FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

New York Court Holds Insurer Can Rely on Exclusions After Incorrectly Denying Defense

March 26, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Reversing its prior decision, the New York Court of Appeals held that the insurer could raise policy exclusions regarding its duty to indemnify after it incorrectly denied its duty to defend. K2 Invest. Group, LLC v. Am. Guar. & Liab. Co., 2014 N.Y. LEXIS 201 (N.Y. Ct. App. Feb. 18, 2014). The insured was sued for legal malpractice. His insurer, American Guarantee, refused to defend and a default judgment was entered. The insured assigned his rights against American Guarantee to the plaintiffs. When the underlying plaintiffs sued, American Guarantee said coverage was barred by two exclusions. In a previous decision, K2 Inv. Group, LLC v. Am Guar. & Liab. Ins. Co., 21 NY 3d 284, the court held that American Guarantee's breach of its duty to defend prevented it from relying on policy exclusions. This, however, contradicted another case issued by the court, Servidone Const. Corp. v. Security Ins. Co. of Hartford, 64 N.Y 2d 419 (1985). Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Craig Holden Named Top 100 Lawyer by Los Angeles Business Journal

June 27, 2022 — Craig Holden - Lewis Brisbois
Los Angeles, Calif. (May 17, 2022) - Los Angeles Partner Craig Holden has been named to the Los Angeles Business Journal’s (LABJ) “Top 100 Lawyers” list, which recognizes the most impactful attorneys in the Los Angeles region for their ongoing efforts as outstanding legal professionals. The attorneys on the list were honored on May 12 at LABJ’s inaugural Top 100 Lawyers Awards at the ASU California Center. In the publication’s special section, LABJ Publisher Josh Schimmels noted that the attorneys on the Top 100 Lawyers list “have demonstrated exceptional legal skill and achievements across the full spectrum of responsibility, exemplary leadership and contributions to the Los Angeles community at large.” He also observed, “Considering the fact that the Los Angeles region has long been known for its status as a hub for legal [through] leaders and record-setting attorneys, being a standout in that field is particularly impressive.” Likewise, in discussing his inclusion on the list, Mr. Holden remarked, “I am honored to be included on this list with so many exceptional attorneys from the LA legal community.” Read the court decision
Read the full story...
Reprinted courtesy of Craig Holden, Lewis Brisbois
Mr. Holden may be contacted at Craig.Holden@lewisbrisbois.com

---

U.K. to Set Out Plan for Fire-Risk Apartment Cladding Crisis

March 01, 2021 — Emily Ashton & Olivia Konotey-Ahulu - Bloomberg
The U.K. government will set out its plans for stripping cladding from potentially unsafe apartment blocks, more than three years after a fire at London’s Grenfell Tower killed 72 people. Reports suggest Housing Secretary Robert Jenrick will set out a package of measures amounting to billions of pounds when he makes a statement to the House of Commons on Wednesday. Ministers announced a 1.6 billion pound ($2.2 billion) “safety fund” to remove dangerous cladding last year but Jenrick is expected to announce additional support on top of this. The price for the repairs could be as high as 15 billion pounds, according to a parliamentary committee last June. Reprinted courtesy of Emily Ashton, Bloomberg and Olivia Konotey-Ahulu, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

---

Scaffolding Purchase Suggests No New Building for Board of Equalization

July 30, 2014 — Beverley BevenFlorez-CDJ STAFF
Employees at California’s Board of Equalization spoke out against the Brown administration after the state purchased new scaffolding for the defect-riddled building, rather than finding a new facility, reported the Sacramento Bee. The existing scaffolding was leased for $10,000 per month, but the lease expired, prompting the purchase of new scaffolding for about $100,000. The board’s Chairman Jerome Horton stated “that while the change may make financial sense in the short term, it sends a signal that the Department of General Services intends to keep Equalization’s 2,200 or so employees in the troubled building,” according to the Sacramento Bee. Building problems include “toxic mold, defective elevators, leaking windows, corroded wastewater pipes, floods, and exterior glass panels that spontaneously break or pop off.” So far, $2.3 million has been paid “in connection with building-related employee injury claims” along with $60 million in repairs. However, an additional $115 million is estimated to completely fix the defects. Read the court decision
Read the full story...
Reprinted courtesy of

---

Doctrine of Merger Not a Good Blend for Seller of Sonoma Winery Property

April 15, 2015 — Kristen Lee Price and Lawrence S. Zucker II – Haight Brown & Bonesteel LLP
In Ram’s Gate Winery, LLC v. Joseph G. Roche, et al. (No. A139189 & A141090, filed 4/9/15) (Ram’s Gate), the California Court of Appeal for the First Appellate District held the doctrine of merger did not extinguish a seller’s contractual duty to disclose potentially hazardous seismic conditions on a Sonoma winery property. In Ram’s Gate, the buyer of the property filed a lawsuit alleging the seller failed to disclose information relating to earthquake issues prior to the close of escrow. In the parties’ “Purchase and Sales Agreement” (Purchase Agreement) the seller agreed to disclose any information known to it regarding “known geological hazards . . . soil reports . . . geotechnical reports” and other facts “having effect on the value of the ownership or use of the property.” The seller, however, argued this disclosure warranty did not survive the escrow period because it did not expressly provide for survival while other provisions in the Purchase Agreement did. Reprinted courtesy of Kristen Lee Price, Haight Brown & Bonesteel LLP and Lawrence S. Zucker II, Haight Brown & Bonesteel LLP Ms. Price may be contacted at kprice@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Contractors: A Lesson on Being Friendly

April 06, 2016 — Garret Murai – California Construction Law Blog
I know. You’re just trying to be friendly. Don’t. Particularly when you’re a contractor bidding on a public works project. Those dinners at swanky restaurants, tickets to The Jersey Boys, and all expense paid trips to the Napa Valley have a way of appearing less “friendly” in hindsight, and more like bribery, or as they say, “pay to play.” In Sweetwater Union High School District v. Gilbane Building Company, California Court of Appeals for the Fourth District, Case No. D067383 (February 24, 2016), three contractors, Gilbane Building Company (“Gilbane”), The Seville Group, Inc. (“Seville”) and Gilbane/SGI Joint Venture (“Gilbane/SGI”) (collectively “Contractors”) were sued by the Sweetwater Union School District (“District”) to void their contracts with the District and for disgorgement of all monies paid to them under Government Code section 1090 after it was discovered that the Contractors had engaged in a “pay to play” scheme involving several officials of the District. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Sometimes You Get Away with Unwritten Contracts. . .

July 28, 2018 — Christopher G. Hill - Construction Law Musings
I have spoken often regarding the need for a well written construction contract that sets out the “terms of engagement” for your construction project. A written construction contract sets expectations and allows the parties to the contract to determine the “law” of their project. An unwritten “gentleman’s agreement” can lead to confusion, faulty memories, and more money paid to construction counsel than you would like as we lawyers play around in the grey areas. One other area where the written versus unwritten distinction makes a difference is in the calculation of the statute of limitations. In Virginia, a 5 year statute of limitations applies to written contracts while a 3 year statute of limitations applies to unwritten contracts. This distinction came into stark relief in the case of M&C Hauling & Constr. Inc. v. Wilbur Hale in the Fairfax, Virginia Circuit Court. In M&C Hauling, M&C provided hauling services to the defendant through a subcontract with Hauling Unlimited in 2014, the last of which was in July. M&C provided over 2000 hours of hauling and provided time tickets (that were passed to Mr. Hale on Hauling Unlimited letterhead and signed by Mr. Hale or his agent) and an invoice stating the price term of $75.00 per hour. No separate written contract between M&C and Hauling Unlimited or Mr. Hale existed. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---