CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract

May 10, 2022 — Ted Senet & Christopher Trembley - Gibbs Giden
California local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount. In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor. As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:

Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.

Reprinted courtesy of Ted Senet, Gibbs Giden and Christopher Trembley, Gibbs Giden Mr. Senet may be contacted at tsenet@gibbsgiden.com Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com Read the court decision
Read the full story...
Reprinted courtesy of

---

How Pennsylvania’s Supreme Court Decision Affects Coverage of Faulty Workmanship Claims

March 31, 2014 — Beverley BevenFlorez-CDJ STAFF
Darin J. McMullen of the firm Anderson Kill explained how a recent opinion by the Pennsylvania Supreme Court allows “Pennsylvania policyholders” to “more confidently challenge insurance companies’ denials of faulty workmanship claims.” The decision in Indalex Inc. v. National Union Fire Ins. Co. of Pittsburgh, PA, 2013 Pa. Super 311 (Dec. 3, 2013) “reverses a nearly decade-long trend of Pennsylvania decisions narrowing the scope of insurance coverage for construction and defect-related claims under commercial general liability insurance policies,” according to McMullen. “Equally important, the Indalex ruling dealt a blow to the insurance industry’s continual efforts to win overbroad expansion of the rulings in Kvaerner Metals Div. of Kvaerner U.S., Inc. v. Commercial Union Ins. Co., Millers Capital Ins. Co. v. Gambone Bros. Dev. Co., and Erie Ins. Exchange v. Abbott Furnace Co., which found that claims of faulty workmanship in some circumstances may not constitute coverage-triggering ‘occurrences.’” Read the court decision
Read the full story...
Reprinted courtesy of

---

Ohio Supreme Court Holds No Occurence Arises from Subcontractor's Faulty Workmanship

January 09, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Ohio Supreme Court bucked the modern trend by finding that there was no coverage under CGL policy's the subcontractor's exception for faulty workmanship claimed against the insured. Ohio N. Univ. v. Charles Constr. Servs. 2018 Ohio LEXIS 2375 (Ohio Oct. 9, 2018). The University contracted with Charles Construction Services, Inc. to build a new luxury hotel and conference center on campus. After work was completed, the University discovered extensive water damage from hidden leaks that it believed were caused by the defective work of Charles Construction and its subcontractors. Repairs were made at the cost of $6 million. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

In Contracts, One Word Makes All the Difference

July 21, 2018 — Christopher G. Hill - Construction Law Musings
Here at Musings, I sometimes feel as if I am beating the “contract is king” drum to death. However, each time I start to get this feeling, a new case out of either the Virginia state courts or the Fourth Circuit Court of Appeals here in Richmond reminds me that we all, lawyers and contractors alike, need to be reminded of this fact on a regular basis. The terms written into a construction contract (or any other contract for that matter) will control the outcome of any dispute in just about every case. A recent 4th Circuit case takes this to the extreme in pointing out the the choice which of two tiny words can change the entire set of procedural rules and even the courthouse in which your dispute will be decided. In FindWhere Holdings Inc. v. Systems Env. Optimization LLC, the Fourth Circuit looked at a forum selection clause found in a contract between the parties. In this case, the clause stated that any dispute would be litigated in the courts “of the State of Virginia.” When the defendants tried to remove the case from Virginia state court to the Eastern District of Virginia federal courts, the federal court remanded the case, sending it back to the Circuit Court of Loudoun County, Virginia. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Sustainable, Versatile and Resilient: How Mass Timber Construction Can Shake Up the Building Industry

April 10, 2023 — Cait Horner, Adam J. Weaver & Allan C. Van Vliet - Gravel2Gavel Construction & Real Estate Law Blog
Design professionals, real estate developers and builders alike are advocating for a relatively new way of using one of the world’s oldest building materials—wood—in large-scale commercial and residential construction projects. Mass timber, or structural timber, touts such benefits as carbon reduction and seismic durability—all with a lower construction time. With ESG on the minds of clients, investors and tenants, mass timber projects present an attractive construction option for the integration of sustainable resources and these various benefits. The most common and popular form of mass timber, cross-laminated timber (CLT), has been recently gaining popularity in the U.S. after widespread adoption in Europe over the past 20 years. CLT consists of layers of trimmed and kiln-dried lumber boards, usually three, five or seven across, stacked and glued crosswise at 90-degree angles. These stacked lumber boards create large slabs that are used to build floors, walls and ceilings—put those fabricated pieces together, and you have a whole building constructed of CLT. Reprinted courtesy of Cait Horner, Pillsbury, Adam J. Weaver, Pillsbury and Allan C. Van Vliet, Pillsbury Ms. Horner may be contacted at cait.horner@pillsburylaw.com Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com Mr. Van Vliet may be contacted at allan.vanvliet@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

New WOTUS Rule

November 13, 2023 — David R. Cook Jr. - Autry, Hall & Cook, LLP
The U.S. Army Corps of Engineers amended the regulation to conform the definition of “waters of the United States” to conform to the Supreme Court’s ruling in Sackett v. Environmental Protection Agency. See the prior blog post about the Supreme Court’s ruling: Sackett v. Environmental Protection Agency – Construction and Utility Law | Atlanta | AHC Law Federal Register :: Revised Definition of “Waters of the United States”; Conforming Reprinted courtesy of David R. Cook Jr., Autry, Hall & Cook, LLP Mr. Cook may be contacted at cook@ahclaw.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Needs Collaborative Planning

January 20, 2020 — Aarni Heiskanen - AEC Business
What makes construction different from manufacturing is its dynamic nature. Unlike a systemized production plant, a construction site is a mesh of interconnected processes that are far from optimized. The traditional top-down planning practice does not solve problems on the construction site, as recent research reveals. Making planning collaborative is a necessary step in making construction less wasteful. Everybody in the industry has felt frustration with inefficiencies in construction, but seeing the data is still disconcerting. I’ve had the pleasure of attending several workshops organized by the Finnish Aalto University’s research teams. These eye-opening events both revealed how much waste we have in construction today and suggested solutions to this problem. Four Aalto University graduate students shared insights from their research at a workshop of the Waste Workgroup of the Building 2030 consortium. They focused on projects where takt production, a lean construction method, had been used. Takt production breaks the work down into equally timed work batches and typically shortens project lead time considerably—up to 50%. However, even these well-planned projects included waste and unnecessary movement, as the researchers found out. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

California Expands on Scope of Coverage for Soft Cost Claims

February 14, 2023 — Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.
The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage. The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project. As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.
Ms. Rabiyan may be contacted at CRabiyan@sdvlaw.com

---