Seattle Washington Building Expert Directory

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Where-Forum Art Thou? Is the Chosen Forum Akin to No Forum at All?

May 30, 2022 — William Doerler - The Subrogation Strategist
Many courts enforce forum selection clauses in contracts between parties. In W. Bay Plaza Condo. Ass’n v. Sika Corp., No. 3D21-1834, 2022 Fla. App. LEXIS 1637 (W. Bay Plaza), the Court of Appeal of Florida, Third District (Court of Appeal) answered the question of whether a mandatory forum selection clause in a manufacturer’s warranty was enforceable as to a condominium association, who was a non-signatory. The trial court enforced the forum selection clause – calling for litigation in New Jersey rather than Florida – and the Court of Appeal affirmed the ruling. As stated in W. Bay Plaza, in late 2013 and early 2014, West Bay Plaza Condominium Association (W.B. Plaza Condo. Ass’n) contracted with Built Right Installers International Corporation, R.J. Miranda Consultants, Inc. and UCI Engineering Inc. (collectively, the Construction Defendants) to have repairs done to the exterior of the property. In 2016, Sika Corporation (Sika), a New Jersey corporation, gave a five-year warranty to W.B. Plaza Condo. Ass’n for three sealant products used to repair the garage at the property. In 2019, W.B. Plaza Condo. Ass’n sued the Construction Defendants for breach of contract and professional negligence. Subsequently, W.B. Plaza Condo. Ass’n amended its complaint and filed a claim against Sika, alleging that Sika breached its warranty because its products failed to provide a watertight barrier. Sika filed a motion to dismiss the action, alleging that Florida was an improper venue because its’ warranty contained a mandatory forum selection clause. W.B. Plaza Condo. Ass’n argued that it was not bound by the forum selection clause because it was a non-signatory to the warranty and, even if it was bound by the clause, there were compelling reasons not to enforce it. Read the court decision
Read the full story...
Reprinted courtesy of William Doerler, White and Williams LLP
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com

Estimate Tops $5.5B for Cost of Rebuilding After Maui Fires

August 21, 2023 — James Leggate - Engineering News-Record
Rebuilding after wildfires on the island of Maui in Hawaii could cost more than $5.5 billion, according to a preliminary assessment prepared by the University of Hawaii Pacific Disaster Center and local officials. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Quick Note: Insurer Must Comply with Florida’s Claims Administration Act

September 14, 2017 — David Adelstein - Florida Construction Legal Updates
As an insured, know YOUR rights under Florida’s Claims Administration Act (Florida Statute s. 627.426). I wrote an article on this exact topic. If a third-party claim is asserted, or in the process of being asserted, against you, do yourself a favor and consult a lawyer that can assist you with preserving your insurance coverage rights. You pay liability insurance premiums for a reason so make sure you are not doing anything that could jeopardize rights under applicable insurance policies. A liability insurer must comply with the Claims Administration Act if it wants to deny coverage based on a coverage defense (e.g., the insured’s failure to cooperate with the insurer). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Fifth Circuit Reverses Insurers’ Summary Judgment Award Based on "Your Work" Exclusion

November 18, 2011 — Tred R. Eyerly - Insurance Law Hawaii

Application of the facts to the "your work" exclusion was the key to resolving coverage issued in Am. Home Assurance Co. v. Cat Tech L.L.C., 2011 U.S. App. LEXIS 21076 (5th Cir. Oct. 5, 2011).

