Delays and Suspension of the Work Under Fixed Price Government Contract
July 22, 2024 —
David Adelstein - Florida Construction Legal UpdatesHere is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors.
In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Court Again Defines Extent of Contractor’s Insurance Coverage
November 26, 2014 —
Craig Martin – Construction Contractor AdvisorThe ever changing landscape of insurance coverage for contractors continues to be clarified in Texas. The Fifth Circuit Court of Appeals applied Texas law in Crownover v. Mid-Continent Casualty Company, concluding that contractors do have insurance coverage to cover claims that a project was not constructed in a good and workmanlike manner.
In this case, the Crownovers hired a contractor to build a house. The contract contained a warranty-to-repair clause. Shortly after construction was completed, cracks began to appear in the walls and foundation, and there were problems with the heating and air conditioning system. The Crownovers demanded that the contractor repair the problems and the contractor refused. The Crownovers brought an arbitration proceeding against the contractor and prevailed, obtaining a judgment that the contractor must pay for repairs to the foundation and HVAC system. The contractor then filed for bankruptcy and the bankruptcy court allowed the Crownovers to pursue their claim against the contractor’s insurer.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
Developer Sues TVA After It Halts Nuke Site Sale
December 19, 2018 —
Mary B. Powers - Engineering News-RecordThe multibillion-dollar completion of a nuclear unit at the Tennessee Valley Authority’s unfinished 1,260-MW Bellefonte plant in Alabama is in limbo after the federal power producer refused to complete its sale to Nuclear Development LLC, which has since filed a breach of contract complaint in federal district court.
Read the court decisionRead the full story...Reprinted courtesy of
Mary B. Powers, ENRENR may be contacted at
ENR.com@bnpmedia.com
A Property Tax Exemption, Misapplied, in Texas
June 18, 2019 —
Anthony B. Cavender - Gravel2GavelIn an important ruling for Texas businesses, the Texas Supreme Court has unanimously ruled that the TCEQ misapplied the Texas property tax’s exemption for specified pollution control equipment.
Since 1993, the Texas Constitution has included a provision which authorizes the Texas Legislature to exempt from ad valorem taxation “all or part of real and personal property used … wholly or partly … for the control or reduction of air, water or land pollution.” This provision is implemented by Section 11.31 of the Texas Tax Code, which is administered by the Texas Commission on Environmental Quality. (See the rules at Title 30, Chapter 17 of the Texas Administrative Code.) If the Executive Director of the TCEQ determines that the equipment is used wholly or partly for pollution control, he issues a “positive use determination”; in the event it does not, the Executive Director issues a “negative use determination and rejects the application for the exemption. In 2007, Section 11.31 was amended at 11.31 (k) to list several items of equipment that are presumed to be pollution-control equipment, including “heat recovery steam generators” or HRSGs. This equipment is used by powerplants to reduce nitrogen oxide emissions that are the product of generation of electricity. Several applications were submitted to the TCEQ by the Brazos Electric Power Cooperative, seeking a tax exemption for its HRSG units. In July 2012, the TCEQ denied these applications, with the flat declaration that HRSGs are not pollution-control equipment—“they are used solely for production.” The Brazos Cooperative sued the Commission, and on May 3, 2019, in the case of Brazos Electric Power Cooperative, Inc. v. TCEQ, the Texas Supreme Court issued a unanimous opinion reversing the Commission, and the lower court (the Eight Court of Appeals, sitting in El Paso) that affirmed the Commission’s action.
Read the court decisionRead the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
Congratulations to BWB&O for Ranking #4 in Orange County Business Journal’s 2023 Book of Lists for Law Firms!
April 10, 2023 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPBremer Whyte Brown & O’Meara, LLP is excited to announce that Orange County Business Journal has ranked our firm as a top 4 law firm in the 2023 Book of Lists!
BWB&O continues to grow and strives to provide a consistently excellent work product and solution-oriented approach to our clients’ legal issues, coupled with hiring, and retaining diverse and outstanding lawyers, all while providing an outstanding work life balance/integration. We foster a culture that embraces family, friendship, and fun while also supporting individual growth.
