Cambridge Massachusetts Building Expert Directory

Negligent Misrepresentation Claim Does Not Allege Property Damage, Barring Coverage

December 20, 2017 — Tred Eyerly - Insurance Law Hawaii
The Tennessee Court of Appeals reversed the trial court's determination that the seller's alleged negligent misrepresentation regarding the propensity of the property to flood was covered. Erie Ins. Exh. v. Maxwell, 2017 Tenn. App. LEXIS 746 (Tenn. Ct. App. Nov. 15, 2017). The Chapmans purchased a residence from the Maxwells on March 7, 2014. Prior to the sale, the Maxwells completed a residential property disclosure in which they allegedly misrepresented the propensity of the property to flood. Five months after the purchase, the residence sustained damage as a result of two floods within three days. The Chapmans sued, alleging they relied on the Maxwells' representations regarding the propensity of the property to flood. The Chapmans further alleged that they sustained property damage as a result of the Maxwells' negligence and negligent misrepresentations. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Is the Issuance of a City Use Permit Referable? Not When It Is an Administrative Act

January 10, 2018 — Adam E. Lang - Real Estate Litigation Blog
Arizona’s Constitution gives electors in cities, towns, and counties the ability to refer legislation that was enacted by their local elected officials to the ballot for popular vote. Ariz. Const. art. IV, Pt. 1 § 1(8). But only legislative acts are referable; administrative acts are not. In general, a legislative act makes new law and creates policy, is permanent in nature, and is generally applied. On the other hand, an administrative act is one that executes and implements a law already in place. Wennerstrom v. City of Mesa, 169 Ariz. 485, 489-90, 821 P.2d 146, 150-51 (1991). For more than fifty years, Arizona courts have been clear: zoning and rezoning ordinances are legislative acts and therefore referable to popular vote. City of Phoenix v. Fehlner, 90 Ariz. 13, 17, 363 P.2d 607, 609 (1961) (holding that “what constitutes an appropriate zone is primarily for the legislature”); Fritz v. City of Kingman, 191 Ariz 432, 432, 957 P.2d 337, 337 (1998) (noting “we reaffirm our view that zoning decisions are legislative matters subject to referendum”); Pioneer Trust Co. of Arizona v. Pima Cty., 168 Ariz. 61, 64–65, 811 P.2d 22, 25–26 (1991) (holding “that, in Arizona, zoning decisions are legislative acts subject to referendum” and that even a “conditional approval of . . . rezoning was a legislative act”); Cottonwood Dev. v. Foothills Area Coal. of Tucson, Inc., 134 Ariz. 46, 653 P.2d 694 (1982) (analyzing whether zoning referendum complied with statutory requirements); Wait v. City of Scottsdale, 127 Ariz. 107, 108, 618 P.2d 601, 602 (1980) (noting “that the enactment and amendment of zoning ordinances constitute legislative action”); City of Phoenix v. Oglesby, 112 Ariz. 64, 65, 537 P.2d 934, 935 (1975) (“The matter of zoning is appropriately one for the legislative branch of government.”); Queen Creek Land & Cattle Corp. v. Yavapai Cty. Bd. of Sup’rs, 108 Ariz. 449, 452, 501 P.2d 391, 394 (1972) (denying an attempt to enjoin referendum on county’s zoning decision). Read the court decision
Read the full story...
Reprinted courtesy of Adam E. Lang, Snell & Wilmer
Mr. Lang may be contacted at alang@swlaw.com

Why Construction Law- An Update

May 07, 2015 — Christopher G. Hill – Construction Law Musings
Back in 2009, only a year or so after my first post here at Musings, I posted on why I’m in the field of construction law. Well, a lot has happened in the over 5 years since then, not the least of which is my move to solo practice in July of 2010 and the later certification as a mediator. As I sit here, I look back at the passage of time and the events between my last thoughts on this subject and now and wonder if my thoughts have changed? Frankly, not much has changed as far as my attitude toward the practice of construction law. Despite my kids occasionally rolling their eyes when I talk about a case of interest to me and their sometimes moniker for me as a “dirt lawyer,” I continue to find the representation of the construction professionals that I call clients and friends to be fulfilling and worthwhile. Even in the face of criticisms that we lawyers cause more problems that we solve, I firmly believe that I and other good construction lawyers can and do help avoid and anticipate more problems than I cause. As one of the few solo construction attorneys here in the Richmond area, if anything, I am more involved in the construction community. Between my continued and even increased involvement with the AGC of Virginia and my more recent appointment to the board of the Virginia State Bar‘s Construction Law and Public Contracts Section, I have gained even more insight into the workings of the legal and business landscapes of construction. With each new piece of information gained by such involvement, I see another side to the business of construction that I may not have thought of. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Construction Law Musings
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

BWB&O Partners are Recognized as 2022 AV Preeminent Attorneys by Martindale-Hubbell!

December 06, 2021 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations to BWB&O Partners on their recognition in Martindale-Hubbell® as AV Preeminent attorneys. This honor is given to attorneys who are ranked at the highest level of professional excellence for their legal expertise, communication skills, and ethical standards by their peers. Newport Beach Partner, Nicole Whyte Newport Beach Partner, Keith Bremer Newport Beach Partner, John Toohey Newport Beach Partner, Jeremy Johnson Woodland Hills Partner, John O'Meara Woodland Hills Partner, Patrick Au Arizona Partner, John Belanger Las Vegas Partner, Peter Brown Las Vegas Partner, Lucian Greco Las Vegas Partner, Anthony Garasi San Diego Partner, Vik Nagpal San Diego Partner, Alexander Giannetto Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Traub Lieberman Attorneys Recognized as 2021 New York – Metro Super Lawyers®

October 18, 2021 — Traub Lieberman
Traub Lieberman is pleased to announce that six Partners from the Hawthorne, NY Office have been selected to the 2021 New York - Metro Super Lawyers list. 2021 New York – Metro Super Lawyers

Jonathan Harwood – Professional Liability
Lisa Rolle – Construction Litigation
Christopher Russo – Professional Liability
Lisa Shrewsberry – Professional Liability
Stephen Straus – Insurance Coverage
Richard Traub – Insurance Coverage

Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

Washington High Court Holds Insurers Bound by Representations in Agent’s Certificates of Insurance

March 16, 2020 — Michael S. Levine & Michelle M. Spatz - Hunton Insurance Recovery Blog
In responding to a certified question from the Ninth Circuit in T-Mobile USA Inc. v. Selective Insurance Company of America, the Washington Supreme Court has held that an insurer is bound by representations regarding a party’s additional insured status contained in a certificate of insurance issued by the insurer’s authorized agent, even where the certificate contains language disclaiming any effect on coverage. To hold otherwise, the court noted, would render meaningless representations made on the insurer’s behalf and enable the insurer to mislead parties without consequence. The certified question and ruling stem from T-Mobile USA’s appeal of the district court’s summary judgment ruling in favor of Selective Insurance Company on T-Mobile USA’s breach of contract and declaratory judgment claims. Selective issued the insurance policy at issue to a contractor of T-Mobile Northeast, LLC, a wholly owned subsidiary of T-Mobile USA. Through endorsement, the policy extended “additional insured” status to T-Mobile NE because the contract between T-Mobile NE and the insured required that T-Mobile NE be added as an additional insured. Additional insured status was not, however, extended to T-Mobile USA, as T-Mobile USA had not entered a written contract with the insured. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Michelle M. Spatz, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Ms. Spatz may be contacted at mspatz@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

New Jersey Traffic Circle to be Eliminated after 12 Years of Discussion

February 04, 2014 — Beverley BevenFlorez-CDJ STAFF
The online publication New Jersey.com reported that on February 6th a “Pre-Construction Public Information hearing” will be held in Little Ferry, New Jersey, to discuss “the upcoming Route 46 Circle Elimination construction project.” The project includes “installation of a storm water pump station” as well as reconfiguring the circle into “a conventional four-way signalized intersection with a brand new traffic signal.” Conti Enterprises of Edison was awarded the bid “at a cost of $33,837,739,” according to New Jersey.com. The project, which has been discussed for over a decade, stalled over combining the elimination of the traffic school with rehabilitation of a bridge. Improvements include “replacing of the entire bridge deck, structural steel member replacement and strengthening, sidewalk replacement on both sides of the structure and substructure patching, crack sealing and reconstruction where needed.” The informational meeting will introduce the public to the engineer and contractor for the project. "This information session will help residents learn more about the project and what to expect as the state undertakes this work," Little Ferry Mayor Mauro Raguseo told New Jersey.com. "I wish we could fast forward to the completion of the project so we can realize the benefits without the headaches, but that's not reality. We all need to be prepared." Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES