Cambridge Massachusetts Building Expert Directory

Liquidated Damages Clause Not Enforced

October 02, 2023 — David R. Cook Jr. - Autry, Hall & Cook, LLP
A liquidated-damages clause was not enforced in a recent case before the Georgia Court of Appeals. The clause did not contain standard provisions that would normally allow a trial court to enforce the clause as written. As a result, the trial court looked beyond the contract to determine whether the City satisfied the requirements for enforcement of the liquidated-damages clause. Below are the relevant excerpts. City of Brookhaven v. Multiplex, LLC, A23A0843, 2023 WL 4779591 (Ga. Ct. App. July 27, 2023) Here, the Contract provides for “Liquidated Damages at the rate of $1,000.00 per calendar day” in the last paragraph of the Scope of Work addendum. The Contract lacks, however, any language indicating that the liquidated damages were not intended to be a penalty. See Fuqua Const. Co. v. Pillar Dev., Inc., 293 Ga. App. 462, 466, 667 S.E.2d 633 (2008) (rejecting use of parol evidence where the parties “explicitly agreed” in “unambiguous contract language” that the liquidated damages were not a penalty). Absent such language, the court can look to parol evidence in the record to determine the effect the provision was intended to have. See J.P. Carey Enterprises, 361 Ga. App. at 391-392 (1) (b), 864 S.E.2d 588 (looking to “extrinsic evidence” such as emails, documents, and deposition testimony to determine whether the damages provision at issue was a penalty); see also Gwinnett Clinic, Ltd. v. Boaten, 340 Ga. App. 598, 602-603, 798 S.E.2d 110 (2017) (“Shah’s testimony also suggested that one purpose of the liquidated damages provision was to deter employees from breaching the agreement”). Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Skyline Cockpit’s Game-Changing Tower Crane Teleoperation

August 21, 2023 — Aarni Heiskanen - AEC Business
In this episode of the AEC Business podcast, host Aarni Heiskanen interviews Zachi Flatto, CEO and co-founder of Skyline Cockpit. The startup offers a tower crane teleoperation, AI monitoring, and autonomous driving system. Zachi discusses the background of Skyline Cockpit, how they make construction safer and more efficient, and what technologies they use. A ground-breaking change in crane operation Zachi Flatto, the CEO and co-founder of Skyline Cockpit, is leading a startup that specializes in providing advanced technology solutions for tower crane operations. The company’s main objective is to eliminate the need for crane operators to climb 100 meters every morning and spend long hours operating the crane from such heights. Zachi firmly believes that in 2023, this traditional practice is no longer necessary. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Why Metro Atlanta Is the Poster Child for the US Housing Crisis

January 04, 2023 — Brentin Mock - Bloomberg
Last year, the Federal Reserve declared that not one of the 13 counties that make up metro Atlanta qualified as an affordable housing market. In many places, monthly housing costs consume more than 40% of homeowners’ incomes, well beyond the 30% threshold that the Federal Reserve uses to monitor market affordability. Accelerating housing prices have been the narrative for virtually every major US metro lately, but Atlanta is somewhat “paradigmatic” of the trend, according to Georgia State University urban studies professor Dan Immergluck. Since arriving in Atlanta in 2005, Immergluck has been tracking and documenting the direction of metro Atlanta’s housing conditions, focusing on segregation and gentrification patterns. His new book, Red Hot City: Housing, Race and Exclusion in 21st-Century Atlanta, released in October, is the culmination of much of that scholarship. What Red Hot City reveals is that while exorbitant house prices are typically the result of market forces, Atlanta can blame a lot of its own policy decisions over the last 20 years, particularly as it pertains to large civic projects like the BeltLine and Centennial Yards, a massive new development planned for south downtown Atlanta. Read the court decision
Read the full story...
Reprinted courtesy of Brentin Mock, Bloomberg

Newmeyer & Dillion Attorney Casey Quinn Selected to the 2017 Mountain States Super Lawyers Rising Stars List

June 15, 2017 — Newmeyer & Dillion LLP
LAS VEGAS, Nev. – JUNE 14, 2017 – Prominent business and real estate law firm Newmeyer & Dillion LLP is pleased to announce that litigation attorney Casey Quinn has been selected to the 2017 Mountain States Super Lawyers Rising Stars list. Each year, no more than 2.5 percent of lawyers are selected to receive this honor. Quinn will be recognized in the July 2017 issue of Mountain States Super Lawyers Magazine. Quinn, an associate in the Las Vegas office of Newmeyer & Dillion, focuses his practice in complex commercial and construction litigation. He represents a variety of business entities in commercial disputes, including contract claims, business torts, privacy lawsuits, defamation, and fraud. Quinn is the immediate-past chair of the Construction Law section of the State Bar of Nevada and has successfully argued before the Supreme Court of Nevada, as well as settled disputes through various forms of conflict resolution including mediation and arbitration. Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high-degree of peer recognition and professional achievement. The patented selection process includes independent research, peer nominations and peer evaluations. About Newmeyer & Dillion For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit http://www.newmeyeranddillion.com/. Read the court decision
Read the full story...
Reprinted courtesy of

Residential Construction: Shrinking Now, Growing Later?

August 17, 2011 — CDJ STAFF

Jim Haugey, the Chief Economist for Reed Construction Data noted that new residential construction spending fell 0.2% in June and a slightly larger drop of 0.5% in residential remodeling. While economic growth is still low, Haugey states that homebuilders have “record low inventories.” He forecasts a shrinkage of 1.5% in 2011, followed by about 20% growth in 2012.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

NTSB Cites Design Errors in Fatal Bridge Collapse

November 28, 2018 — Scott Judy - Engineering News-Record
Design errors may have played a role in the collapse of the 174-foot-long bridge span that was under construction at Florida International University, according to a Nov. 15 investigative update from the National Transportation Safety Board (NTSB). The structure, which was being constructed over live traffic along SW 8th Street, killed six when it suffered a sudden, catastrophic collapse on March 15. Read the court decision
Read the full story...
Reprinted courtesy of Scott Judy, ENR
Mr. Judy may be contacted at judys@enr.com

The Legal Landscape

June 17, 2024 — David McMillin - Construction Executive
The construction industry continues to change as new technologies reshape jobsites and new generations of leaders rethink the way companies should operate. But one piece of the puzzle remains very much the same: Everyone needs a good lawyer. According to the most recent edition of the Arcadis Construction Disputes Report, the average value of a dispute in the industry has soared to $42.8 million—a 42% year-over-year increase between 2021 and 2022. And based on how busy the attorneys at Construction Executive’s 2024 Top 50 Construction Law Firmshave been this year, there is no sign of legal issues becoming less important to builders and contractors. Every construction leader wants to spend more time and energy doing what they do best—building projects safely, efficiently and profitably—and less time thinking about the things that might land them in court. How can you best avoid big disputes bound for mediation, arbitration or litigation? What emerging rules and regulations should be on your radar as you develop strategies for success? While legal issues will never disappear, listening to what some of the best construction lawyers in the country—all members of 2024 Top 50 Construction Law Firms—are thinking about offers a helpful perspective on future-proofing your business against risk, liability and worse. Reprinted courtesy of David McMillin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Florida’s Fourth District Appeals Court Clarifies What Actions Satisfy Florida’s Construction Defect Statute of Repose

November 14, 2018 — Rahul Gogineni - The Subrogation Specialist
In Gindel v. Centex Homes, 2018 Fla.App. LEXIS 13019, Florida’s Fourth District Court of Appeal recently concluded that the date on which the plaintiffs provided a pre-suit notice in compliance with §558.004 of Florida’s construction defect Right-to-Cure statute, Fla. Stat. §§ 558.001 to 558.005, et. seq., is the date on which the plaintiff commenced a “civil action or proceeding,” i.e. an “action,” within the meaning of Florida’s construction defect statute of repose, Florida Statue § 95.11(3)(c). Thus, reversing the decision of the trial court, the Fourth District held that the plaintiffs timely-filed their construction defect action against the defendants. Read the court decision
Read the full story...
Reprinted courtesy of Rahul Gogineni, White and Williams LLP
Mr. Gogineni may be contacted at goginenir@whiteandwilliams.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES