Seattle Washington Building Expert Directory

Force Majeure Under the Coronavirus (COVID-19) Pandemic

March 08, 2021 — Lindsay T. Watkins - Ahlers Cressman & Sleight PLLC
As COVID-19 disrupts work and life as we know it, the question many contractors have is what protections are available against the inevitable project impacts and delays? Generally, construction contracts require a contractor to timely perform work until project completion or potentially face damages (liquidated or actual) and possible termination. When events occur, however, that are beyond our control (such as a national pandemic), it is important to review and understand what contract provisions or avenues are available for potential relief. 1. Review Your Contract For A Force Majeure Provision. A “force majeure” contract provision is commonly included in construction contracts, service agreements, purchase orders, etc. It typically covers events or conditions that can be neither anticipated nor controlled. These provisions, however, will vary greatly from contract to contract and may not include the language “force majeure” but rather may be included in general delay or impact clauses. For example, some common provisions include:

Washington State Department of Transportation Clause (2018 Standard Specifications for Road, Bridge and Municipal Construction): The Contractor shall rebuild, repair, restore, and make good all damages to any portion of the permanent or temporary Work occurring before the Physical Completion Date and shall bear all the expense to do so, except damage to the permanent Work caused by: (a) acts of God, such as earthquake, floods, or other cataclysmic phenomenon of nature, or (b) acts of the public enemy or of governmental authorities; or (c) slides in cases where Section 2-03.3(11) is applicable; Provided, however, that these exceptions shall not apply should damages result from the Contractor’s failure to take reasonable precautions or to exercise sound engineering and construction practices in conducting the Work.

Read the court decision
Read the full story...
Reprinted courtesy of Lindsay T. Watkins, Ahlers Cressman & Sleight PLLC
Ms. Watkins may be contacted at Lindsay.Watkins@acslawyers.com

The Woodland Hills Office Secures a Total Defense Award on Behalf of their High-End Custom Home Builder Client!

June 04, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Partner Daniel Crespo and Associate Theresa Mallen secured a total defense award in arbitration. Our client is a high-end custom home builder with a decades-long flawless record of museum quality construction. Our client was accused of performing substandard construction and the homeowners asserted a multiple million-dollar cost of repair. We took a zero-liability position and argued that the alleged defects were not defects at all but were rather mere reflections of an incomplete project. In sum, our client was forced to terminate the contract and cease construction due to the homeowners’ failure to make progress payments as they became due. The arbitration endured 16 days of testimony scattered over the course of 7 months. Ultimately, the arbitrator ruled that there were no construction defects at the project and that the homeowners “shall take nothing.” The arbitrator also ruled in favor of our client on its affirmative claim for monies owed by the homeowners’ breach of contract plus interest. A total victory for our client. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Client Alert: Design Immunity Affirmative Defense Not Available to Public Entities Absent Evidence of Pre-Accident Discretionary Approval of the Plan or Design

April 15, 2014 — R. Bryan Martin & Melinda M. Carrido – Haight Brown & Bonesteel LLP
On April 8, 2014, in Martinez v. County of Ventura, Case No. B24476, the Second Appellate District of the California Court of Appeal reversed the jury's defense verdict for the County of Ventura, holding that the County's evidence in support of its Design Immunity defense to a public property dangerous condition claim was insufficient as a matter of law. Plaintiff filed suit against the County of Ventura (the "County") after sustaining paraplegic injuries when his motorcycle struck an asphalt berm abutting a raised drain (the top-hat drain system) on a road in the County. The drain system consisted of a heavy steel cover on three legs elevated eight to ten inches off the ground, with a sloped asphalt berm to channel water into the drain. Plaintiff alleged that the top-hat drain system constituted a dangerous condition of public property pursuant to California Government Code section 835. Under this Section, a public entity is liable for "injury proximately caused by a dangerous condition of its property if the condition created a reasonably foreseeable risk of the kind of injury sustained, and the public entity had actual or constructive notice of the condition a sufficient time before the injury to have taken preventative measures." The jury found the top-hat drain system constituted a dangerous condition of public property. Reprinted courtesy of R. Bryan Martin, Haight Brown & Bonesteel LLP and Melinda M. Carrido, Haight Brown & Bonesteel LLP Mr. Martin may be contacted at bmartin@hbblaw.com; Ms. Carrido may be contacted at mcarrido@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Recognized in 2022 U.S. News – Best Lawyers “Best Law Firms”

November 15, 2021 — Traub Lieberman
Traub Lieberman has been listed in the 2022 U.S. News – Best Lawyers “Best Law Firms”. The firm has been named as Metropolitan Tier 2 in St. Petersburg, FL for Appellate Practice and as Metropolitan Tier 2 in West Palm Beach, FL for Personal Injury Litigation – Defendants. The U.S. News – Best Lawyers® “Best Law Firms” rankings are based on a rigorous evaluation process that includes the collection of client and lawyer evaluations, peer review from leading attorneys, and review of additional information provided by law firms as part of the formal submission process. Please click here to learn more about the methodology for selection. Reprinted courtesy of Traub Lieberman Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Eastern District of Pennsylvania Confirms Carrier Owes No Duty to Defend Against Claims for Faulty Workmanship

April 05, 2021 — Anthony L. Miscioscia & Marianne Bradley - White and Williams LLP
On March 17, 2021, the Eastern District of Pennsylvania issued its decision in Estate Chimney & Fireplace v. IFG Companies & Burlington Insurance Company, 2021 U.S. Dist. LEXIS 50360 (E.D. Pa. March 17, 2021), finding that an insurance carrier had no duty to defend its insured where the allegations in the underlying litigation involved claims of faulty workmanship. Estates Chimney & Fireplace, LLC (Estates Chimney) had performed inspections and replaced chase covers for a number of chimneys in a condominium complex. Chase covers are pieces of metal, which are placed over chimneys in order to keep out environmental elements. Several condominium owners sued Estates Chimney, alleging that Estates Chimney had improperly installed, then improperly replaced, their chimney caps, which caused their chimneys to cease working properly. As a result, the underlying plaintiffs allegedly incurred costs to repair or replace the chimney caps and chimneys. Estates Chimney sought coverage from its carrier, who denied coverage based upon its determination that the claims in the underlying lawsuits arose out of faulty workmanship, which did not result in damage to the property of a third party. Estates Chimney filed a declaratory judgment action, seeking a declaration that it was entitled to coverage under the policy. Both parties moved for summary judgment, and the Eastern District ruled in favor of the carrier. Reprinted courtesy of Anthony L. Miscioscia, White and Williams LLP and Marianne Bradley, White and Williams LLP Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com Ms. Bradley may be contacted at bradleym@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

The Case For Designers Shouldering More Legal Responsibility

November 21, 2018 — Richard Korman - Engineering News-Record
Ujjval Vyas is dignified, articulate and persistent. In past years he earned a law degree and a PhD where his thesis concerned Philip Johnson and architectural modernism. He is a founder of a hydrogen energy company. He is also leading a crusade, largely by himself, advocating that designers should be held to a "clients come first" approach applied to other professionals—an idea that would burden engineers and architects with the weight of vastly increased legal liability. The reactions to his ideas in the past have ranged from scornful to sympathetic. Read the court decision
Read the full story...
Reprinted courtesy of Richard Korman, ENR
Mr. Korman may be contacted at kormanr@enr.com

Construction Defect Bill a Long Shot in Nevada

June 28, 2013 — CDJ STAFF
Construction defect reform may still be on the table in Nevada, according to the Reno Gazette Journal. Assembly member Pat Hickey got a committee hearing for Assembly Bill 504 on Sunday. The bill is backed by the construction industry and opposed by trial lawyers. Hickey told the Assembly Commerce and Labor committee that “this bill is not perfect, I would like for it to do more,” and said that without changes Nevada will “continue to reward litigation over resolution.” AB504 would, among other provisions, provide some protection to subcontractors from the actions of general contractors, though Ira Hansen, an assembly member from Sparks and the owner of a plumbing business, called it a “backhanded slap.” The Gazette noted that similar language pertaining to subcontractors was in AB367, which is sponsored by Democrats. Hickey and Hansen are both Republicans. Read the court decision
Read the full story...
Reprinted courtesy of

Lien Actions Versus Lien Foreclosure Actions

June 02, 2016 — David R. Cook Jr. – AHHC Construction Law Blog
The lawsuits required to perfect and foreclose upon a lien have confused lien claimants and their attorneys for years. This confusion was recently demonstrated in a recent case entitled Founders Kitchen and Bath, Inc. v. Alexander, No. A15A1262, 2015 WL 6875026 (Ga. App. 2015). In the case, the trial court granted an owner’s motion for summary judgment against a subcontractor that sought to foreclose on its materialman’s lien. In deciding to reverse the trial court’s decision, the Court held that issues of material fact still existed as to whether the owner and subcontractor were in privity of contract. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES