Cambridge Massachusetts Building Expert Directory

Difficult Task for Court to Analyze Delay and Disorder on Construction Project

August 23, 2021 — David Adelstein - Florida Construction Legal Updates
One of my favorites quotes from a case, and I am sure others in the construction industry feel the same way or can relate, is from the District of Columbia Court of Appeals in Blake Construction Co., Inc. v. C.J. Coakley Co., Inc., 431 A.2d 569, 575 (D.C. 1981):

We note parenthetically and at the outset that, except in the middle of a battlefield, nowhere must men coordinate the movement of other men and all materials in the midst of such chaos and with such limited certainty of present facts and future occurrences as in a huge construction project such as the building of this 100 million dollar hospital. Even the most painstaking planning frequently turns out to be mere conjecture and accommodation to changes must necessarily be of the rough, quick and ad hoc sort, analogous to ever-changing commands on the battlefield. Further, it is a difficult task for a court to be able to examine testimony and evidence in the quiet of a courtroom several years later concerning such confusion and then extract from them a determination of precisely when the disorder and constant readjustment, which is to be expected by any subcontractor on a job site, become so extreme, so debilitating and so unreasonable as to constitute a breach of contract between a contractor and a subcontractor.

Do you agree with this sentiment? The reality is that retrospectively analyzing delay on a complicated construction project with numerous moving parts on a day-by-day, hour-by-hour, basis is no easy feat. It is not easy for the parties and certainly not easy for courts to unravel. With every party claiming delay based on a retrospective analysis there will be another party with either a different delay analysis or providing credible cross examination as to flaws with the delay analysis. The same bodes true with loss of productivity / inefficiency claims and the particular case-specific facts are important, preferably with evidence such as photos, videos, notifications, daily reports, manpower reports, etc., supporting the facts. But the facts are complicated, and the delay analysis is complicated, and it is a difficult task for a trier of fact to unravel these facts. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Concrete Worker Wins Lawsuit and Settles with Other Defendant

December 04, 2013 — CDJ STAFF
Hildo De Franca was injured in 2010 while pouring concrete for a residence in Perkasie, Pennsylvania. According to the lawsuit, when a concrete line plugged, the truck operator increased pump pressure, despite this not being the appropriate procedure. Mr. De Franca was injured when the hose snapped back after the clog burst free. Mr. De Franca sued both the Trans-Fleet Concrete Inc. and Albino Concrete Construction. Mr. De Franca was employed by a third party, Girafa Construction Inc., which had been hired by Albino. Albino Construction settled with Mr. De Franca for $500,000. Trans-Fleet did not settle. The judgment against them was for $2.25 million, of which $2 million was for pain and suffering. As a result of the accident, Mr. De Franca suffered a mild brain injury and a compression fracture in his spine. Read the court decision
Read the full story...
Reprinted courtesy of

Sales of New Homes in U.S. Increased 5.4% in July to 507,000

August 26, 2015 — Shobhana Chandra – Bloomberg
Purchases of new homes in the U.S. rebounded in July, bolstering signs the real-estate market is picking up. Sales climbed 5.4 percent, the biggest gain this year, to a 507,000 annualized pace from a 481,000 rate in the prior month, a Commerce Department report showed Tuesday in Washington. The median forecast of 75 economists surveyed by Bloomberg called for 510,000. Demand had declined 7.7 percent in June. Demand for new properties is likely to keep expanding amid strong employment, low borrowing costs and a lack of available existing homes from which to choose. The improving outlook may spur more residential construction, contributing to the economic expansion in the second half of the year. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Professionals Could Face More Liability Exposure Following California Appellate Ruling

December 17, 2024 — Jamison Rayfield & Brian Slome - Lewis Brisbois
San Diego/San Francisco, Calif. - The California Court of Appeal recently reversed a summary judgment ruling in favor of a geotechnical engineering firm that had conducted a brief inspection of a residential construction project's footing trench for $360. The case arose when homeowner Cheryl Lynch experienced significant property damage after her home's foundation failed and the structure began subsiding into a slope. Lynch sued Peter & Associates for professional negligence and nuisance, despite having no direct contractual relationship with the firm, which had been hired by her contractor to perform the geotechnical inspection. The court distinguished this case from Bily v. Arthur Young & Co. (1992) 3 Cal.4th 370, which had limited auditors' professional duty to third parties, noting that Bily dealt with purely economic damages, whereas Lynch involved physical property damage, making Bily's policy concerns about unlimited liability inapplicable. The court emphasized that construction professional negligence cases, particularly those involving residential property damage, warrant a different analysis than cases involving economic loss. Reprinted courtesy of Jamison Rayfield, Lewis Brisbois and Brian Slome, Lewis Brisbois Mr. Rayfield may be contacted at Jamison.Rayfield@lewisbrisbois.com Mr. Slome may be contacted at Brian.Slome@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

Cyber Thieves Phish Away a $735K Payment to a Minnesota Contractor

May 06, 2024 — Richard Korman - Engineering News-Record
The contractor's project manager asked for money due, $735,000 under Payment Application 13, to be sent by the owner electronically. "Hi Rick," the project manager, whose first name is Jalen, wrote in an email dated Aug. 15. "Can we have payments remitted electronically as we currently have numerous uncleared checks on hold?" Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Wisconsin Supreme Court Holds Fire Damage Resulted from Single Occurrence

November 21, 2018 — Brian Margolies - TLSS Insurance Law Blog
In its recent decision in Secura Ins. v. Lyme St. Croix Forest Co., LLC 2018 WI 103 (Oct. 30, 2018), the Wisconsin Supreme Court had occasion to consider whether a forest fire that caused damage to several homes and properties should be considered a single or multiple occurrences. Secura insured Lyme St. Croix Forest Company under a general liability policy. Of relevance was the policy’s $500,000 sublimit of coverage for property damage due to fire arising from logging or lumbering operations, subject to a $2 million general policy aggregate limit. Lyme St. Croix sought coverage under the policy for a fire that resulted from its logging equipment. The fire lasted for three days, burning nearly 7,500 acres and causing damage to numerous homes and businesses. Read the court decision
Read the full story...
Reprinted courtesy of Brian Margolies, Traub Lieberman Straus & Shrewsberry LLP
Mr. Margolies may be contacted at bmargolies@tlsslaw.com

California Restricts Principles of “General” Personal Jurisdiction

April 01, 2015 — Kristian B. Moriarty and R. Bryan Martin – Haight Brown & Bonesteel LLP
In BNSF Railway Company v. Superior Court (Kralovetz) (Filed 3/27/2015, No. B260798), the California Court of Appeal, Second District, held a Delaware railroad corporation, with its principal place of business in Texas, was not subject to “general” personal jurisdiction in California, despite California housing 8.1% of the corporation’s total workforce, accounting for 6% of the corporation’s revenue, and containing just under 5% of its total track mileage. Plaintiff, Vicki Kralovetz, filed suit in California Superior Court against defendant, BNSF Railway Company (“BNSF”), and others, for wrongful death. Plaintiff contended her husband was exposed to asbestos products manufactured by BNSF in Kansas while working at a dismantling facility owned by BNSF’s predecessor in interest. Plaintiff claimed the exposure caused her husband to contract mesothelioma, which resulted in his death. Reprinted courtesy of Kristian B. Moriarty, Haight Brown & Bonesteel LLP and R. Bryan Martin, Haight Brown & Bonesteel LLP Mr. Moriarty may be contacted at mmoriarty@hbblaw.com Mr. Martin may be contacted at bmartin@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

White and Williams Recognizes Women’s History Month: Remembering Virginia Barton Wallace

April 08, 2024 — White and Williams LLP
March is Women’s History Month – a month dedicated to the accomplishments and history of women in the United States. The theme for International Women’s Day, which is this Thursday March 7, is “Inspire Inclusion.” White and Williams LLP is dedicated to understanding, valuing and inspiring inclusion in the field of law White and Williams is proud of the women who have become leaders in the firm’s history, starting with Virginia “Ginny” Barton Wallace, an extraordinarily accomplished pioneer among female attorneys. She joined the firm immediately after graduating from University of Pennsylvania School of Law in 1950, and in 1961, Ginny became the first woman to become the first female partner not only at White and Williams but also at any law firm in Philadelphia. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES