Fairfield Connecticut Building Expert Directory

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Corps Proposes $4.6B Plan to Steel Miami for Storm Surge

June 22, 2020 — Pam Radtke Russell - Engineering News-Record
A $4.6-billion U.S. Army Corps of Engineers proposal to protect Miami from future storm surge, largely by building massive sea walls and elevating infrastructure systems, is the latest of such plans the agency has developed for East Coast communities. Pam Radtke Russell, Engineering News-Record Ms. Russell may be contacted at Russellp@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

It’s Time to Start Planning for Implementation of OSHA’s Silica Rule

May 03, 2017 — Nathan Owens & Louis “Dutch” Schotemeyer – Newmeyer & Dillion LLP
Getting a notification from OSHA that your company is being investigated for a health or safety violation is an unwanted disruption to your business that could lead to a hefty monetary fine. Worse yet, if your company is found to have committed multiple violations, OSHA may categorize your company as a severe violator, which makes you subject to follow-up inspections. In the last 6 years, OSHA has added 520 companies to the Severe Violator Enforcement Program - sixty percent of which are in the construction industry. New OSHA regulations impacting the construction industry may result in more companies facing investigations and fines, or worse yet, laying off workers and unable to compete for new work. In 2013, OSHA proposed a new mandate to reduce silicosis in workers. The mandate, which was revised multiple times before being made final in March 2016, requires that employers ensure their workers are exposed to no more than 50 micrograms of crystalline silica in an eight hour period (down from the current standard of 250 micrograms). Under the new mandate, employers are also held to heightened reporting requirements, protective measures and medical testing for employees with extended exposure to silica. In the construction industry alone, OSHA believes the new mandate will prevent 1,080 cases of silicosis and more than 560 deaths. Builder and trade groups believe the new mandate will result in the loss of tens of thousands of jobs and cost the building industry billions of dollars. The National Association of Home Builders estimates that the Silica Rule will cost homebuilders $1,500 per start. While the two sides mount their arguments and seek support, how to implement the rule and its long term feasibility are still contested questions. Recognizing the challenges employers will have with the heightened requirements of the Silica Rule, OSHA just announced that enforcement is being delayed 90 days to develop additional guidance for implementation of the rule in the construction industry. The new start date for enforcement of the Silica Rule is September 23, 2017.* Many in the industry are hoping the Trump administration repeals the Silica Rule like they have “blacklisting” and the Volks rule. However, until that happens, OSHA expects your company to implement processes to ensure compliance by the new start date. *The Silica Rule was adopted by Cal/OSHA in August 2016 even though Cal/OSHA’s own silica standard had been in place since 2008. Cal/OSHA adopted the federal standard with the June 23, 2017 effective date; however; in an effort to synchronize with OSHA, Cal/OSHA recently announced that the effective date in California will also be September 23, 2017. Nathan Owens is the Las Vegas Managing Partner of Newmeyer & Dillion, and represents businesses and individuals operating in a wide array of economic sectors including real estate, construction, insurance and health care in all stages of litigation in state and federal court. For questions related to the OSHA and the Silica Rule, you can reach him at Nathan.Owens@ndlf.com. Louis “Dutch” Schotemeyer is an associate in Newmeyer & Dillion’s Newport Beach office. Dutch’s practice concentrates on the areas of business litigation, labor and employment law, and construction litigation. For questions related to OSHA or the Silica Rule, you can reach him at Dutch.Schotemeyer@ndlf.com Read the court decision
Read the full story...
Reprinted courtesy of

Corps Releases Final Report on $29B Texas Gulf Coast Hurricane Defense Plan

October 11, 2021 — James Leggate - Engineering News-Record
A $28.87 billion plan to protect the Texas Gulf Coast’s residents and infrastructure against hurricanes and storm surge with a series of coastal storm risk management and ecosystem restoration projects took a step closer to reality Sept. 10 with the release of a final feasibility report and final environmental impact statement from the U.S. Army Corps of Engineers and Texas General Land Office (GLO). Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at https://www.enr.com/leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Nation’s Top Court Limits EPA's Authority in Clean Air Case

July 25, 2022 — Pam McFarland - Engineering News-Record
The U.S. Supreme Court has limited the ability of the U.S. Environmental Protection Agency to regulate power plant greenhouse gas emissions, but the ruling was more limited than some environmental advocates had feared. Reprinted courtesy of Pam McFarland, Engineering News-Record Ms. McFarland may be contacted at mcfarlandp@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Another Reminder that Your Construction Contract is Only as Good as Those Signing It

December 17, 2024 — Christopher G. Hill - Construction Law Musings
Here at Construction Law Musings, we beat the constant drum that “the contract is king” and “draft a good and well-worded construction contract” consistently. As a Virginia construction attorney, I stand by these statements and fully endorse a well-written construction contract. Such a contract will set expectations and provide the rules for your deal (particularly in the commercial context). Without this solid foundation (yes, I see the potential construction pun), when there are issues on the job site, there will be no baseline for how to resolve those issues. That said, I am also reminded on an almost daily basis that humans interact with these contracts. People negotiate the contracts and are the main forces that drive the success (or failure) of the construction project. Money is involved (often a lot of it) and there can at times be temptations to try and squeeze one last dollar out of the job despite what the contract says. Even the strongest contract cannot act as real-time protection against one party that refuses to comply with the contract and its performance or payment terms. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Deferred Maintenance?

December 17, 2024 — Daniel Lund III - Lexology
A Tennessee-based “outsourced maintenance vendor” to an engine company filed suit in Louisiana state court seeking to recover nearly $150,000 on “open account,” for work previously performed. The engine company removed the case to the Federal District Court in New Orleans and asserted as a defense that the vendor lacked a proper Louisiana construction contractor’s license. The engine company filed a motion for summary judgment based on the defense. Under Louisiana law, a contract between parties is “absolutely null”--considered to have never existed--where one of the parties performed services without a required Louisiana contractor’s license, and the combined work reaches a $50,000 threshold. The engine company asserted that the vendor performed typical construction contractor work, including plywood flooring, applied epoxy to concrete flooring, erected part of a commercial carport, undertook certain heavy demolition, and installed fences, guardrails, and wire racks. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Hundreds of Snakes Discovered in Santa Ana Home

February 04, 2014 — Beverley BevenFlorez-CDJ STAFF
404 Snakes—more than half dead—were discovered after a “nearly daylong search” in a home in Santa Ana, California, reported the Los Angeles Times. “Over the past few months, neighbors called authorities about the foul odor,” claimed the Orange County Register. “They thought it was trash. Then Jehovah’s Witnesses knocked on the door.” Concerned that someone might have died, they called the police. William Buchman, the homeowner, “identified as a snake breeder, was arrested on suspicion of animal cruelty, a felony,” according to the Los Angeles Times. Police wore gas masks and “clutched Tasers” as they entered the home. “Rats scampered over furniture and scores of clear plastic boxes holding the snakes lined the walls.” The Orange County Register claimed that up until recently Bachman was a “regular joe.” A neighbor said, “Let me tell you, Bill was a nice guy, outspoken, knowledgeable. He talked to my grandkids about school.” According to the Los Angeles Times, Buchman’s mother died in 2011, which appeared to “have affected him profoundly.” Read the full story at The Los Angeles Times... Read the full story at The Orange County Register... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES