction Executive established the rankings by asking over 600 hundred U.S. construction law firms to complete a survey. Constructive Executive’s data collection includes: 2022 revenues from the firm’s construction practice, the number of attorneys in the firm’s construction practice, percentage of the firm’s total revenues derived from its construction practice, the number of states in which the firm is licensed to practice, the year in which the construction practice was established, and the number of construction industry clients served during the fiscal year 2022. Read the court decision
Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

Contractors and Force Majeure: Contractual Protection from Hurricanes and Severe Weather

October 11, 2017 — Christopher G. Hill - Construction Law Musings
This week’s Guest Post Friday here at Musings welcomes back Clay Olsen. Clay is is an attorney at Harper Whitwell PLLC. The firm is located in Mississippi and South Carolina where they routinely represent the interests of construction. This season is not special as hurricanes are a part of life on the east coast and gulf shores. From New York to Louisiana, just about every state has seen massive property loss from hurricanes during the past ten years. We often see harsh outcomes for those on the coast living in finished homes. What happens to the unfinished and current projects awaiting completion? If you’re building on the coast, take a look at all of the following risk aversion mechanisms:

Builders Risk Insurance is necessary as is Coverage for named storms. Be sure to review the “excluded perils” or speak to your agent as hurricane coverage best not be omitted.

Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Offices of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Wilke Fleury Attorneys Recognized in “The Best Lawyers in America” & “Best Lawyers: One’s to Watch” 2024 Editions

September 06, 2023 — Wilke Fleury LLP
Congratulations 2024 Best Lawyers & Ones to Watch wf | Wilke Fleury David A. Frenznick, Kathryne E. Baldwin Daniel L. Egan, Adriana C. Cervantes, Jason G. Eldred Wilke Fleury is extremely proud to have two attorneys recognized in The Best Lawyers in America and three attorneys recognized in the Best Lawyers: Ones to Watch in America! Best Lawyers has been regarded by lawyers and the public for more than 40 years as the most credible measure of legal integrity and distinction in the United States. Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES