FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

---

Construction Defect Scam Tied to Organized Crime?

July 31, 2013 — CDJ STAFF
The Las Vegas Review-Journal reports that the initial tip-off came from Scott Canepa, a construction defect attorney who alerted the FBI about Leon Benzer’s activities in taking over homeowner boards. Canepa learned that Nancy Quon was taking part in the scheme and went to the FBI with the information. After FBI officials met with Canepa, they launched an investigation, which they named “Operation GrandMaster.” Although a Benzer associate stated that Benzer claimed not to have ties to organized crime, and according to the Review-Journal, “preferred to think of himself as ‘just a bully,’” the case involves connections to a number of figures with ties to organized crime. Benzer with associated with John V. Spilotro, a lawyer whose uncle was an alleged overseer for Chicago organized crime operating in Las Vegas in the 70s and 80s. Another conspirator, Paul Citelli, reportedly has ties to organized crime in Buffalo. Read the court decision
Read the full story...
Reprinted courtesy of

---

Title II under ADA Applicable to Public Rights-of-Way, Parks and Other Recreation Areas

June 29, 2017 — Richard E. Morton - Haight Brown & Bonesteel LLP
Plaintiff Ivana Kirola, who suffers from cerebral palsy, sued the City and County of San Francisco, in a class action contending certain public areas, including rights-of-way, pools, parks and other recreation areas, did not meet the mandate of Title II of the American With Disabilities Act (Kirola v. City and County of San Francisco, 9th Circuit Court of Appeals, No. 14-17521, 2017 DJDAR 5982). Title II provides that no qualified individual with a disability “shall, by reason of such disability, be excluded from participation in or be denied the benefits of the services, programs, or activities of a public entity, or be subjected to discrimination by any such entity.” Title II’s implementing regulations mandate that each facility constructed after January 26, 1992 be “readily accessible to and usable by individuals with disabilities.” And, for each facility “altered after January 26, 1992,” the altered portion must, “to the maximum extent feasible,” be likewise accessible. The Federal Architectural and Transportation Barriers Compliance Board creates nonbinding Americans With Disabilities Act Accessibility Guidelines (ADAAG) to ensure compliance with Title II, and that the Department of Justice (DOJ) adopt its own binding regulations, consistent with the ADAAG standards. Here, the District Court interpreted ADAAG standards as not applying to public rights-of-way, parks, and playground facilities. The District Court concluded that none of Kirola’s experts were reliable in their interpretation of the standards and how the standards applied to the public rights-of-way, etc. Conversely, the District Court concluded that all of the city’s experts were reliable. It thus disregarded and discarded every ADAAG violation identified by Kirola’s experts, accepting only the small number of violations identified by the city’s experts. Read the court decision
Read the full story...
Reprinted courtesy of Richard E. Morton, Haight Brown & Bonesteel LLP
Mr. Morton may be contacted at rmorton@hbblaw.com

---

Wisconsin Supreme Court Holds that Subrogation Waiver Does Not Violate Statute Prohibiting Limitation on Tort Liability in Construction Contracts

October 21, 2019 — Gus Sara - The Subrogation Strategist
In Rural Mut. Ins. Co. v. Lester Bldgs., LLC 2019 WI 70, 2019 Wisc. LEXIS 272, the Supreme Court of Wisconsin considered whether a subrogation waiver clause in a construction contract between the defendant and the plaintiff’s insured violated Wisconsin statute § 895.447, which prohibits limitations of tort liability in construction contracts. The Supreme Court affirmed the lower court’s decision that the waiver clause did not violate the statute because it merely shifted the responsibility for the payment of damages to the defendant’s insurance company. The waiver clause did not limit or eliminate the defendant’s tort liability. This case establishes that while § 895.447 prohibits construction contracts from limiting tort liability, a subrogation waiver clause that merely shifts responsibility for the payment of damages from a tortfeasor to an insurer does not violate the statute and, thus, is enforceable. In Rural Mutual, the plaintiff’s insured, Jim Herman, Inc. (Herman), entered into a contract with Lester Buildings, LLC (Lester) to design and construct a barn on Herman’s property. The contract included a provision that stated the following: Both parties waive all rights against each other and any of their respective contractors, subcontractors and suppliers of any tier and any design professional engaged with respect to the Project, for recovery of any damages caused by casualty of other perils to the extent covered by property insurance applicable to the Work or the Project, except such rights as they have to the proceeds of such property insurance and to the extent necessary to recover amounts relating to deductibles of self-insured retentions applicable to insured losses. . . . This waiver of subrogation shall be effective notwithstanding allegations of fault, negligence, or indemnity obligation of any party seeking the benefit or production [sic] of such waiver. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

---

See the Stories That Drew the Most Readers to ENR.com in 2023

January 16, 2024 — C.J. Schexnayder - Engineering News-Record
As construction's very busy and eventful year nears its close and the sector awaits many more ups and downs in 2024, ENR offers a look back at the Top 20 news stories that most caught readers' attention across a broad market spectrum—from the construction start of the long-awaited $16 billion New York-New Jersey rail tunnel rebuild and winners shortlisted for the first $7 billion in U.S. government funds for developing clean-energy hydrogen hubs to the still unfolding legal battle over Las Vegas Sphere project complexities and why a Texas jury awarded $860 million in a fatal Texas crane collapse verdict. Reprinted courtesy of C.J. Schexnayder, Engineering News-Record Mr. Schexnayder may be contacted at schexnayderc@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

US Homes Face Costly Retrofits for Induction Stoves, EV Chargers

May 20, 2024 — Kendra Pierre-Louis - Bloomberg
Buyers of new homes in the US may find themselves saddled with electrical systems better suited to the 20th century than the 21st. The International Code Council, which sets model construction standards for new homes, was expected to include building electrification measures in its 2024 energy code on March 20. But following appeals lodged by industry groups, the ICC board moved the measures to the code’s appendices, effectively making them optional, as first reported by the Huffington Post. If new homes aren’t wired for increasing power needs from electric appliances and car chargers, it will bump the effort and cost of making such upgrades onto homeowners — a deterrent to going electric. Energy efficiency advocates say this could slow the pace of the energy transition, costing both jobs and the planet. Read the court decision
Read the full story...
Reprinted courtesy of Kendra Pierre-Louis, Bloomberg

---

Changes and Extra Work – Is There a Limit?

October 09, 2018 — Joseph R. Young - Smith Currie
Design and construction changes can be a challenge for everyone involved in a construction project. Designers and contractors endeavor to deliver a project that meets the owner’s needs, budget, and aesthetic considerations. As a project comes to fruition, the project frequently changes, and the parties must address and resolve the financial considerations of those changes and implement the changes at the project level. Often times the most critical aspect of a contractor’s financial success or failure of a construction project is its ability to manage changes. Contractors are sometimes faced with changes that are beyond the reasonable expectation of the original undertaking and have significant planning, scheduling, and cost implications that may not be considered or addressed in the contract’s changes clause. Changes of this magnitude may be considered “cardinal changes” and provide the contractor with recourse beyond restrictions imposed by the contract’s changes clause. But cardinal change is a risky basis for a contractor to refuse to perform additional or changed work. Even major changes can probably be more safely handled within the terms of the contract’s changes clause. Read the court decision
Read the full story...
Reprinted courtesy of Joseph R. Young, Smith Currie
Mr. Young may be contacted at jryoung@smithcurrie.com

---

Massachusetts Federal Court Holds No Coverage for Mold and Water Damage Claim

February 11, 2019 — Brian Margolies - TLSS Insurance Law Blog
In its recent decision in Clarendon National Ins. Co. v. Philadelphia Indemnity Ins. Co., 2019 WL 134614 (D. Mass. Jan. 8, 2019), the United States District Court for the District of Massachusetts had occasion to consider the application of a prior knowledge provision in the context of a claim for mold and water-related bodily injury and property damage. Philadelphia insured a condominium property management company under a general liability insurance policy for the period September 1, 2007 through September 1, 2008. In 2009, the insured was sued by a unit owner alleging bodily injury and property damage resulting from toxic mold conditions resulting from leaks that had been identified in her unit as early as 2004. Notably, the complaint alleged that mold was identified in 2006 and that repair efforts were undertaken, but that these efforts all proved unsuccessful. Plaintiff alleged that she was forced to vacate her apartment in 2008 as a result of the conditions. Read the court decision
Read the full story...
Reprinted courtesy of Brian Margolies, Traub Lieberman
Mr. Margolies may be contacted at bmargolies@tlsslaw.com

---