Read the court decisionRead the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Winning Attorney Fees in Litigation as a California Construction Contractor or Subcontractor
December 27, 2021 —
William L. Porter - Porter Law GroupThe General Rule in California: The Winner Does NOT Receive Attorney Fees and Costs:
There is a common misconception that court decisions require the loser in a lawsuit to reimburse the winner for the fees and costs incurred during the lawsuit. Reliance on this misconception in developing a legal strategy for dealing with disputes is a serious strategic error. Where the legal issue is, for example, “breach of contract,” the general rule in California is that there are only two methods by which the winning litigant will be awarded the attorney fees and costs incurred in bringing or defending the lawsuit. The first of these is if the contract in question contains an effective attorney fee clause specifically providing that the prevailing party will recover their attorney fees and costs. The second is if there is a statute on point which provides that the prevailing party will be awarded those fees and costs. The general rule in California is that each party pays their own attorney fees and costs, unless there is an independent legal basis that provides otherwise. This is known as the “American Rule,” used throughout most of the country.
The Issue is Important Because Spending More Money Than You Can Be Awarded is a Losing Strategy:
The importance of whether the prevailing party in a lawsuit will be awarded their fees and costs cannot be underestimated. The party contemplating whether to bring a lawsuit must seriously consider whether it is even worth the trouble. In many cases, unless the one bringing the lawsuit (the “plaintiff”) is entitled to be reimbursed for the considerable attorney fees and costs incurred in bringing the case, it is just not worth doing so. There is no point spending $50,000 on attorneys on a $40,000 claim unless the plaintiff can be awarded both the $40,000 and the $50,000 if the plaintiff wins. Unless fees and costs are awarded, the plaintiff will still be out $10,000 in the very best of cases. For a party sued (the “defendant”) a similar situation arises in that the defendant faces the reality that it may be less expensive to just pay on a frivolous or false claim than to fight it. Either scenario is unsatisfactory. On the whole, it is beneficial to have an attorney fee clause in a contract when either a plaintiff or a defendant must vindicate its rights. Both deserve to be fully compensated to achieve justice. It is also beneficial to have an attorney fee clause in a contract to encourage the one who is at fault to resolve the case rather than risk paying the fees and costs of the other party who is likely to win the case. In either case, the presence of an attorney fee clause facilitates the party in the right and encourages resolution outside of litigation. These are admirable societal goals.
Read the court decisionRead the full story...Reprinted courtesy of
William L. Porter, Porter Law GroupMr. Porter may be contacted at
bporter@porterlaw.com
Motion to Dismiss Insureds' Counterclaim on the Basis of Prior Knowledge Denied
September 04, 2018 —
Tred R. Eyerly - Insurance Law HawaiiThe insurer unsuccessfully moved to dismiss portions of the insureds' counterclaim based upon prior knowledge. Hudson Spec. Ins. Co. v. Talex Enter., 2018 U.S. Dist. LEXIS 105598 (S. D. Miss. June 25, 2018).
The insureds' building collapsed in McComb, Mississippi. Pubic utilities were damaged and traffic disrupted. The City sued the insured, alleging that the building collapsed because there was too much water gathered on its roof. The City further alleged that the insureds knew too much water was on the roof because they had been told by someone hired to clean the drain that it was clogged and by a contractor that the roof was so damaged that it could not safely be repaired.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Nevada Bill Aims to Reduce Legal Fees For Construction Defect Practitioners
March 21, 2011 —
CDJ STAFFAssemblyman Ira Hansen and twelve additional members of Nevada’s Assembly are sponsoring Assembly Bill 285. AB 285 Revises provisions governing an award of attorney’s fees in causes of action for constructional defects. Existing law generally provides that a claimant may recover reasonable attorney’s fees as part of the claimant’s damages in a cause of action for constructional defects. (NRS 40.655)
This bill removes this provision and instead authorizes a court to award reasonable attorney’s fees to a prevailing party involved in such a cause of action if an independent basis for the award exists pursuant to existing law which authorizes a court to award attorney’s fees in certain circumstances, or Rule 68 of the Nevada Rules of Civil Procedure, which provides for the payment of reasonable attorney’s fees by an offeree who rejects an offer and subsequently fails to obtain a more favorable judgment.
In an AP report published in Business Week it is suggested that the target objective of legislators centers on what it refers to as Nevada’s "Rampant construction defect lawsuits".
According to Business Week "The suits bring in hundreds of millions of dollars for lawyers and have put construction companies out of business. Hansen says fewer construction firms mean higher prices for Nevada consumers."
Click Here To Read Full Text and Revisions of Assembly Bill 285
Read the court decisionRead the full story...Reprinted courtesy of