Ergon Refining, Inc. hired Cat Tech L.L.C. to service a hydrotreating reactor. In January 2005, Cat Tech replaced certain parts in the reactor. After Cat Tech finished the job and left, Ergon noticed a high pressure drop in the reactor, forcing it to be shut down. Cat Tech returned in February 2005, removed, repaired and replaced the damaged parts, and loaded new parts. After completion, a second large pressure drop occurred during the reactor’s start-up process. The reactor was shut down until October 2005, when Ergon hired a different contractor to perform the repair work. Additional damage to the reactor was found.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

Missouri Legislature Passes Bill to Drastically Change Missouri’s “Consent Judgment” Statute

August 10, 2021 — Jason Taylor - Traub Lieberman Insurance Law Blog
On June 29, 2021, Missouri Governor Mike Parson signed SB-HB 345 into law, which will drastically change Section 537.065 of the Missouri Revised Statutes. Section 537.065 provides an insured who has been denied insurance coverage a statutory mechanism to settle certain tort claims through an agreement akin to a consent judgment. Typically referred to as a “065 Agreement,” the statute allows a plaintiff and insured-tortfeasor to settle a claim for damages and specify which assets are available to satisfy the claim, typically the tortfeasor’s available insurance policy. In the past, such agreements were often accomplished without the insurer’s participation or even its knowledge. Under such agreements, the insured-tortfeasor assigns all rights to the insurance policy to the plaintiff and agrees not to contest the issues of liability or damages. In exchange the plaintiff agrees not to execute any judgment against the insured. The parties conduct what amounts to an uncontested and often “sham” trial resulting in a judgment far in excess of any actual damages or applicable policy limits had the case been contested. In a subsequent proceeding to collect on the judgment, the tortfeasor’s insurer is bound by the determinations of liability and damages made in the underlying action. This statutory framework presented plenty of opportunities for abuse. In 2017, the statute was amended in order to address some of those issues, including a requirement that the insured provide notice of a settlement demand under Section 065 and providing insurers a limited right to intervene in the tort action before liability and damages have been determined. Ostensibly, the intent of the 2017 amendments was to reduce the number of large and uncontested judgments and allow the insurance carrier an opportunity to continue litigating the injured party’s claim where the insured has no incentive or is contractually prohibited from doing so. Yet, creative plaintiff’s attorneys found several “loopholes” around these changes, most prominently, by moving their disputes from state court to binding arbitration and dispensing with notice to the insurer altogether, or at least until after the arbitration has concluded. Read the court decision
Read the full story...
Reprinted courtesy of Jason Taylor, Traub Lieberman
Mr. Taylor may be contacted at jtaylor@tlsslaw.com

ASHRAE Approves Groundbreaking Standard to Reduce the Risk of Disease Transmission in Indoor Spaces

July 10, 2023 — ASHRAE
ATLANTA, June 27, 2023 (GLOBE NEWSWIRE) -- ASHRAE announced the approval for publication of its highly anticipated standard to reduce the risk of airborne infectious aerosol transmission in buildings, bringing numerous benefits to occupants and promoting healthier environments. ASHRAE Standard 241, Control of Infectious Aerosols establishes minimum requirements to reduce the risk of disease transmission by exposure to infectious aerosols in new buildings, existing buildings, and major renovations. Infectious aerosols are tiny, exhaled particles that can carry pathogens that cause infections or disease. These particles are so small that they can remain in the air for long periods of time. Use of this standard could reduce exposure to the SARS-COVID-2 virus, which causes COVID-19, the flu virus and other pathogens. Standard 241 provides requirements for many aspects of air system design, installation, operation, and maintenance. Standard 241 available now for presale in the ASHRAE Bookstore. About ASHRAE Founded in 1894, ASHRAE is a global professional society committed to serve humanity by advancing the arts and sciences of heating ventilation, air conditioning, refrigeration, and their allied fields. For more information and to stay up-to-date on ASHRAE, visit ashrae.org and connect on Instagram, LinkedIn, Facebook, Twitter and YouTube. Read the court decision
Read the full story...
Reprinted courtesy of

Modified Plan Unveiled for Chicago's Sixth-Tallest Tower

February 15, 2018 — Jeff Yoders – ENR
The Chicago Plan Commission on Jan. 18 approved a $700-million development that, as presented, would include the city’s sixth-tallest building. Read the court decision
Read the full story...
Reprinted courtesy of Jeff Yoders, Engineering News-Record
Mr. Yoders may be contacted at yodersj@enr.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES